Content of the PAL Sample Clauses

Content of the PAL. The PAL issued by the DOT to the Municipality shall set forth, at a minimum: (a) the Funding source(s), the related government Funding authorization or program information, and the associated Funding ratio between the federal government, the DOT, and the Municipality, as applicable, for the Construction Project; (b) the maximum reimbursement or payment to the Municipality under the PAL; (c) an estimated cost break-down for all work under the Construction Project; (d) an amount for Contingencies, which upon written authorization from the DOT shall be available to fund required work or change in costs, as approved by DOT, via the Construction Order process and in accordance with applicable federal requirements and in accordance Municipality Construction Manual; (e) the amount of the Demand Deposit(s) due to the DOT from the Municipality for the Municipality’s proportionate share of applicable costs for work under the Construction Project, as determined by the Funding ratio; (f) the Project Amount; and (g) any applicable affirmative action goal(s) assigned with respect to work on the Construction Project, as follows: (1) if the Construction Project receives federal participation in Funding, the DBE goal assigned by the DOT applicable to the Prime Contractor, and additionally, where the Municipality retains an Inspection Consultant to perform the Inspection Activities, the DBE goal assigned by the DOT to the Inspection Consultant. If federal funds are not used to fund the Inspection Activities on the Construction Project, then no DBE goal will be assigned for the Inspection Activities; (2) if the Construction Project receives DOT Funding, and no federal participation in Funding, the SBE goal assigned by the DOT applicable to the Prime Contractor, and additionally, where the Municipality retains an Inspection Consultant, the SBE goal assigned to the Inspection Consultant; or (3) regardless of the Funding source(s), the SBPPP goal assigned by the DOT applicable to the Prime Contractor, and additionally, where the Municipality retains an Inspection Consultant, the SBPPP goal assigned to the Inspection Consultant. (h) Any applicable Transportation Facilities or Transportation Amenities installed or constructed within State owned rights-of-way that will be maintained by the Municipality in accordance with the applicable PAL, subject to the review and approval by the DOT prior to the Municipality commencing maintenance. The Municipality shall comply with the applica...
AutoNDA by SimpleDocs
Content of the PAL. The PAL issued by the DOT to the Municipality shall set forth, at a minimum: (a) the Funding source(s), the related government Funding authorization or program information, and the associated Funding ratio between the DOT, and the Municipality, as applicable, for the Construction Project; (b) the maximum payment to the Municipality under the PAL; (c) an estimated cost break-down for all work under the Construction Project; (d) as may be applicable, the amount of the Demand Deposit(s), due to the DOT from the Municipality for the Municipality’s proportionate share of applicable costs for work under the Construction Project, as determined by the Funding ratio; (e) the Project Amount; and (f) any applicable affirmative action goal(s) , as follows: (1) the SBE or SBPPP goal as assigned by the DOT with respect to work on the Construction Project applicable to the Prime Contractor, and additionally, where the Municipality retains an Inspection Consultant, the SBE or SBPPP goal assigned to the Inspection Consultant; or (2) reference to the Municipality’s requirement to comply with its affirmative action goal setting requirements imposed pursuant to State law at § 4a-60g(b) of the Connecticut General Statutes, as may be revised, and associated reporting to the Commission on Human Rights and Opportunities.
Content of the PAL. The DOT shall issue a PAL to the Municipality which will set forth, at least: (a) the funding source, the related federal and DOT program information, and the associated funding ratio between the federal government, the DOT, and the Municipality, as applicable, for the Construction Project; (b) the estimated cost for all work under the Construction Project; (c) the amount of the Demand Deposit(s) due to the DOT from the Municipality for the Municipality’s proportionate share of applicable costs for work under the Construction Project; and (d) the Project Amount.

