Cooperation and Harmony on Site Sample Clauses

Cooperation and Harmony on Site. (a) This PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete construction of the Covered Projects economically, efficiently, continuously, and without any interruption, delays, or work stoppages. (b) The Contractors, Unions, and Contractor employees collectively and individually, realize the importance of maintaining continuous and uninterrupted performance of Covered Projects, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance parties to ensure the time limits and deadlines are met.
Sample 1Sample 2Sample 3See All (25)
AutoNDA by SimpleDocs
Cooperation and Harmony on Site. (a) This CBA is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete construction of the Covered Projects economically, efficiently, continuously, and without any interruption, delays, or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and employees, collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered Work, and agree to resolve all disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangement of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal Parties to any pending grievance to ensure the time limits and deadlines are met.
Sample 1Sample 2See All (7)
Cooperation and Harmony on Site. 10.1.1 This Agreement is intended to establish and xxxxxx continued close cooperation between the City, Contractors, and Unions. The Trades Council shall assign a representative to this Agreement for the purpose of assisting the local Unions, and working with the CWA Administrator, together with the Contractors, to complete the Project Work efficiently, continuously and without any interruption, delays or work stoppages. 10.1.2 The Contractors and Unions, will attempt to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. 10.1.3 The CWA Administrator shall facilitate the processing of grievances under Articles 7, 8, and 10, including the scheduling and arrangements of facilities for meetings, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the Contractors and Unions to any pending grievance to insure the time limits and deadlines are met.
Sample 1Sample 2Sample 3See All (5)
Cooperation and Harmony on Site. (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the Unions, together with the Contractors, to complete the construction of the Project economically, efficiently, continuously and without any interruption, delays or work stoppages. (b) The Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 8 or 9.
Sample 1Sample 2Sample 3See All (5)
Cooperation and Harmony on Site. (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the local. Unions, and working with the Prime Contractor, together with other Contractors, to complete the construction of the Covered Work economically, efficiently, continuously and without any interruption, delays or work stoppages. (b) The Prime Contractor, other Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article V or VI.
Sample 1Sample 2Sample 3
Cooperation and Harmony on Site. (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the Unions, and working with the District, together with the Contractors, to complete the construction of the Project economically, efficiency, continuously and without any interruption, delays or work stoppages. (b) The District, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Council shall oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met.
Sample 1
Cooperation and Harmony on Site. 10.1.1 This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the CWA Administrator, together with the Contractors, to complete the construction of the Project economically, efficiently, continuously and without any interruption, delays or work stoppages. 10.1.2 The CWA Administrator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. 10.1.3 The CWA Administrator shall oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met.
Sample 1
AutoNDA by SimpleDocs
Cooperation and Harmony on Site. This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the PLA Administrator, together with the Contractors, to complete the construction of the Project economically, efficiently, continuously and without any interruption, delays or work stoppages.
Sample 1
Cooperation and Harmony on Site. 10.1.1 This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. At its own cost the Trades Council shall assign a representative to each Project Work for the purpose of assisting the local Unions, and working with the CWA Administrator, together with the Contractors, to complete the construction of the Project economically, efficiently, continuously and without any interruption, delays or work stoppages. 10.1.2 The CWA Administrator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of the Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. 10.1.3 The CWA Administrator shall oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met. In the event that the above Arbitrators are unavailable at any time, the CWA Administrator shall request a panel seven (7) alternative arbitrators from the Federal Mediation and Conciliation Service, and the Contractor and involved Union shall attempt to mutually select an Arbitrator from that panel. In the event that the Contractor and the Union cannot come to an agreement, the parties shall, beginning with the Contractor, alternate in striking arbitrators from the list until one name remains who shall be the arbitrator.
Sample 1

Related to Cooperation and Harmony on Site

  • Cooperation and Records Retention Seller and Buyer shall (i) each provide the other with such assistance as may reasonably be requested by any of them in connection with the preparation of any return, audit, or other examination by any taxing authority or judicial or administrative proceedings relating to liability for Taxes, (ii) each retain and provide the other with any records or other information that may be relevant to such return, audit or examination, proceeding or determination, and (iii) each provide the other with any final determination of any such audit or examination, proceeding, or determination that affects any amount required to be shown on any tax return of the other for any period. Without limiting the generality of the foregoing, Buyer and Seller shall each retain, until the applicable statutes of limitations (including any extensions) have expired, copies of all tax returns, supporting work schedules, and other records or information, in a timely manner, as and that may be relevant to such returns for all tax periods or portions thereof ending on or before the Closing Date and shall not destroy or otherwise dispose of any such records without first providing the other party with a reasonable opportunity to review and copy the same.

  • Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies. 2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.

  • Cooperation and Coordination The Parties acknowledge and agree that it is their mutual objective and intent to minimize, to the extent feasible and legal, taxes payable with respect to their collaborative efforts under this Agreement and that they shall use all commercially reasonable efforts to cooperate and coordinate with each other to achieve such objective.

  • Litigation and Regulatory Cooperation During and after the Executive’s employment, the Executive shall cooperate fully with the Company in the defense or prosecution of any claims or actions now in existence or which may be brought in the future against or on behalf of the Company which relate to events or occurrences that transpired while the Executive was employed by the Company. The Executive’s full cooperation in connection with such claims or actions shall include, but not be limited to, being available to meet with counsel to prepare for discovery or trial and to act as a witness on behalf of the Company at mutually convenient times. During and after the Executive’s employment, the Executive also shall cooperate fully with the Company in connection with any investigation or review of any federal, state or local regulatory authority as any such investigation or review relates to events or occurrences that transpired while the Executive was employed by the Company. The Company shall reimburse the Executive for any reasonable out-of-pocket expenses incurred in connection with the Executive’s performance of obligations pursuant to this Section 7(f).

  • Areas of Cooperation 1. To achieve the objectives of cooperation in fisheries within the described principles, cooperation will include fisheries management and conservation issues, vessel management and post harvest arrangements and financial and trade measures and development of fisheries and fisheries products and marine aquaculture. 2. The EC Party will contribute to the mobilisation of the resources for the implementation of the identified areas of cooperation at national and regional levels, which will also include support for regional capacity building. Furthermore, the EC Party contributes to the measures as described in the section concerning financial and trade measures, and on infrastructure development specific for fisheries and marine aquaculture.

  • Cooperation on Safety The Employer and Union will cooperate in continuing and perfecting regulations which will afford adequate protection to employees engaged in hazardous areas.

  • Cooperation of the Parties The Seller undertakes to notify the Buyer of any obstacles on his part, which may negatively influence proper and timely delivery of the Equipment.

  • Litigation and Compliance (a) There are no actions, suits, claims or proceedings, whether in equity or at law or, any Governmental investigations pending or, to the knowledge of VCP23, threatened: (i) against or affecting VCP23 or with respect to or affecting any asset or property owned, leased or used by VCP23; or (ii) which question or challenge the validity of this Agreement, or the Amalgamation or any action taken or to be taken pursuant to this Agreement, or the Amalgamation; except for actions, suits, claims or proceedings which would not, in the aggregate, have a Material Adverse Effect on VCP23 nor is VCP23 aware of any basis for any such action, suit, claim, proceeding or investigation . (b) VCP23 has conducted and is conducting its business in compliance with, and is not in default or violation under, and has not received notice asserting the existence of any default or violation under, any Law applicable to its business or operations, except for non-compliance, defaults and violations which would not, in the aggregate, have a Material Adverse Effect on VCP23. (c) Neither VCP23, nor any asset of VCP23 is subject to any judgment, order or decree entered in any lawsuit or proceeding which has had, or which is reasonably likely to have, a Material Adverse Effect on VCP23 or which is reasonably likely to prevent VCP23 from performing its obligations under this Agreement. (d) VCP23 has duly filed or made all reports and returns required to be filed by it with any Government and has obtained all permits, licenses, consents, approvals, certificates, registrations and authorizations (whether Governmental, regulatory or otherwise) which are required in connection with its business and operations, except where the failure to do so has not had and would not have a Material Adverse Effect on VCP23.

  • Information and Services Required of the Owner The Owner shall provide information with reasonable promptness, regarding requirements for and limitations on the Project, including a written program which shall set forth the Owner’s objectives, constraints, and criteria, including schedule, space requirements and relationships, flexibility and expandability, special equipment, systems, sustainability and site requirements.

  • Safeguarding and Protecting Children and Vulnerable Adults The Supplier will comply with all applicable legislation and codes of practice, including, where applicable, all legislation and statutory guidance relevant to the safeguarding and protection of children and vulnerable adults and with the British Council’s Child Protection Policy, as notified to the Supplier and amended from time to time, which the Supplier acknowledges may include submitting to a check by the UK Disclosure & Barring Service (DBS) or the equivalent local service; in addition, the Supplier will ensure that, where it engages any other party to supply any of the Services under this Agreement, that that party will also comply with the same requirements as if they were a party to this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!