CLAIM NOTICE AND RESOLUTION PROCEDURE Sample Clauses

CLAIM NOTICE AND RESOLUTION PROCEDURE a) In the event Contractor has a claim or request for a time extension, additional compensation., any other adjustment of the Contract terms, or any dispute arising out of the work (hereinafter “Claim”), Contractor shall notify Company in writing within five (5) working days following the occurrence of the event giving rise to the Claim. b) As soon as practicable after Claim notification, Contractor shall submit the Claim to Company with all supporting information and documentation. Contractor shall also respond promptly to all Company inquiries about the Claim and its basis. c) Any Claim not disposed of by agreement shall be decided by Company, which shall provide a written decision to Contractor. Such decision shall be final unless Contractor, within thirty (30) calendar days after such receipt of Company’s decision, provides to Company a written protest, stating clearly and in detail the basis thereof. It is agreed that Contractor’s failure to protest Company’s decision shall constitute a waiver by Contractor of its Claim. Even if a Claim arises, Contractor shall continue its performance of this Contract.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
CLAIM NOTICE AND RESOLUTION PROCEDURE. If, at any time, Company determines the progress of the Work is unsatisfactory, Contractor may be directed to work overtime, increase its workforce, work additional shifts, add supervision or take other corrective actions to ensure the timely and orderly prosecution of the Work, at no additional cost to Company.
Sample 1Sample 2
CLAIM NOTICE AND RESOLUTION PROCEDURE. ‌ In the event Consultant has a claim or request for a time extension, additional compensation, any other adjustment of the Contract terms, or any dispute arising under the Contract (hereinafter “Claim”), Consultant shall provide Company with Notice of such Claim within five (5) business days following the occurrence of the event giving rise to the Claim. Consultant’s failure to give Notice as required will constitute a waiver of all of Consultant’s rights with respect to the Claim. As soon as practicable after Claim notification, Consultant shall submit the Claim to Company with all supporting information and documentation. Consultant shall also respond promptly to all Company inquiries about the Claim and its basis. Any Claim that is not disposed of by mutual agreement between the Parties shall be decided by Company, which shall provide a written decision to Consultant. Such decision shall be final unless Consultant, within thirty (30) days after such receipt of Company's decision, provides to Company a written protest, stating clearly and in detail the basis thereof. Consultant's failure to protest Company's decision within that time period shall constitute a waiver by Consultant of its right to dispute the decision. Even if a Claim arises, Consultant shall continue its performance of this Contract.‌
Sample 1
CLAIM NOTICE AND RESOLUTION PROCEDURE. In the event Contractor has a claim or request for a time extension, additional compensation, any other adjustment of the Contract terms (including without limitation claims with respect to any Force Majeure Event), or any dispute arising out of the Work (hereinafter “Claim”), Contractor shall provide Company with Notice of such Claim within five (5) business days following the occurrence of the event giving rise to the Claim. Contractor’s failure to give Notice as required will constitute a waiver of all of Contractor’s rights with respect to the Claim. As soon as practicable after Claim notification, but in no event less than ten (10) days thereafter, Contractor shall submit the Claim to Company with all supporting information and documentation. Contractor shall also respond promptly to all Company inquiries about the Claim and its basis. If Contractor fails to provide such Company Claim details within such period, such failure will constitute a waiver of all of Contractor’s rights with respect to the Claim. Any Claim, which is not disposed of by mutual agreement between the Parties, shall be decided by Company which shall provide a written Notice to Contractor. Such decision shall be final unless Contractor, within thirty (30) calendar days after such receipt of Company’s decision, provides to Company a written protest, stating clearly and in detail the basis thereof. Contractor’s failure to protest Company’s decision within that time period shall constitute a waiver by Contractor of its right to dispute the decision. Even if a Claim arises, Contractor shall continue its performance of the Work.
Sample 1Sample 2
CLAIM NOTICE AND RESOLUTION PROCEDURE. In the event Associate has a claim or request for a time extension, additional compensation, any other adjustment of the Contract terms, or any dispute arising out of the Work (hereinafter "Claim"), Associate shall notify Company in writing within five (5) business days following the occurrence of the event giving rise to the Claim. Associate's failure to give notice as required will constitute a waiver of all of Associate's rights with respect to the Claim. As soon as practicable after Claim notification, Associate shall submit the Claim to Company with all supporting information and documentation. Associate shall also respond promptly to all Company inquiries about the Claim and its basis. Any Claim, which is not disposed of by mutual agreement between the Parties, shall be decided by Company, which shall provide a written decision to Associate. Such decision shall be final unless Associate, within thirty (30) calendar days after such receipt of Company's decision, provides to Company a written protest, stating clearly and in detail the basis thereof. It is agreed that Associate's failure to protest Company's decision shall constitute a waiver by Associate of its Claim. If after receipt of written protest a mutal agreement between the parties cannot be reached, Associate and Company agree to third party mediation to settle said claim. Even if a Claim arises, Associate shall continue its performance of this Contract.
Sample 1Sample 2
CLAIM NOTICE AND RESOLUTION PROCEDURE. No change shall be binding upon Owner until a change order is executed by an authorized representative of Owner which EXPRESSLY STATES THAT IT CONSTITUTES A CHANGE ORDER TO THIS CONTRACT. THE ISSUANCE OF INFORMATION, ADVICE, APPROVALS, OR INSTRUCTIONS BY ANYONE OTHER THAN THE AUTHORIZED COMPANY REPRESENTATIVE SHALL NOT CONSTITUTE AN AUTHORIZED CHANGE ORDER PURSUANT TO THIS ARTICLE.
Sample 1