Related to Content of the PAL

  • Intent of the Parties Except as provided in the next sentence, the sole procedure to resolve any claim arising out of or relating to this Agreement or any related agreement is the dispute resolution procedure set forth in this Article Eighteen. Either Party may seek a preliminary injunction or other provisional judicial remedy if such action is necessary to prevent irreparable harm or preserve the status quo, in which case both Parties nonetheless will continue to pursue resolution of the dispute by means of this procedure.

  • AGREEMENT OF THE PARTIES The language used in this Agreement will be deemed to be the language chosen by the parties hereto to express their mutual intent, and no rule of strict construction will be applied against any party hereto. Neither Executive nor the Company shall be entitled to any presumption in connection with any determination made hereunder in connection with any arbitration, judicial or administrative proceeding relating to or arising under this Agreement.

  • Development of the Property Except as modified by this Agreement, the Development and the Property will be developed in accordance with all applicable local, state, and federal regulations, including but not limited to the City’s ordinances and the zoning regulations applicable to the Property, and such amendments to City ordinances and regulations that that may be applied to the Development and the Property under Chapter 245, Texas Local Government Code, and good engineering practices (the “Applicable Regulations”). If there is a conflict between the Applicable Regulations and the Development Standards, the Development Standards shall control.

  • Development of the Project 4.1 TSP's obligations in development of the Project: a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project; b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with: i. the Electricity Act and the Rules made thereof; ii. the Grid Code; iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020. iv. Safety/ security Guidelines laid down by the Government; v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement; c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code. d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement; e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities; f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities; g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities; h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this; i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India; j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above. k. to comply with all its obligations undertaken in this Agreement. 4.2 Roles of the Nodal Agency in implementation of the Project: 4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia: a. appoint an Independent Engineer within 90 days of the Effective Date b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project; c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and f. perform any other responsibility (ies) as specified in this Agreement.

  • Maintenance of the Property Neither Broker nor Brokerage Firm is responsible for maintenance of the 324 Property nor are they liable for damage of any kind occurring to the Property, unless such damage is caused by their negligence or 325 intentional misconduct.

  • Cooperation of the Parties The Seller undertakes to notify the Buyer of any obstacles on his part, which may negatively influence proper and timely delivery of the Equipment.

  • Preservation, Maintenance, and Protection of the Property Inspections. Borrower will not destroy, damage, or impair the Property, allow the Property to deteriorate, or commit waste on the Property. Whether or not Borrower is residing in the Property, Borrower must maintain the Property in order to prevent the Property from deteriorating or decreasing in value due to its condition. Unless Lender determines pursuant to Section 5 that repair or restoration is not economically feasible, Borrower will promptly repair the Property if damaged to avoid further deterioration or damage. If insurance or condemnation proceeds are paid to Lender in connection with damage to, or the taking of, the Property, Borrower will be responsible for repairing or restoring the Property only if Xxxxxx has released proceeds for such purposes. Lender may disburse proceeds for the repairs and restoration in a single payment or in a series of progress payments as the work is completed, depending on the size of the repair or restoration, the terms of the repair agreement, and whether Borrower is in Default on the Loan. Lender may make such disbursements directly to Borrower, to the person repairing or restoring the Property, or payable jointly to both. If the insurance or condemnation proceeds are not sufficient to repair or restore the Property, Borrower remains obligated to complete such repair or restoration. Lender may make reasonable entries upon and inspections of the Property. If Lender has reasonable cause, Xxxxxx may inspect the interior of the improvements on the Property. Lender will give Borrower notice at the time of or prior to such an interior inspection specifying such reasonable cause.

  • Description of the Project THIS SHOULD BE NO MORE THAN A TWO PARAGRAPH DESCRIPTION THAT PROVIDES A BACKGROUND OF THE PROBLEM, AS WELL AS HOW THE CONTRACTOR INTENDS TO SOLVE THE PROBLEM. KEEP IN MIND THAT THE CONTRACT SHOULD “STAND ON ITS OWN,” I.E. ANYONE SHOULD BE ABLE TO PICK IT UP AND FIGURE OUT WHAT IS GOING ON.)

  • Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!