Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
Lessor’s Rights If Lessee fails to perform Lessee's obligations under this Paragraph 7, or under any other paragraph of this Lease, Lessor may at its option (but shall not be required to) enter upon the Premises after ten (10) days' prior written notice to Lessee (except in the case of an emergency, in which case no notice shall be required), perform such obligations on Lessee's behalf and put the same in good order, condition and repair, and the cost thereof together with interest thereon at the maximum rate then allowable by law shall become due and payable as additional rental to Lessor together with Lessee's next rental installment.
Xxxxxx’s Right to Transfer If all of the Shares proposed in the Notice to be transferred to a given Proposed Transferee are not purchased by the Company and/or its assignee(s) as provided in this Section 5, then the Holder may sell or otherwise transfer such Shares to that Proposed Transferee at the Offered Price or at a higher price, provided that such sale or other transfer is consummated within one hundred and twenty (120) days after the date of the Notice, that any such sale or other transfer is effected in accordance with any applicable securities laws and that the Proposed Transferee agrees in writing that the provisions of this Section 5 shall continue to apply to the Shares in the hands of such Proposed Transferee. If the Shares described in the Notice are not transferred to the Proposed Transferee within such period, a new Notice shall be given to the Company, and the Company and/or its assignees shall again be offered the Right of First Refusal before any Shares held by the Holder may be sold or otherwise transferred.
No Right to Set-Off The Recipient shall timely pay the full amount of Service Charges and Reimbursement Charges and shall not set-off, counterclaim or otherwise withhold any amount owed to the Provider under this Agreement on account of any obligation owed by the Provider to the Recipient.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
Lessor’s Right to Inspect Lessee shall permit Lessor and its authorized representatives as frequently as reasonably requested by Lessor to inspect the Leased Property and Lessee’s accounts and records pertaining thereto and make copies thereof, during usual business hours upon reasonable advance Notice, subject only to any business confidentiality requirements reasonably requested by Lessee.
Bank’s Rights 3.1 The Bank shall have a right to:
(a) Recover the Rent and any other cost incurred by the Bank in relation to the Locker to the debit of the Customer’s account, in the event the same is not paid by the Customer, when due; and
(b) Refuse access to the Locker-
(i) In case the rent due on the Locker remains unpaid; and
(ii) Customer fails to provide proof of identity when demanded by the Bank, at the time of seeking access to the Locker.
