CONTRACT HOLDER'S RESPONSIBILITY Sample Clauses

CONTRACT HOLDER'S RESPONSIBILITY. The sole responsibility of the Contract Holder is to serve as party to the Contract. The Contract Holder will have no responsibility for the administration of any Plan or agreement, or for Contributions or any payments or other distributions hereunder. Equitable will deal with the Contract Holder in accordance with the terms and conditions of the trust agreement pursuant to which the Contract Holder agreed to act as such and in such manner as the Contract Holder and Equitable agree, without the consent of any other person.
AutoNDA by SimpleDocs
CONTRACT HOLDER'S RESPONSIBILITY. If the Contract Holder is the trustee of a trust established pursuant to a trust agreement between us and said trustee and adopted by the Employer, such trustee will have no responsibility for Contributions or any payments or other distributions under the Plan or Contract or for the administration of the Plan or Contract. In addition, we will deal with such trustee in accordance with the terms and conditions of the trust agreement pursuant to which the trustee agreed to act as such and in such manner as the trustee and we agree, without the consent of any other person.
CONTRACT HOLDER'S RESPONSIBILITY. The sole responsibility of the Contract Holder is to serve as party to the Contract. The Contract Holder will have no responsibility for the administration of the Plan or any Employer Plan or agreement, or for Contributions or any payments or other distributions hereunder. Equitable will deal with the Contract Holder in accordance with the terms and conditions of the trust agreement pursuant to which the Contract Holder agreed to act as such and in such manner as the Contract Holder and Equitable agree, without the consent of any other person. Any Employer or Employer Plan Trustee making Contributions under the Contract will have adopted and accepted the Master Trust or the Pooled Trust and this Contract as part of the Employer Plan with respect to which such Contributions are made.
CONTRACT HOLDER'S RESPONSIBILITY. It is the responsibility of the contract holder to follow the manufacturer’s specifications for the use and care/maintenance of the Covered Product.
CONTRACT HOLDER'S RESPONSIBILITY. It is the responsibility of the Service Contract Holder to follow the manufacturer’s specifications for the use and care/maintenance of the covered Product. Florida: This Service Contract is between the Provider, Technology Insurance Company, Inc. (License No. 03605) and You, the purchaser. The rates charged to You for this Service Contract are not subject to regulation by the Florida Office of Insurance Regulation. CANCELLATION is deleted and replaced with the following: You may cancel Your Service Contract by informing the selling dealer or the Administrator, WCPS of Florida, Inc. (License No. 80202) of Your cancellation request. In the event the Service Contract is canceled by You, return of the premium shall be based upon ninety percent (90%) of the unearned pro-rata premium less any Claims that have been paid or less the cost of repairs made on Your behalf. In the event the Service Contract is canceled by the Administrator or Provider, return of the premium shall be based upon one hundred percent (100%) of the unearned pro-rata premium less any Claims that have been paid or less the cost of repairs made on Your behalf. Georgia: DEFINITIONS – The definition of “Waiting Period” is deleted and replaced as follows: the period of time starting on the Agreement purchase date, through thirty (30) days thereafter, during which time no Claims are considered for coverage under this Agreement. All other references to a (90) day waiting period from the Agreement purchase dateare replaced with a (30) day waiting period from the Agreement purchase date. CANCELLATION is amended as follows: The Provider may only cancel this Service Contract for fraud by You, material misrepresentation by You, or nonpayment by You. WHAT IS NOT COVERED – Only unauthorized product repairs, modifications or alterations performed after the effective date of the Service Contract are excluded. WAITING PERIOD – A term equivalent to the thirty (30) day waiting period will be added to the term of Your Service Contract.
CONTRACT HOLDER'S RESPONSIBILITY. TABLE OF GUARANTEED ANNUITY PAYMENTS 42 2003-GAC 403(B) 3 PART I - DEFINITIONS
CONTRACT HOLDER'S RESPONSIBILITY. It is the responsibility of the contract holder to follow the manufacturer’s specifications for the use and care/maintenance of the Covered Product. by the number of days still remaining on the Service Agreement, less the value of any service received and any cancellation fee stated in the Service Agreement will be paid to the Service Agreement holder.
AutoNDA by SimpleDocs

Related to CONTRACT HOLDER'S RESPONSIBILITY

  • Seller’s Responsibility If the Seller determines that the Interface Problem is primarily attributable to the design of a Warranted Part, the Seller shall, if so requested by the Buyer and pursuant to the terms and conditions of Clause 12.1, correct the design of such Warranted Part to the extent of the Seller’s obligation as defined in Clause 12.1.

