Subcontracting for the Provision of Services (a) The parties acknowledge that, subject to the provisions of the Enabling Legislation, the HSP may subcontract the provision of some or all of the Services. For the purposes of this Agreement, actions taken or not taken by the subcontractor, and Services provided by the subcontractor, will be deemed actions taken or not taken by the HSP, and Services provided by the HSP.
(b) When entering into a subcontract the HSP agrees that the terms of the subcontract will enable the HSP to meet its obligations under this Agreement. Without limiting the foregoing, the HSP will include a provision that permits the Funder or its authorized representatives, to audit the subcontractor in respect of the subcontract if the Funder or its authorized representatives determines that such an audit would be necessary to confirm that the HSP has complied with the terms of this Agreement.
(c) Nothing contained in this Agreement or a subcontract will create a contractual relationship between any subcontractor or its directors, officers, employees, agents, partners, affiliates or volunteers and the Funder.
(d) When entering into a subcontract, the HSP agrees that the terms of the subcontract will enable the HSP to meet its obligations under the FLSA.
Performance of Service; Limitation of Liability A. PFS shall exercise reasonable care in the performance of its duties under this Agreement. PFS shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust in connection with matters to which this Agreement relates, including losses resulting from mechanical breakdowns or the failure of communication or power supplies beyond PFS's control, except a loss arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence, or willful misconduct on its part in the performance of its duties under this Agreement. Notwithstanding any other provision of this Agreement, if PFS has exercised reasonable care in the performance of its duties under this Agreement, the Trust shall indemnify and hold harmless PFS from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which PFS may sustain or incur or which may be asserted against PFS by any person arising out of any action taken or omitted to be taken by it in performing the services hereunder, except for any and all claims, demands, losses, expenses, and liabilities arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence or from willful misconduct on its part in performance of its duties under this Agreement, (i) in accordance with the foregoing standards, or (ii) in reliance upon any written or oral instruction provided to PFS by any duly authorized officer of the Trust, such duly authorized officer to be included in a list of authorized officers furnished to PFS and as amended from time to time in writing by resolution of the Board of Trustees of the Trust. PFS shall indemnify and hold the Trust harmless from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which the Trust may sustain or incur or which may be asserted against the Trust by any person arising out of any action taken or omitted to be taken by PFS as a result of PFS's refusal or failure to comply with the terms of this Agreement, its bad faith, negligence, or willful misconduct. In the event of a mechanical breakdown or failure of communication or power supplies beyond its control, PFS shall take all reasonable steps to minimize service interruptions for any period that such interruption continues beyond PFS's control. PFS will make every reasonable effort to restore any lost or damaged data and correct any errors resulting from such a breakdown at the expense of PFS. PFS agrees that it shall, at all times, have reasonable contingency plans with appropriate parties, making reasonable provision for emergency use of electrical data processing equipment to the extent appropriate equipment is available. Representatives of the Trust shall be entitled to inspect PFS's premises and operating capabilities at any time during regular business hours of PFS, upon reasonable notice to PFS.
B. In order that the indemnification provisions contained in this section shall apply, it is understood that if in any case the indemnitor may be asked to indemnify or hold the indemnitee harmless, the indemnitor shall be fully and promptly advised of all pertinent facts concerning the situation in question, and it is further understood that the indemnitee will use all reasonable care to notify the indemnitor promptly concerning any situation which presents or appears likely to present the probability of a claim for indemnification. The indemnitor shall have the option to defend the indemnitee against any claim which may be the subject of this indemnification. In the event that the indemnitor so elects, it will so notify the indemnitee and thereupon the indemnitor shall take over complete defense of the claim, and the indemnitee shall in such situation initiate no further legal or other expenses for which it shall seek indemnification under this section. The indemnitee shall in no case confess any claim or make any compromise in any case in which the indemnitor will be asked to indemnify the indemnitee except with the indemnitor's prior written consent.
C. PFS is hereby expressly put on notice of the limitation of shareholder, Trustee, officer, employee or agent liability as set forth in the Declaration of Trust of the Trust and agrees that obligations assumed by the Trust pursuant to this Agreement shall be limited in all cases to the Trust and its assets, and if the liability relates to one or more Funds, the obligations hereunder shall be limited to the respective assets of such Fund. PFS further agrees that it shall not seek satisfaction of any such obligation from any shareholder of a Fund, nor from any Trustee, officer, employee or agent of the Trust.
Provision of Services by Third Parties The Administrator shall, to the extent it determines that it would be advisable in connection with or incidental to the activities contemplated hereby, arrange for and coordinate the services of other professionals, experts and consultants to provide any or all of the Services, in which case, the costs and expenses of such third parties for providing such services shall be borne by the Administrator other than as set forth in Section 3; it being understood that the Administrator shall not charge to the Issuer any fees in addition thereto with respect to such outsourced Painting-Level Services that are described in Section 1(a)(i) and Entity-Level Services described in Section 1(a)(ii), but the Administrator shall be entitled to reimbursement for third party costs incurred in connection with Non-Routine Services described in Section 1(a)(iii) as set forth in Section 3(b). Reimbursement for Non-Routine Services shall be reimbursed by the Issuer out of the proceeds from a sale of the Painting. In addition, Masterworks may determine to sell the Painting without engaging a third-party intermediary, in which event, the Administrator would charge the buyer of the Painting a reasonable fee not to exceed the lowest published buyer’s premium charged by Sotheby’s, Christie’s or Pxxxxxxx in effect at such time.
Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .
Service Warranty Provider has carefully examined and analyzed the provisions of this Agreement, including but not limited to all exhibits attached and incorporated into it, and can and will perform, or cause, the Services to be performed in strict accordance with the provisions and requirements of the Agreement. Services will be performed in a timely, professional and workmanlike manner in accordance with all applicable industry and professional standards.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Performance Warranty Contractor shall warrant all work under this Contract, taking necessary steps and precautions to perform the work to County’s satisfaction. Contractor shall be responsible for the professional quality, technical assurance, timely completion and coordination of all documentation and other goods/services furnished by the Contractor under this Contract. Contractor shall perform all work diligently, carefully, and in a good and workmanlike manner; shall furnish all necessary labor, supervision, machinery, equipment, materials, and supplies, shall at its sole expense obtain and maintain all permits and licenses required by public authorities, including those of County required in its governmental capacity, in connection with performance of the work. If permitted to subcontract, Contractor shall be fully responsible for all work performed by subcontractors.
Service Warranties Contractor warrants that: (i) the Services will be rendered with promptness and diligence and will be executed in a workmanlike manner, in accordance with the practices and professional standards used in well-managed operations performing services similar to the Services; and (ii) Contractor will perform the Services in the most cost-effective manner consistent with the required level of quality and performance. Contractor warrants that each Deliverable will conform to and perform in accordance with the requirements of this Agreement and all applicable specifications and documentation. For each such Deliverable, the foregoing warranty shall commence for such Deliverable upon the JBE’s acceptance of such Deliverable, and shall continue for a period of one (1) year following acceptance. In the event any Deliverable does not to conform to the foregoing warranty, Contractor shall promptly correct all nonconformities to the satisfaction of the JBE.
Product and Service Warranties 21- SECTION 3.30
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