Related to CLAIM NOTICE AND RESOLUTION PROCEDURE

  • Resolution Procedure a. Step 1 i. The complainant, if comfortable with that approach, may choose to speak to or correspond directly with the alleged harasser to express their feelings about the situation. ii. Before proceeding to Step 2, the complainant may approach their administrative officer, staff rep or other contact person to discuss potential means of resolving the complaint and to request assistance in resolving the matter. If the matter is resolved to the complainant's satisfaction the matter is deemed to be resolved. Refer to Article E.

  • DISPUTES RESOLUTION PROCEDURE 10.1 A major objective of this Agreement is to eliminate lost time and/or production arising out of disputes or grievances. The Parties to this Agreement are committed to complying with the terms of this procedure.

  • Governing Law and Resolution of Disputes 14.1 The execution, effectiveness, construction, performance, amendment and termination of this Agreement and the resolution of disputes hereunder shall be governed by the laws of China. 14.2 In the event of any dispute with respect to the construction and performance of this Agreement, the Parties shall first resolve the dispute through friendly negotiations. In the event the Parties fail to reach an agreement on the dispute within 30 days after either Party’s request to the other Parties for resolution of the dispute through negotiations, either Party may submit the relevant dispute to the China International Economic and Trade Arbitration Commission for arbitration, in accordance with its Arbitration Rules. The arbitration shall be conducted in Beijing. The arbitration award shall be final and binding on all Parties. 14.3 Upon the occurrence of any disputes arising from the construction and performance of this Agreement or during the pending arbitration of any dispute, except for the matters under dispute, the Parties to this Agreement shall continue to exercise their respective rights under this Agreement and perform their respective obligations under this Agreement.

  • Issue Resolution Procedures As soon as possible after any occupational health and safety issue has been reported, the company’s or management representative and elected safety representative must meet to try to resolve the issue. The resolution of the issue must take into account those of the following factors that are relevant: o Whether the hazard or risk can be isolated o The number and location of employees affected o Whether appropriate temporary measures are possible or desirable o Whether environmental monitoring is desirable o The time that may elapse before the hazard or risk is permanently corrected o Who is responsible for performing work and overseeing the removal of the hazard or risk. As soon as possible after the resolution of an issue, details of the agreement must be brought to the attention of affected employees in an appropriate manner. Should the matter not be resolved, the issue shall be dealt with in line with Clause 20 of the VBIA “Safety Disputes Resolution Procedure”.