  • SELLER’S RESPONSIBILITIES (a) Seller shall act in performance of this Agreement as an independent contractor and not as an agent for Company or the Government in performing this Agreement, maintaining complete control over its employees and all lower-tier subcontractors. Nothing contained in this Agreement or any lower-tier subcontract shall create any contractual relationship between any such lower-tier subcontractor and the Government or Company. Seller is solely responsible for the actions of itself and its lower-tier subcontractors, agents or employees. (b) Seller shall be responsible for all liability and related expenses resulting from (1) injury, death, damage to or loss of property or (2) violation of Part 1.12a Compliance with Laws, which is in any way connected with its performance of work under this Agreement. Seller's responsibility shall apply to activities of Seller, its agents, lower-tier subcontractors, or employees and such responsibility includes the obligation to indemnify, defend, and hold harmless the Government and the Company for Seller's conduct. However, such liability and indemnity does not apply to injury, death, or damage to property to the extent it arises from the negligent or willful misconduct of Company. (c) If Company’s costs are determined to be unallowable, its fee reduced, or it incurs any cost or damages as a result of Seller’s violation of applicable laws, orders, rules, regulations, or ordinances, or the submission of defective cost or pricing data, Company may make an equivalent reduction in amounts due Seller. (d) If Seller is a State agency, such as an Educational Institution, all liabilities and remedies shall be determined in accordance with the laws applicable to this Agreement under Part 1.2.

  • Owner’s Responsibility Proper preventative maintenance of the exterior and interior of the vehicle is the responsibility of the owner. See the owner’s manual(s) for proper care instructions. Defects or damage as a result of improper care or maintenance are not covered by this warranty agreement.

  • Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.

  • PROVIDER’S RESPONSIBILITIES A DBE prime may receive credit toward the DBE goal for work performed by his-her own forces and work subcontracted to DBEs. A DBE prime must make a good faith effort to meet the goals. In the event a DBE prime subcontracts to a non-DBE, that information must be reported to the Department. a. A Provider who cannot meet the contract goal, in whole or in part, shall document the “Good Faith Efforts” taken to obtain DBE participation. The following is a list of the types of actions that may be considered as good faith efforts. It is not intended to be a mandatory checklist, nor is it intended to be exclusive or exhaustive. Other factors or types of efforts may be relevant in appropriate cases. (1) Soliciting through all reasonable and available means the interest of all certified DBEs who have the capability to perform the work of the contract. The solicitation must be done within sufficient time to allow the DBEs to respond to it. Appropriate steps must be taken to follow up initial solicitations to determine, with certainty, if the DBEs are interested. (2) Selecting portions of the work to be performed by DBEs in order to increase the likelihood that the DBE goals will be achieved. This includes, where appropriate, breaking out contract work items into economically feasible units to facilitate DBE participation, even when the Provider might otherwise prefer to perform the work items with its own forces. (3) Providing interested DBEs with adequate information about the plans, specifications, and requirements of the contract in a timely manner to assist them in responding to a solicitation. (4) Negotiating in good faith with interested DBEs by making a portion of the work available to DBE subproviders and suppliers and selecting those portions of the work or material needs consistent with the available DBE subproviders and suppliers. (5) The ability or desire of the Provider to perform the work of a contract with its own organization does not relieve the Provider’s responsibility to make a good faith effort. Additional costs involved in finding and using DBEs is not in itself sufficient reason for a Provider’s failure to meet the contract DBE goal, as long as such costs are reasonable. Providers are not, however, required to accept higher quotes from DBEs if the price difference is excessive or unreasonable. (6) Not rejecting DBEs as being unqualified without sound reasons based on a thorough investigation of their capabilities. (7) Making efforts to assist interested DBEs in obtaining bonding, lines of credit, or insurance as required by the recipient or Provider. (8) Making efforts to assist interested DBEs in obtaining necessary equipment, supplies, materials or related assistance or services. (9) Effectively using the services of available minority/women community organizations; minority/women contractors’ groups; local, state, and Federal minority/women business assistance offices; and other organizations as allowed on a case-by-case basis to provide assistance in the recruitment and placement of DBEs. (10) If the Department’s Director of the Business Opportunity Programs Office determines that the Provider has failed to meet the good faith effort requirements, the Provider will be given an opportunity for reconsideration by the Director of the appropriate Division. NOTE: The Provider must not cause or allow subproviders to bid their services. b. The preceding information shall be submitted directly to the Chair of the Consultant Selection Team responsible for the project. c. The Provider shall make all reasonable efforts to honor commitments to DBE subproviders named in the commitment submitted under Section 2.c. of this attachment. Where the Provider terminates or removes a DBE subprovider named in the initial commitment, the Provider must demonstrate on a case-by-case basis to the satisfaction of the department that the originally designated DBE was not able or willing to perform. d. The Provider shall make a good faith effort to replace a DBE subprovider that is unable or unwilling to perform successfully with another DBE, to the extent needed to meet the contract goal. The Provider shall submit a completed Exhibit H-2 Form for the substitute firm(s). Any substitution of DBEs shall be subject to prior written approval by the Department. The Department may request a statement from the firm being replaced concerning its replacement prior to approving the substitution. e. The Provider shall designate a DBE liaison officer who will administer the DBE program and who will be responsible for maintenance of records of efforts and contacts made to subcontract with DBEs. f. Providers are encouraged to investigate the services offered by xxxxx owned and controlled by disadvantaged individuals and to make use of these banks where feasible.

