Claims for Extra Cost or Time Sample Clauses

Claims for Extra Cost or Time. If the Contractor claims that any instructions by drawings or otherwise, after the date of the Construction Agreement, involve extra costs under this Contract that were not included in the original bid, or require an extension in the construction schedule, the Contractor shall give the Owner and the Architect written notice thereof no later than ten (10) days after the receipt of such instructions, and in any event before proceeding to execute the Work, except in an emergency endangering life or property, and the procedure shall then be as provided for changes in the Work. No such claim shall be valid unless so made. Any change in the Contract amount or construction schedule must be authorized by Change Order.
Sample 1
AutoNDA by SimpleDocs
Claims for Extra Cost or Time. After the date of this Agreement, if the Design/Builder claims that it is entitled to extra costs or time under this Agreement that were not included in the original contract, the Design/Builder shall give the Owner written notice thereof no later than ten (10) days after discovery of the claim and shall not execute additional Work, except in an emergency as set forth in Section 7.08, and the procedure shall then be as provided for changes in the Work. No such claim shall be valid unless so made. Any undisputed change in the GMP amount or Project completion date(s) shall be authorized by Change Order.
Sample 1

Related to Claims for Extra Cost or Time

  • PROCEDURES FOR EVALUATION A. The evaluations of school year employees covered by this agreement shall be completed no later than May 30 of each school year for 9-month employees and by June 30 for 10/12-month employees. The evaluation shall be reviewed with the employee, with a copy given to the employee at the conclusion of the review. An employee may present written comments, which shall be attached to the written evaluation document. The evaluator and employee shall sign the evaluation document. The employee’s signature does not constitute approval or disapproval, but only that the evaluation has been reviewed with the employee.

  • Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.

  • Liability for expenses Each party will pay its own expenses incurred in negotiating, executing, stamping and registering this Participation Agreement.

  • Are There Penalties for Early Distribution from a Traditional IRA? Distributions from your Traditional IRA made before age 59½ will be subject (in addition to ordinary income tax) to a 10% non-deductible penalty tax unless (i) the distribution is a return of non-deductible contributions, (ii) the distribution is made because of your death, disability, or as part of a series of substantially equal periodic payments over your life expectancy or the joint life expectancy of you and your beneficiary, (iii) the distribution is made for unreimbursed medical expenses in excess of 7.5% of adjusted gross income or is made for reimbursement of medical premiums while you are unemployed, (iv) the distribution is made to pay for certain higher education expenses for you, your spouse, your child, your grandchild, or the child or grandchild of your spouse, (v) subject to various limits, the distribution is used to purchase a first home or, in limited cases, a second or subsequent home for you, your spouse, or you or your spouse’s child, grandchild or ancestor, (vi) the distribution is an exempt withdrawal of an excess contribution, (vii) the distribution is made due to an IRS tax levy, or (viii) the distribution is made by member of the Armed Forces Reserve called to active duty for either a period exceeding 179 days or for an indefinite period and is effective for members called to active duty. The penalty tax may also be avoided if the distribution is rolled over to another individual retirement account. See Item 9 above for special rules applicable to distributions from a SIMPLE IRA.

  • No Liability for Errors CenturyLink is not liable for mistakes in their respective signaling networks (including but not limited to signaling links and Signaling Transfer Points (STPs)) and call- related databases (including but not limited to the Line Information Database (LIDB), Toll Free Calling database, local Number Portability database, Advanced Intelligent Network databases, Calling Name database (CNAM), 911/E911 databases, and OS/DA databases).

  • Criteria for Evaluation Criteria for employee performance review shall be made available to the employee before the start of the evaluation period and shall remain unchanged during the evaluation period unless the employee is made aware of the changes.

  • Issues for Expedited Arbitration (a) All grievances except those relating to the following shall be resolved by expedited arbitration:

  • Requests for Exclusion Any Settlement Class member who wishes to opt-out of the Settlement must complete and mail a Request for Exclusion (defined below) to the Settlement Administrator within sixty (60) calendar days of the date of the initial mailing of the Notice Packets (the “Response Deadline").

  • Transportation for Employees Transportation will be provided to employees who are required to work other than their normal working hours, and who must travel to or from their home during the hours between 11:30 p.m. and 6:00 a.m. and when convenient public transportation or other transportation facilities are not available. An employee shall be reimbursed for the cost of commercial transportation within their headquarters area, upon presentation of receipts.

  • Compensation for Employees Employees shall receive compensation at the biweekly or hourly rate for the range and step or flat rate assigned to the class in which they are employed.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!