Medications Psychotropic medications and medications associated with treating a diagnosed mental health condition.
Vaccinations Contractor understands, acknowledges, and agrees that, pursuant to Article II of the General Appropriations Act, none of the General Revenue Funds appropriated to the Department of State Health Services (DSHS) may be used for the purpose of promoting or advertising COVID-19 vaccinations in the 2024-25 biennium. It is also the intent of the legislature that to the extent allowed by federal law, any federal funds allocated to DSHS shall be expended for activities other than promoting or advertising COVID-19 vaccinations. Contractor represents and warrants that it is not ineligible, nor will it be ineligible during the term of this Contract, to receive appropriated funding pursuant to Article II.
Studies The clinical, pre-clinical and other studies and tests conducted by or on behalf of or sponsored by the Company or its subsidiaries that are described or referred to in the Registration Statement, the Pricing Disclosure Package and the Prospectus were and, if still pending, are being conducted in accordance in all material respects with all statutes, laws, rules and regulations, as applicable (including, without limitation, those administered by the FDA or by any foreign, federal, state or local governmental or regulatory authority performing functions similar to those performed by the FDA). The descriptions of the results of such studies and tests that are described or referred to in the Registration Statement, the Pricing Disclosure Package and the Prospectus are accurate and complete in all material respects and fairly present the published data derived from such studies and tests, and each of the Company and its subsidiaries has no knowledge of other studies or tests the results of which are materially inconsistent with or otherwise call into question the results described or referred to in the Registration Statement, the Pricing Disclosure Package and the Prospectus. Except as described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, neither the Company nor its subsidiaries has received any notices or other correspondence from the FDA or any other foreign, federal, state or local governmental or regulatory authority performing functions similar to those performed by the FDA with respect to any ongoing clinical or pre-clinical studies or tests requiring the termination or suspension of such studies or tests. For the avoidance of doubt, the Company makes no representation or warranty that the results of any studies, tests or preclinical or clinical trials conducted by or on behalf of the Company will be sufficient to obtain governmental approval from the FDA or any foreign, state or local governmental body exercising comparable authority.
Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.
Adverse Events Subsequent to the date hereof, there shall not have occurred any of the following: (i) a suspension or material limitation in trading in securities generally on the New York Stock Exchange, the NASDAQ National Market or the NASDAQ Global Market, (ii) a general moratorium on commercial banking activities in the People’s Republic of China or New York, (iii) the outbreak or escalation of hostilities involving the United States or the People’s Republic of China or the declaration by the United States or the People’s Republic of China of a national emergency or war if the effect of any such event specified in this clause (iii) in your reasonable judgment makes it impracticable or inadvisable to proceed with the public offering or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus, or (iv) such a material adverse change in general economic, political, financial or international conditions affecting financial markets in the United States or the People’s Republic of China having a material adverse impact on trading prices of securities in general, as, in your reasonable judgment, makes it impracticable or inadvisable to proceed with the public offering of the Shares or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Medication 1. Xxxxxxx’s physician shall prescribe and monitor adequate dosage levels for each Client.
2. Xxxxxxx’s physician shall not impose and/or limit dosage capitations for any prescribed medication for the treatment of opioid use disorder.
Vaccination and Inoculation
(a) The Employer agrees to take all reasonable precautions to limit the spread of infectious diseases among employees, including in-service seminars for employees. Where the Employer or Occupational Health and Safety Committee identifies high risk areas which expose employees to infectious or communicable diseases for which there are protective immunizations available, such immunizations shall be provided at no cost to the employee. The Committee may consult with the Medical Health Officer. Where the Medical Health Officer identifies such a risk, the immunization shall also be provided at no cost. The Employer shall provide Hepatitis B vaccine, free of charge, to those employees who may be exposed to bodily fluids or other sources of infection.
(b) An employee may be required by the Employer, at the request of and at the expense of the Employer, to take a medical examination by a physician of the employee's choice. Employees may be required to take skin tests, x-ray examination, vaccination, and other immunization (with the exception of a rubella vaccination when the employee is of the opinion that a pregnancy is possible), unless the employee's physician has advised in writing that such a procedure may have an adverse effect on the employee's health.
