Control of Parking Sample Clauses

Control of Parking. Tenant shall at all times comply with all applicable ordinances, rules, regulations, codes, laws, statutes and requirements of all federal, state, county and municipal governmental bodies or their subdivisions respecting the use of the Garage. Landlord reserves the right from time to time to adopt, modify and enforce reasonable rules governing the use of the Garage, including any key-card, sticker or other identification or entrance system, and hours of operation. Landlord may refuse to permit any person who violates such rules to park in the Garage, and any violation of the rules will subject the car to removal from the Garage.
AutoNDA by SimpleDocs
Control of Parking. Landlord reserves the right from time to time to ------------------ adopt, modify and enforce reasonable rules governing the use of the Garage, including any key-card, sticker or other identification or entrance system, and hours of operation. Landlord may refuse to permit any person who violates such rules to park in the Garage. Except for paid reserved spaces specified in Paragraph 12 of the Basic Lease Provisions, the parking spaces hereunder will be provided on an unreserved "first-come, first-served" basis. Landlord reserves the right to assign specific spaces, and to reserve spaces for visitors, small cars, handicapped persons and for other lessees, guests of other lessees, or other parties, and Tenant and Tenant's Designated Parkers will not park in any such assigned or reserved spaces. Landlord also reserves the right to close all or any portion of the Garage in order to make repairs or perform maintenance services, or to alter, modify, restripe or renovate the Garage, or if required by casualty, strike, condemnation, act of God, governmental law or requirement or other reason beyond Landlord's reasonable control.
Control of Parking. Landlord reserves the right from time to time to adopt, modify and enforce reasonable rules governing the use of the Lot, including any keycard, sticker or other identification or entrance system, and hours of operation. Landlord may refuse to permit any person who violates such rules to park in the Lot. The parking spaces hereunder will be provided on an unreserved “first-come, first-served” basis. Landlord reserves the right to assign specific spaces, and to reserve spaces for visitors, small cars, handicapped persons and for other lessees, guests of other lessees, or other parties, and Tenant and Tenant’s Designated Parkers will not park in any such assigned or reserved spaces. Landlord also reserves the right to close all or any portion of the Lot in order to make repairs or perform maintenance services, or to alter, modify, restripe or renovate the Lot, or if required by casualty, strike, condemnation, act of God, governmental law or requirement or other reason beyond Landlord’s reasonable control.
Control of Parking. Landlord reserves the right from time to time to adopt, modify and enforce reasonable rules governing the use of the Garage and Lot, including any key-card, sticker or other identification or entrance system, and hours of operation. Xxxxxxxx may refuse to permit any person who violates such rules to park in the Garage and Lot. The parking spaces hereunder will be provided on an unreserved “first-come, first-served” basis. Landlord reserves the right to assign specific spaces, and to reserve spaces for visitors, small cars, handicapped persons and for other lessees, guests of other lessees, or other parties, and Tenant and Tenant’s Designated Xxxxxxx will not park in any such assigned or reserved spaces. Landlord also reserves the right to close temporarily all or any portion of the Garage and Lot in order to make repairs or perform maintenance services, or to alter, modify, re-stripe or renovate the Garage and Lot, or if required by casualty, strike, condemnation, act of God, governmental law or requirement or other reason beyond Landlord’s reasonable control.
Control of Parking. Tenant shall at all times comply with all applicable ordinances, rules, regulations, codes, laws, statutes and requirements of all federal, state, county and municipal governmental bodies or their subdivisions respecting the use of the Parking Facilities. Landlord reserves the right from time to time to adopt, modify and enforce reasonable rules governing the use of the Parking Facilities, including any key-card, sticker or other identification or entrance system, and hours of operation. Landlord may refuse to permit any person who violates such rules to park in the Parking Facilities, and any violation of the rules will subject the car to removal from same.
Control of Parking. Tenant shall at all times comply with all applicable ordinances, rules, regulations, codes, laws, statutes and requirements of all federal, state, county and municipal governmental bodies or their subdivisions respecting the use of the Garage, Basement, and Lot. Landlord reserves the right from time to time to adopt, modify and enforce reasonable rules governing the use of the Garage, Basement, and Lot, including any key-card, sticker or other identification or entrance system, and hours of operation. Landlord may refuse to permit any person who violates such rules to park in the Garage, Basement, and Lot, and any violation of the rules will subject the car to removal from the Garage, Basement, and Lot.
Control of Parking. We reserve the right to control parking in any manner
AutoNDA by SimpleDocs
Control of Parking. (i) The Tenant shall, if requested by the Landlord, for the purpose of control of the Tenants' and their employees' parking, within a period of fourteen (14) days after requested so to do furnish the Landlord with the current provincial license number of any vehicles owned or used by the Tenant and any vehicles owned or used by the employees of the Tenant. (ii) The Tenant agrees that if the Tenant, its employees. suppliers and other persons not being customers having business with the Tenant, park vehicles In areas not allocated for that purpose. the Landlord Shall have the right to remove such vehicle or vehicles or to cause such vehicle or vehicles to be removed and the Tenant will save harmless the Landlord from any and all expense and damages arising therefrom and the Tenant will pay the cost of such removal.

