Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Department’s Contract Manager The Department’s Contract Manager, who is primarily responsible for the Department’s oversight of the Contract, will be identified in a separate writing to the Contractor upon Contract signing in the following format: Department’s Contract Manager Name Department’s Name Department’s Physical Address Department’s Telephone # Department’s Email Address If the Department changes the Contract Manager, the Department will notify the Contractor. Such a change does not require an amendment to the Contract.
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.
Service Core Allowance The company shall pay $0.95 per hour for all work carried out in construction of service core. This allowance will be adjusted annually (effective from 1 June) in accordance with CPI movements (All Groups, Melbourne) for the preceding 12 months to March (increases to be rounded to the nearest 5 cents).
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Longevity Payments (a) Longevity payments as set out in the salary schedule in Appendix A-1 (Interest Arbitration ineligible employees) and Appendix A-2 (Interest Arbitration eligible employees) will be provided to eligible employees upon completion of 10, 15, 20 and 25 years of continuous service. Continuous service shall mean time in a title or combination of titles which have existed and/or presently exist in the Security Services Unit, Agency Police Services Unit or Security Supervisors Unit. Such payment will be added to base pay effective on the payroll period which next begins following the actual completion of 10, 15, 20 and 25 years of continuous service. (b) In no event may an employee's basic annual salary exceed the longevity maximum of the salary grade as the result of the longevity payment or adjustment. (c) Employees whose basic annual salary after the application of the general increase and implementation of the new salary schedule is above the job rate will be considered to have received longevity payments in the amount by which their basic annual salary exceeds the job rate for their grade. (d) Such longevity payments will be added to and considered part of base pay for all purposes except for determining an employee's change in salary upon movement to a different salary grade and his potential for movement to the job rate of the new grade, after which determination the appropriate longevity payments will be restored. (e) The longevity amount for all employees will be adjusted to reflect the longevity payments which are appropriate to their current salary grade.
Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:
Site Allowance All new construction and extension/refurbishment work having a project value in excess of $2.0m will attract the then current City of Melbourne Site Allowance.
