We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Delay in Commercial Operation Sample Clauses

Delay in Commercial Operation. If the Certificate of Commercial Operations has not been submitted in accordance with this Agreement within the Build/Renovation Period, unless the delay is on account of reasons due to Force Majeure or any time extension agreed between the Parties, an amount equivalent to 0.55% (zero point five five percent) of the Performance Security for each Day of delay, subject to a maximum of 180 (one hundred and eighty) Days from the completion of the Build/Renovation Period, shall be appropriated from the Performance Security until the Certificate of Commercial Operation is issued and the Washery commences operations. Provided however, in case of delay beyond 180 (one hundred and eighty) Days from the completion of the Build/Renovation Period, the Authority shall have the right to terminate this Agreement.
Delay in Commercial Operation. If the Certificate of Commercial Operations has not been submitted in accordance with this Agreement within the Build/Renovation Period or the certificate of commercial operation commencement of blast furnace unit(s) (if applicable) has not been submitted within the Build/Renovation Period, unless the delay is on account of reasons due to Force Majeure or any time extension agreed between the Parties, an amount equivalent to 0.55% (zero point five five percent) of the Performance Security for each Day of delay, subject to a maximum of 180 (one hundred and eighty) Days from the completion of the Build/Renovation Period, shall be appropriated from the Performance Security until the Certificate of Commercial Operation/certificate of commercial operation commencement of blast furnace unit(s) (if applicable) is issued and the Washery commences operations. Provided however, in case of delay beyond 180 (one hundred and eighty) Days from the completion of the Build/Renovation Period, the Authority shall have the right to terminate this Agreement.
Delay in Commercial Operation 

Related to Delay in Commercial Operation

  • Commercial Operation (i) On or before December 31, 2021, Interconnection Customer must demonstrate commercial operation of all generating units. Demonstrating commercial operation includes achieving Initial Operation in accordance with Section 1.4 of Appendix 2 to this ISA and making commercial sales or use of energy, as well as, if applicable, obtaining capacity qualification in accordance with the requirements of the Reliability Assurance Agreement Among Load Serving Entities in the PJM Region.

  • Commercial Operation Date 6.4.1 The SPV shall ensure that the Project Commercial Operation Date is achieved on or prior to the Scheduled Commercial Operation Date. The SPV shall provide a written notice to MSEDCL at least 30 (thirty) days in advance intimating MSEDCL of the proposed date on which the Commercial Operation Date of a Unit or the Project is proposed to be achieved. 6.4.2 If the Commercial Operation Date for the Units having a capacity equivalent to at least 75% (seventy five percent) of the Contracted Capacity is achieved before the Scheduled Commercial Operation Date, then all Units in respect of which the Commercial Operation Date has been achieved prior to the Scheduled Commercial Operation Date would be eligible for incentives as follows: (a) the Unit(s) injecting energy at 11 kV /22 kV shall be given an incentive of Rs. 0.25/ kWh; and (b) the Unit(s) injecting energy at 33 kV shall be given an incentive of Rs. 0.15/ kWh, for the power sold to MSEDCL for the first 3 (three) years from the Commercial Operation Date. To receive such incentives from MSAPL, which shall be over and above the Tariff, the SPV shall follow the process agreed to by the SPV under the Implementation Agreement. 6.4.3 It is hereby clarified that the aforementioned incentive shall not be available: (i) in respect of any Unit if the Commercial Operation Date for such Unit has not been achieved prior to the Scheduled Commercial Operation Date; and (ii) if the aggregate capacity of the Units for which the Commercial Operation Date has been achieved prior to Scheduled Commercial Operation Date is less than 75% (seventy five percent) of the Contracted Capacity. 6.4.4 In the event that Commercial Operation Date for any of the Units is achieved after the Scheduled Commercial Operation Date, the SPV shall be liable to pay Liquidated Damages as per the provisions set out below. 6.4.5 Without prejudice to any other rights of MSEDCL under this PPA, in case one or more Units of the SPV are unable to achieve Commercial Operation Date within a period of 2 (two) months from the Scheduled Commercial Operation Date, the capacity of such Units shall be annulled, and the Contracted Capacity shall be reduced to that extent. For Illustration: The Project has a Contracted Capacity of 100 MW and comprises of 10 Units of 10 MW each. If at the end of the aforementioned period of 14 (fourteen) months from the Effective Date, the SPV has achieved Commissioning for only 8 out of 10 Units, then the Contracted Capacity of the Project will stand reduced for the capacity of the 2 Units which have not been Commissioned, i.e. the Contracted Capacity will be 80 (100 (original Contracted Capacity)) – 10 (capacity of each Unit)*2 (number of Units not Commissioned).

  • Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System. 4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System. 4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA. 4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code. 4.1.5 The Power Producer shall commission the Project within SCOD. 4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer. 4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.

  • Pre-Commencement Phase Services The services required to be provided by the Contractor for the Pre- Commencement Phase of the Project in accordance with the Contract Documents.

  • Commercial Diligence Following Regulatory Approval of a Licensed Product in the SymBio Territory (and prior to Regulatory Approval with respect to pre-launch activities), SymBio shall use Commercially Reasonable Efforts to Commercialize such Licensed Product in the SymBio Territory. In addition, SymBio shall: (a) use Commercially Reasonable Efforts to perform the activities specified in the Commercialization Plan and use Commercially Reasonable Efforts to meet the dates specified therein; (b) achieve First Commercial Sale of each Licensed Product in the SymBio Territory within [ * ] after Regulatory Approval for such Licensed Product has been obtained provided, however, if SymBio is prevented from meeting the foregoing deadline due to (a) a Force Majeure or requirements of a Regulatory Authority, provided that SymBio gives written notice to Eagle at the time SymBio becomes aware that such Force Majeure or Regulatory Authority requirement is likely to or will prevent SymBio from meeting such deadline, or (b) a failure by Eagle to comply with its obligations under this Agreement or the Supply Agreement, then in each case (a) and (b) herein such deadline shall be extended for the amount of time during which SymBio is so prevented from meeting the applicable deadline; and (c) for a period of [ * ] years following First Commercial Sale of each Licensed Product, ensure that the total number of sales representatives deployed, details performed, and advertising and promotional monies spent by SymBio in aggregate for all Licensed Products (collectively, and not for each Licensed Product) in the SymBio Territory during each semi-annual (6-month) period represents at least [ * ] of the total number of sales representatives, details, and advertising and promotional monies committed by or on behalf of SymBio, directly or indirectly, for its bendamustine products (collectively, the Licensed Product and the Existing SymBio Products) in the SymBio Territory during such semi-annual period; provided, however, that in no event shall SymBio provide less than [ * ] primary, first position details in aggregate for all Licensed Products (collectively, and not for each Licensed Product) each year during such [ * ] year period.

