Contractor’s Remedy Sample Clauses

Contractor’s Remedy. Contractor’s remedy, if any, for any breach of this Agreement shall be solely in damages and Contractor shall look solely to Company for recover of such damages. Contractor waives and relinquishes any right Contractor may otherwise have to obtain injunctive or equitable relief against any third party with respect to any dispute arising under this Agreement. Contractor shall look solely to Company for any compensation which may be due to Contractor hereunder.
Sample 1Sample 2Sample 3See All (26)
AutoNDA by SimpleDocs
Contractor’s Remedy. Contractor shall give written notice to Owner of any alleged breach by Owner, and Owner shall have a reasonable time within which to cure any alleged breach. If Owner is in breach of this Contract, Contractor's exclusive remedies shall be (a) a reasonable extension of the Contract Time and (b) a reasonable increase in the Contract Sum, which increase shall be limited to the actual, out-of-pocket costs and expenses incurred by Contractor as a direct result of Owner's breach.
Sample 1Sample 2
Contractor’s Remedy. Contractor's remedy, if any, for any breach of this Agreement shall be solely in damages and Contractor shall look solely to University for recovery of such damages. Contractor waives and relinquishes any right Contractor might otherwise have (a) to obtain injunctive or equitable relief for any reason, and (b) to proceed against any dispute arising under this Agreement.
Sample 1
Contractor’s Remedy. 15.2.1 The Contractor’s sole and exclusive remedy for the default of the Owner, other than the failure of the Owner to pay the Contractor, will be to bring a suit for damages in the Common Pleas Court of Lorain County, Ohio. The Contractor’s right to exercise that remedy shall be subject to its giving the Owner the required notices and following any other procedures required by the Contract Documents.
Sample 1
Contractor’s Remedy. Customer’s remedy, if any, for any breach of this Agreement shall be solely in damages and Customer shall look solely to Contractor for recover of such damages. Customer waives and relinquishes any right Customer may otherwise have to obtain injunctive or equitable relief against any third party with respect to any dispute arising under this Agreement.
Sample 1
Contractor’s Remedy a. In the event of any material default of Owner hereunder, Contractor shall give Owner notice specifying the nature of such breach. If payment from Owner has not been received by Contractor within five calender days of invoice date, Contractor reserves the right to cease work until such payment has been received. Completion date of the work shall be extended automatically by Contractor giving Owner written notice of material default and cessation of work for the number of days for the cessation of work. If Owner has not commenced to cure in full the breach on or before the expiration of five calendar days from receipt of Contractor’s notice, Contractor may, in addition to all other remedies he may have at law or in equity, terminate this agreement upon two business days’ notice specifying the effective date of termination of this agreement.
Sample 1

Related to Contractor’s Remedy

  • Lessor’s Remedies i. Upon the occurrence of an “Event of Default,” Lessor may, in its sole discretion, do any one or more of the following:

  • Buyer’s Remedies If both (a) this Agreement is terminated ---------------- prior to Closing by Buyer pursuant to Section 8.1.2 or 8.1.3 as a result of a ---------------------- breach by Seller in any material respect of any of its representations and warranties made herein or its covenants or agreements made herein and (b) Buyer is not in breach in any material respect of any of its representations and warranties made herein or its covenants or agreements made herein, the Deposit and all accrued interest thereon shall be returned to Buyer, and Buyer shall have, in addition to its right to receive the Deposit and all accrued interest thereon, the right to seek monetary damages from Seller; provided, however, that -------- ------- such damages shall be limited to $1,000,000.00; and provided further, that in no ---------------- event shall Buyer be entitled to make any claim against Seller for, nor be entitled to damages from Seller for, any anticipated profits it lost as a result of Buyer's not acquiring the System; and provided further, that nothing in this ---------------- Section 8.2.2 shall be an admission by Seller that Buyer shall be entitled to ------------- damages for anticipated profits under any circumstances. If Seller defaults in the performance of its obligations under this Agreement, Buyer shall be entitled, in addition to any other remedies that may be available, to request Seller to specifically perform its obligations under this Agreement, if necessary, through injunction, court order or other process, and to recover from Seller any costs or expenses reasonably incurred by Buyer in connection therewith.