Related to Control of Parking

  • Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time: (a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways; (b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available; (c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas; (d) To add additional buildings and improvements to the Common Areas; (e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and (f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.

  • Car Parking You will not be entitled to apply for permit parking on the Campus unless you are entitled to an exemption from this policy.

  • Common Areas Tenant shall have the non-exclusive right to use in common with other tenants in the Project, and subject to the Rules and Regulations referred to in Article 5 of this Lease, those portions of the Project which are provided, from time to time, for use in common by Landlord, Tenant and any other tenants of the Project (such areas, together with such other portions of the Project designated by Landlord, in its discretion, including certain areas designated for the exclusive use of certain tenants, or to be shared by Landlord and certain tenants, are collectively referred to herein as the “Common Areas”). The Common Areas shall consist of the “Project Common Areas” and the “Building Common Areas.” The term “Project Common Areas,” as used in this Lease, shall mean the portion of the Project designated as such by Landlord or areas within the Project that the occupants of the Building are permitted to utilize pursuant to a recorded declaration and which areas shall be maintained in accordance with the declaration. The term “Building Common Areas,” as used in this Lease, shall mean the portions of the Common Areas located within the Building reasonably designated as such by Landlord. The manner in which the Common Areas are maintained and operated shall be at the reasonable discretion of Landlord and the use thereof shall be subject to the Rules and Regulations as Landlord may make from time to time. Landlord reserves the right to close temporarily, make alterations or additions to, or change the location of elements of the Project and the Common Areas, provided that, in connection therewith, Landlord shall perform such closures, alterations, additions or changes in a commercially reasonable manner and, in connection therewith, shall use commercially reasonable efforts to minimize any material interference with Tenant’s use of and access to the Premises.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

  • UNDERGROUND LOCATIONS Prior to the Company commencing any work the Customer must advise the Company of the precise location of all underground services on the site and clearly xxxx the location. The underground mains and services the Customer must identify include, but are not limited to, telephone cables, fibre optic cables, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigations pipes, oil pumping mains and any other services that may be on site. Whilst the Company will take all care to avoid damage to any underground services the Customer agrees to indemnify the Company in respect of all any liability claims, loss, damage, cost and fines as a result of damage to services not precisely located and notified pursuant to this clause.

  • Access; Utilities; Separate Tax Parcels Based solely on evaluation of the Title Policy (as defined in paragraph 8) and survey, if any, an engineering report or property condition assessment as described in paragraph 12, applicable local law compliance materials as described in paragraph 26, and the ESA (as defined in paragraph 43), each Mortgaged Property (a) is located on or adjacent to a public road and has direct legal access to such road, or has permanent access from a recorded easement or right of way permitting ingress and egress to/from a public road, (b) is served by or has access rights to public or private water and sewer (or well and septic) and other utilities necessary for the current use of the Mortgaged Property, all of which are adequate for the current use of the Mortgaged Property, and (c) constitutes one or more separate tax parcels which do not include any property which is not part of the Mortgaged Property or is subject to an endorsement under the related Title Policy insuring the Mortgaged Property, or in certain cases, an application has been made or is required to be made to the applicable governing authority for creation of separate tax parcels (or the Mortgage Loan documents so require such application in the future), in which case the Mortgage Loan requires the Mortgagor to escrow an amount sufficient to pay taxes for the existing tax parcel of which the Mortgaged Property is a part until the separate tax parcels are created.

  • POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.

  • Location of Improvements; No Encroachments All improvements which were considered in determining the Appraised Value of the Mortgaged Property lay wholly within the boundaries and building restriction lines of the Mortgaged Property, and no improvements on adjoining properties encroach upon the Mortgaged Property. No improvement located on or being part of the Mortgaged Property is in violation of any applicable zoning law or regulation;

  • Premises Parking and Common Areas 2.1 Letting Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor, the Premises, for the term, at the rental, and upon all of the terms covenants and conditions set forth in this Lease. Unless otherwise provided herein, any statement of square footage set forth in this Lease, or that may have been used in calculating rental and/or Common Area Operating Expenses, is an approximation which Lessor and Lessee agree is reasonable and the rental and Lessee's Share (as defined in Paragraph 1.6(b)) based thereon is not subject to revision whether or not the actual square footage is more or less.

  • REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!