  • Substantial Completion Section 7.4.1 When Supplier believes that it has achieved the requirements of Substantial Completion, Supplier shall provide written notice (the “Notice of Substantial Completion”) to System Owner stating that Supplier has achieved Substantial Completion, together with copies of all documents (as identified in the definition of Substantial Completion) that are required to be delivered to System Owner to meet Substantial Completion that have not been previously delivered. Section 7.4.2 Upon receipt of the Notice of Substantial Completion, System Owner shall promptly proceed to obtain Independent Engineer’s review and approval of the Notice of Substantial Completion and the Commissioning Report within a reasonable time, but in no event more than ten (10) Business Days following receipt of the Notice of Substantial Completion and all accompanying documents or such longer period of time as specified in the Construction Schedule (the “Substantial Completion Review Period”). Section 7.4.3 Supplier shall provide System Owner with reasonable notice of the date and time of the inspection or review of the System by a representative of the applicable Governmental Authority or Host Utility, if required, for purposes of achieving Substantial Completion, and System Owner shall have the right to have one or more representatives and the Independent Engineer present during such inspection or review. If the representative of the applicable Governmental Authority or Host Utility notifies Supplier or System Owner that the requirements for achieving Substantial Completion have not been achieved, then Supplier shall promptly take such action as necessary to achieve such requirements and, to the extent applicable, schedule another inspection or review of the System. Such procedure shall be repeated until such inspection or review has been satisfactorily completed and approved. Section 7.4.4 If System Owner and the Independent Engineer approve the Notice of Substantial Completion, System Owner shall, within the Substantial Completion Review Period, (a) notify Supplier of its approval and (b) issue written notice to Supplier to complete the Work (the “Notice to Complete”). Section 7.4.5 If System Owner or the Independent Engineer has a reasonable basis not to approve the Notice of Substantial Completion because the requirements for Substantial Completion have not been met, System Owner shall, within the Substantial Completion Review Period, notify Supplier of its non-approval and include a detailed explanation for the basis thereof. Supplier shall promptly undertake such action or work as necessary to achieve such requirements and shall then issue another Notice of Substantial Completion to System Owner stating that Supplier believes that such requirements have been achieved. Such procedure shall be repeated until Substantial Completion is achieved. If Supplier disputes the reasons stated in System Owner’s notification, then such dispute shall be resolved in accordance with Article XIX.

  • Design Development Phase 1.3.1 Based on the approved Schematic Design Documents, model(s) and any adjustments to the Program of Requirements, BIM Execution Plan or Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Design Development Documents derived from the model(s) in accordance with Owner’s written requirements to further define and finalize the size and character of the Project in accordance with the BIM Execution Plan, “Facility Design Guidelines” and any additional requirements set forth in Article 15. The Architect/Engineer shall review the Design Development documents as they are being modeled at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Design Development. The Architect/Engineer shall allow the Construction Manager to utilize the information uploaded into Owner’s PMIS to assist the Construction Manager in fulfilling its responsibilities to the Owner. 1.3.2 As a part of Design Development Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall utilize Owner’s PMIS to accomplish model coordination and collaborate with Construction Manager in the resolution of critical clashes identified by the Construction Manager. Architect/Engineer shall demonstrate and provide written assurance to Owner that conflicts/collisions between models have been resolved. 1.3.3 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments. 1.3.4 Before proceeding into the Construction Document Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Design Development documents and approval of the mutually established Amount Available for the Construction Contract and schedule. 1.3.5 The Architect/Engineer shall prepare presentation materials including an animation derived from the model(s) as defined in “Facility Design Guidelines” at completion of Design Development and if so requested shall present same to the Board of Regents at a regular meeting where scheduled within the state. 1.3.6 The Architect/Engineer shall prepare preliminary recommended furniture layouts for all spaces where it is deemed important to substantiate the fulfillment of program space requirements, or to coordinate with specific architectural, mechanical and electrical elements. 1.3.7 Architect/Engineer shall assist the Owner, if requested, with seeking approval of the Project by the Texas Higher Education Coordinating Board (THECB). Such assistance shall include (i) the preparation of a listing of the rooms and square footages in the Project, and (ii) the preparation of project cost information, in accordance with THECB Guidelines. This information shall be provided at the completion of the Design Development Phase when requested by the Owner. The listing of rooms and square footages shall then be updated to reflect any changes occurring during construction and provided to the Owner at Substantial Completion. 1.3.8 At the completion of the Design Development Phase, or such other time as Owner may specify to Architect/Engineer, at Owner’s sole option and discretion, Owner will furnish Architect/Engineer with a Guaranteed Maximum Price proposal prepared by Construction Manager based upon the Design Development documents prepared by the Architect/Engineer and approved by the Owner. The Architect/Engineer shall assist the Owner and endeavor to further and advocate the Owner’s interests in Owner’s communications with the Construction Manager in an effort to develop a Guaranteed Maximum Price proposal acceptable to Owner, in Owner’s sole option and discretion. If the Owner does not accept the Construction Manager’s Guaranteed Maximum Price proposal, the Architect/Engineer shall participate with the Owner and Construction Manager in constructability reviews and shall revise the documents as necessary in order to reach an agreement. If the Construction Manager’s Guaranteed Maximum Price proposal exceeds the Schematic Design Phase Estimated Construction Cost prepared by, or otherwise accepted by the Construction Manager due to an increase in the scope of the Project caused by further development of the design documents by the Architect/Engineer to the extent that such could not be reasonably inferred by the Construction Manager from the Schematic Design documents, and Owner directs Architect/Engineer to revise the documents, the Architect/Engineer shall revise the documents at its own expense so that the Guaranteed Maximum Price proposal for constructing the Project shall not exceed the Owner’s Amount Available for the Construction Contract and any previously approved Estimated Construction Costs. If it is determined to be in the Owner’s best interest, instead of requiring the Architect/Engineer to revise the Drawings and Specifications, the Owner reserves the right to accept a Guaranteed Maximum Price proposal that exceeds the stipulated Amount Available for the Construction Contract. The Architect/Engineer shall analyze the final Guaranteed Maximum Price proposal document, together with its supporting assumptions, clarifications, and contingencies, and shall submit a detailed written analysis of the document to the Owner. Such analysis shall include, without limitation, reference to and explanation of any inaccurate or improper assumptions and clarifications. The A/E will not be required to make revisions to the documents at its own expense under the provisions of this paragraph if the Owner’s rejection of the Guaranteed Maximum Price proposal is not due to a failure of the A/E to provide the services otherwise required herein. 1.3.9 After the Guaranteed Maximum Price has been accepted, the Architect/Engineer shall incorporate necessary revisions into the Design Development documents. The A/E will not be required to make revisions to the documents at its own expense under the provisions of this paragraph if the revisions are required as the result of inaccurate assumptions and clarifications made in the development of the Guaranteed Maximum Price proposal that are not due to a failure of the A/E to provide the services otherwise required herein.