  • Seller’s Remedies If Purchaser fails to perform its obligations pursuant to this Contract at or prior to Closing for any reason except failure by Seller to perform hereunder, or if prior to Closing any one or more of Purchaser's representations or warranties are breached in any material respect, and this failure or breach is not cured within three (3) Business Days after written notice from Seller to Purchaser (other than failure to close for any reason unrelated to a default by Seller, for which there shall be no notice or cure period), then Seller, as its SOLE and EXCLUSIVE remedy (except as provided in Sections 6(c) and 9), may (i) terminate this Contract and receive the Xxxxxxx Money as liquidated damages and not as penalty, in full satisfaction of claims against Purchaser hereunder, or (ii) waive Purchaser’s failure or breach and proceed to Closing. Seller and Purchaser agree that Seller's damages resulting from Purchaser's default are difficult, if not impossible, to determine, and the Xxxxxxx Money is a fair estimate of those damages and has been agreed to in an effort to cause the amount of damages to be certain. Notwithstanding anything in this Section 11(a) to the contrary, in the event of Purchaser's default or termination of this Contract, Seller shall have all remedies available at law or in equity if Purchaser or any party related to or affiliated with Purchaser is asserting any claims or right to the Property that would otherwise delay or prevent Seller from having clear, indefeasible and marketable title to the Property other than as a result of Purchaser’s exercise of its remedies under subsection (b) hereof. If Closing is consummated, then Seller shall have all remedies available at law or in equity if Purchaser fails to perform any post-closing obligation of Purchaser under this Contract.

  • Purchaser’s Remedies If Seller fails to perform its obligations pursuant to this Agreement for any reason except failure by Purchaser to perform hereunder, or if prior to Closing any one or more of Seller's representations or warranties are breached in any material respect, Purchaser shall elect, as its sole remedy, either to (i) terminate this Agreement by giving Seller timely written notice of such election prior to or at Closing and recover the Earnest Money, (ii) enforce specific performance, or (iii) waive said xxxxxxx or breach and proceed to Closing. Notwithstanding anything herein to the contrary, Purchaser shall be deemed to have elected to terminate this Agreement if Purchaser fails to deliver to Seller written notice of its intent to file a claim or assert a cause of action for specific performance against Seller on or before ten (10) business days following the scheduled Closing Date or, having given such notice, fails to file a lawsuit asserting such claim or cause of action in the county in which the Property is located within two (2) months following the scheduled Closing Date. Purchaser's remedies shall be limited to those described in this Section 10.2 and Sections 10.3 and 10.4 hereof. If, however, the equitable remedy of specific performance is not available, Purchaser may seek any other right or remedy available at law or in equity; provided, however, that in no event shall Seller's liability exceed the lesser of (i) $50,000.00 or (ii) the actual reasonable out-of-pocket expenses incurred by Purchaser and incurred directly in connection with the negotiation of this Agreement or the due diligence activities performed by Purchaser or at Purchaser's direction in connection with the performance of examinations, inspections and/or investigations pursuant to Article 4. For purposes of this provision, specific performance shall be considered not available to Purchaser only if a court of competent jurisdiction (or an arbitrator, as per Exhibit G) determines conclusively that Purchaser is entitled to specific performance on the merits of its claim but said court or arbitrator is unable to enforce specific performance due to reasons beyond the control of the court or arbitrator. IN NO EVENT SHALL SELLER'S DIRECT OR INDIRECT PARTNERS, SHAREHOLDERS, OWNERS OR AFFILIATES, ANY OFFICER, DIRECTOR, EMPLOYEE OR AGENT OF THE FOREGOING, OR ANY AFFILIATE OR CONTROLLING PERSON THEREOF HAVE ANY LIABILITY FOR ANY CLAIM, CAUSE OF ACTION OR OTHER LIABILITY ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE PROPERTY, WHETHER BASED ON CONTRACT, COMMON LAW, STATUTE, EQUITY OR OTHERWISE.