  • Methods of Resolution of Disputes In the event of any dispute with respect to the construction and performance of this Agreement, the Parties shall first resolve the dispute through friendly negotiations. In the event the Parties fail to reach an agreement on the dispute within 30 days after either Party’s request to the other Parties for resolution of the dispute through negotiations, either Party may submit the relevant dispute to the China International Economic and Trade Arbitration Commission for arbitration, in accordance with its arbitration rules. The arbitration shall be conducted in Beijing. The arbitration award shall be final and binding on all Parties.

  • Resolution of Dispute Any dispute regarding this Agreement (including without limitation its validity, interpretation, performance, enforcement, termination and damages) shall be determined in accordance with the laws of the State of California, the United States of America. Any action under this paragraph shall not preclude any party hereto from seeking injunctive or other legal relief to which each party may be entitled.

  • Governing Law; Resolution of Disputes This Agreement and the rights and obligations hereunder shall be governed by and construed in accordance with the laws of the State of Wisconsin. Any dispute arising out of this Agreement shall, at the Executive’s election, be determined by arbitration under the rules of the American Arbitration Association then in effect (in which case both parties shall be bound by the arbitration award) or by litigation. Whether the dispute is to be settled by arbitration or litigation, the venue for the arbitration or litigation shall be Milwaukee, Wisconsin or, at the Executive’s election, if the Executive is not then residing or working in the Milwaukee, Wisconsin metropolitan area, in the judicial district encompassing the city in which the Executive resides; provided, that, if the Executive is not then residing in the United States, the election of the Executive with respect to such venue shall be either Milwaukee, Wisconsin or in the judicial district encompassing that city in the United States among the thirty cities having the largest population (as determined by the most recent United States Census data available at the Termination Date) which is closest to the Executive’s residence. The parties consent to personal jurisdiction in each trial court in the selected venue having subject matter jurisdiction notwithstanding their residence or situs, and each party irrevocably consents to service of process in the manner provided hereunder for the giving of notices.

  • Amicable Resolution (a) Save where expressly stated to the contrary in this Agreement, any dispute, difference or controversy of whatever nature between the Parties, howsoever arising under, out of or in relation to this Agreement (the "Dispute") shall in the first instance be attempted to be resolved amicably in accordance with the procedure set forth in Clause 12.1 (b). (b) Either Party may require such Dispute to be referred to the Authority, and the Chief Executive Officer/Director/Partner of the Developer for the time being, for amicable settlement. Upon such reference, the two shall meet at the earliest mutual convenience and in any event within 15 days of such reference to discuss and attempt to amicably resolve the Dispute. If the Dispute is not amicably settled within 15 (fifteen) days of such meeting between the two, either Party may refer the Dispute to arbitration in accordance with the provisions of Clause 12.2.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

  • Informal Resolution of Disputes 10.5.1 Upon receipt by one Party of notice of a dispute by the other Party pursuant to Section 10.3 or Section 10.4.5, each Party will appoint a knowledgeable, responsible representative to meet and negotiate in good faith to resolve any dispute arising under this Agreement. The location, form, frequency, duration, and conclusion of these discussions will be left to the discretion of the representatives. Upon agreement, the representatives may utilize other alternative Dispute Resolution procedures such as mediation to assist in the negotiations. Discussions and the correspondence among the representatives for purposes of settlement are exempt from discovery and production and will not be admissible in the arbitration described below or in any lawsuit without the concurrence of both Parties. Documents identified in or provided with such communications that were not prepared for purposes of the negotiations are not so exempted, and, if otherwise admissible, may be admitted in evidence in the arbitration or lawsuit.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!