  • Development Diligence Pfizer will use Commercially Reasonable Efforts to Develop (including to seek Regulatory Approval for) at least one (1) Licensed Product in one (1) Major Market Country for each Research Project Target for which Pfizer exercises its Option. Except as provided in Section 2.2 and this Section 3.2.1, Pfizer will have no other diligence obligations with respect to the Development or Regulatory Approval of Licensed Products under this Agreement. For avoidance of doubt, any actions taken by Pfizer’s Affiliates or Sublicensees under this Agreement shall be treated as actions taken by Pfizer in regard to satisfaction of the requirements of this Section 3.2.1.

  • Professional Development Program (a) The parties agree to continue a Professional Development Program for the maintenance and development of the faculty members' professional competence and effectiveness. It is agreed that maintenance of currency of subject knowledge, the improvement of performance of faculty duties, and the maintenance and improvement of professional competence, including instructional skills, are the primary professional development activities of faculty members. (b) Information collected as part of this program shall be the sole property of the faculty member. This information or any judgments arising from this program shall not be used to determine non-renewal or termination of a faculty member's contract, suspension or dismissal of a faculty member, denial of advancement on the salary scale, nor affect any other administrative decisions pertaining to the promotion or employment status of the faculty member. (c) A joint advisory committee consisting of three regular faculty members who shall be elected by and are P.D. Committee Chairpersons and three administrators shall make recommendations for the operation, financing and management of the Professional Development Program.

  • CONTINUOUS IMPROVEMENT 3.1 The Supplier shall adopt a policy of continuous improvement in relation to the Services pursuant to which it will regularly review with the Authority the Services and the manner in which it is providing the Services with a view to reducing the Authority's costs (including the Framework Prices), the costs of Contracting Bodies and/or improving the quality and efficiency of the Services. The Supplier and the Authority will provide to each other any information which may be relevant to assisting the objectives of continuous improvement and in particular reducing costs.