  • General Remedies Upon the occurrence of an Event of Default and during the continuation thereof, the Administrative Agent and the holders of the Secured Obligations shall have, in addition to the rights and remedies provided herein, in the Loan Documents, in any other documents relating to the Secured Obligations, or by law (including, without limitation, levy of attachment and garnishment), the rights and remedies of a secured party under the UCC of the jurisdiction applicable to the affected Collateral and, further, the Administrative Agent may, with or without judicial process or the aid and assistance of others (to the extent permitted under applicable law), (i) subject to the rights of tenants in possession, enter on any premises on which any of the Collateral may be located and, without resistance or interference by the Grantors, take possession of the Collateral, (ii) dispose of any Collateral on any such premises, (iii) require the Grantors to assemble and make available to the Administrative Agent at the expense of the Grantors any Collateral at any place and time designated by the Administrative Agent that is reasonably convenient to both parties, (iv) remove any Collateral from any such premises for the purpose of effecting sale or other disposition thereof, and/or (v) except as provided below in the case of notice required by law, without demand and without advertisement, notice or hearing, all of which each of the Grantors hereby waives to the fullest extent permitted by law, at any place and time or times, sell and deliver any or all Collateral held by or for it at public or private sale, by one or more contracts, in one or more parcels, for cash, upon credit or otherwise, at such prices and upon such terms as the Administrative Agent deems advisable, in its sole discretion (subject to any and all mandatory legal requirements). Each of the Grantors acknowledges that any private sale referenced above may be at prices and on terms less favorable to the seller than the prices and terms that might have been obtained at a public sale and agrees (to the extent permitted by applicable law) that such private sale shall be deemed to have been made in a commercially reasonable manner. Neither the Administrative Agent’s compliance with applicable law nor its disclaimer of warranties relating to the Collateral shall be considered to adversely affect the commercial reasonableness of any sale. In addition to all other sums due the Administrative Agent and the holders of the Secured Obligations with respect to the Secured Obligations, the Grantors shall pay the Administrative Agent and each of the holders of the Secured Obligations all reasonable documented costs and expenses actually incurred by the Administrative Agent or any such holder of the Secured Obligations, including, but not limited to, reasonable attorneys’ fees and court costs, in obtaining or liquidating the Collateral, in enforcing payment of the Secured Obligations, or in the prosecution or defense of any action or proceeding by or against the Administrative Agent or the holders of the Secured Obligations or the Grantors concerning any matter arising out of or connected with this Security Agreement, any Collateral or the Secured Obligations, including, without limitation, any of the foregoing arising in, arising under or related to a case under the Bankruptcy Code. To the extent the rights of notice cannot be legally waived hereunder, each Grantor agrees that any requirement of reasonable notice shall be met if such notice is personally served on or mailed, postage prepaid, to the Borrower in accordance with the notice provisions of Section 11.02 of the Credit Agreement at least ten Business Days before the time of sale or other event giving rise to the requirement of such notice. The Administrative Agent and the holders of the Secured Obligations shall not be obligated to make any sale or other disposition of the Collateral regardless of notice having been given. To the extent permitted by applicable law, any holder of the Secured Obligations may be a purchaser at any such sale. To the extent permitted by applicable law, each of the Grantors hereby waives all of its rights of redemption with respect to any such sale. Subject to the provisions of applicable law, the Administrative Agent and the holders of the Secured Obligations may postpone or cause the postponement of the sale of all or any portion of the Collateral by announcement at the time and place of such sale, and such sale may, without further notice, to the extent permitted by applicable law, be made at the time and place to which the sale was postponed, or the Administrative Agent and the holders of the Secured Obligations may further postpone such sale by announcement made at such time and place.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!