  • CONTRACTOR'S RESPONSIBILITY 1.1. The Basic Services to be performed by CONTRACTOR hereunder is the Citywide Landscape Maintenance. 1.2. The CONTRACTOR agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida, the City of Naples, and in Xxxxxxx County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONTRACTOR pursuant to this Agreement. 1.3. The CONTRACTOR agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services. 1.4. CONTRACTOR agrees to employ and designate, in writing, within five (5) calendar days after receiving its Notice to Proceed, a qualified licensed professional to serve as the CONTRACTOR's project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of the CONTRACTOR with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. 1.5. The CONTRACTOR has represented to the OWNER that it has expertise in the type of professional services that will be required for the Project. The CONTRACTOR agrees that all services to be provided by CONTRACTOR pursuant to this Agreement shall be subject to the OWNER's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all published laws, statutes, ordinances, codes, rules, regulations and requirements of any governmental agencies which regulate or have jurisdiction over the Project or the services to be provided and performed by CONTRACTOR hereunder. In the event of any conflicts in these requirements, the CONTRACTOR shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of the conflict. 1.6. CONTRACTOR agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER's prior written consent, or unless incident to the proper performance of the CONTRACTOR's obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONTRACTOR hereunder, and CONTRACTOR shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph.

  • OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR hereunder; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and (c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder. 2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter. 3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period. 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.

  • Customer’s Responsibility The policies in this document apply to the use of Data by Customers, Redistributors and their End Customers. Customers are responsible for compliance with this policy by all members of the Customer’s Group and by all persons to whom they distribute Data where authorised to do so. Turquoise recommends that Customers make this Schedule available to all Subscribers to their services having access to Data which is subject to Charges, reporting requirements or usage restrictions.

  • PURCHASER's Responsibilities For the duration of the suspension, PURCHASER is responsible to continue maintenance at the operations just as if the operations was in progress. This includes, but is not limited to, protection of completed operations, maintenance of access, protection of stored materials, temporary facilities, and clean-up.

  • Buyer’s Responsibility Buyer shall obtain and maintain all distribution, transmission and interconnection rights and agreements (including all Governmental Authority approvals) required to enable transmission and delivery of electric energy at and after the Delivery Point.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!