Delivery and Acceptance of the Premises Sample Clauses

Delivery and Acceptance of the Premises. Landlord shall deliver possession of the Leased Premises to Tenant on the Commencement Date in broom-clean condition, and with the Landlord’s Work substantially completed and all Building and operating systems and components thereof in good working order and repair, including, but not limited to, the roof, the roof membrane, heating, ventilation, and air conditioning (“HVAC”), electrical, plumbing, lighting, life safety and landscaping. Except as expressly set forth in this Article 2 to the contrary, by taking possession of the Leased Premises, Tenant shall be conclusively deemed to have accepted the Leased Premises in their then-existing “As-Is” condition. Latent defects (which shall be warranted by Landlord, and which exception shall be effective for a one (1) year period following the date the Leased Premises are ready for occupancy) are excepted from the preceding sentence. Notwithstanding the foregoing, Landlord represents to Tenant that as of the Commencement Date the Property, Building and the Leased Premises are to the best of Landlord’s actual knowledge in compliance with local, state and federal laws, regulations and ordinances, including, but not limited to, the Americans with Disabilities Act. If for any reason other than delay caused by Tenant, its agents, employees or consultants, Landlord is unable to deliver possession of the Premises to Tenant by July 1, 2010 with Landlord’s Work substantially completed, Tenant shall have the exclusive option to terminate this Lease by providing written notice to Landlord by July 10, 2010, and in such event neither party shall have any further obligations to the other under this Lease. In the latter event, any Prepaid Rent and the Security Deposit shall be immediately returned to Tenant.
Sample 1Sample 2
AutoNDA by SimpleDocs
Delivery and Acceptance of the Premises. 5.1 Landlord shall have completed Landlord's Work and delivered the Premises to Tenant, and Tenant shall be required to accept the Premises, only after all of the following conditions are satisfied, provided, however, that items (e) and (f) below (collectively, the "POST-COMMENCEMENT DATE WORK") shall not be required to be completed until forty-five (45) days after the Commencement Date, provided Landlord has commenced such work as of the Commencement Date, and, in the reasonable judgment of Landlord's architects, Landlord is able to complete such work within such forty-five (45) day period, and Tenant shall accept the Premises subject to completion of such items (e) and (f):
Sample 1Sample 2
Delivery and Acceptance of the Premises. Landlord shall deliver possession of the Leased Premises to Tenant on the Commencement Date with the roof membrane in water-tight condition without leaks and all operating systems and components thereof in good working order and repair, including, but not limited to, heating, ventilation, and air conditioning (“HVAC”), electrical, plumbing, lighting, water and gas (“Landlord’s Work”). Tenant shall have a one hundred and twenty (120) day warranty period to report any malfunctioning items and may submit a punchlist of the same to Landlord, which punchlist items Landlord will correct at Landlord’s sole cost and expense (and not as an Common Operating Expense). Except as expressly set forth in article 2 to the contrary, Tenant shall accept the Leased Premises in their then-existing “As-Is” condition.
Sample 1
Delivery and Acceptance of the Premises. Tenant accepts the Premises in their “AS IS” condition on the Effective Date, subject only to those representations and warranties of Landlord specifically contained in the Lease. Landlord shall have no obligation to install or make any improvements to the Premises.
Sample 1
Delivery and Acceptance of the Premises. 1. Tenant hereby accepts the Premises in its “As Is” “Where Is” “How Is” condition (subject to Landlord’s completion of the Landlord’s Work, and acknowledges that except for Landlord’s Work, Landlord has not made any representations or warranties with respect to the condition of the Premises and neither Landlord nor any assignee of Landlord shall be liable for any latent defect within the Premises.
Sample 1
Delivery and Acceptance of the Premises. Landlord agrees to deliver to Tenant, and Tenant agrees to accept from Landlord, possession of the Premises forthwith upon delivery by Landlord to Tenant of the Notice of Substantial Completion defined in paragraph 1g of Exhibit C. Notification by Landlord's architect ("Project Architect") of the substantial completion of the Premises in accordance with said Exhibit C shall be conclusive and binding upon the parties hereto. Tenant shall commence the construction of Tenant's Work as described in Exhibit C promptly upon substantial completion of the Premises and shall diligently prosecute such construction to completion and shall open the Premises for business concurrently with the date specified for commencement of Minimum Annual Rental.
Sample 1
Delivery and Acceptance of the Premises. City shall deliver the Premises in a condition fit for use and occupancy by County. Acceptance of the Premises by County shall be construed as recognition that the Premises is in a good state of repair and in sanitary condition.
Sample 1
AutoNDA by SimpleDocs

Related to Delivery and Acceptance of the Premises

  • Acceptance of the Premises By entry and taking possession of the -------------------------- Premises pursuant to this Lease, Tenant accepts the Premises as being in good and sanitary order, condition and repair and accepts the Premises in their condition existing as of the date of such entry, and Tenant further accepts the tenant improvements to be constructed by Landlord, if any, as being completed in accordance with the plans and specifications for such improvements, except for punch list items. Tenant acknowledges that neither Landlord nor Landlord's agents has made any representation or warranty as to the suitability of the Premises to the conduct of Tenant's business. Any agreements, warranties or representations not expressly contained herein shall in no way bind either Landlord or Tenant, and Landlord and Tenant expressly waive all claims for damages by reason of any statement, representation, warranty, promise or agreement, if any, not contained in this Lease. This Lease constitutes the entire understanding between the parties hereto and no addition to, or modification of, any term or provision of this Lease shall be effective until set forth in a writing signed by both Landlord and Tenant.

  • Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 45 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 45 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding anything to the contrary contained herein, if Tenant does not terminate this Lease pursuant to the immediately preceding sentence, Base Rent shall be abated 1 day for each day after such 45 day period (as extended by Force Majeure delays and Tenant Delays) that the Premises are not Delivered to Tenant.

  • Delivery of the Premises When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor. Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely out of the TI Fund. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.

  • Acceptance of Leased Premises On or before the Possession Date, Tenant and Landlord shall each execute the letter agreement in the form attached hereto as Exhibit E (the “Letter Agreement”). By its execution of the Letter Agreement or occupancy of the Leased Premises, Tenant shall be deemed to represent and certify that it has examined the Leased Premises and that it thereby accepts the Leased Premises in its condition at the time, except for the list of defects and/or omissions identified in writing prior to the Possession Date (the “Punch-List”) and latent defects, but subject, in all cases, to Landlord’s repair, maintenance and replacement obligations set forth in this Lease and to the warranty related to the Tenant Improvements, as provided in the Work Letter Agreement. After the notice provided in Section 3.03 and prior to the Possession Date, the parties shall meet in the Leased Premises to establish the Punch-List. Landlord shall review the Punch-List items with Tenant and correct all undisputed Punch- List items within a reasonable time, not to exceed thirty (30) days after receipt of the Punch- List; provided that, if any Punch-List items cannot be corrected within such thirty (30) day period despite reasonable diligence by Landlord, then, so long as Landlord commences correction of such Punch-List items within such thirty (30) day period and diligently pursues such correction to completion, no default by Landlord shall be deemed to have occurred. Punch-List items for completion taking longer than six (6) months to complete (and not otherwise the result of Force Majeure, Tenant Delay, or the COVID-19 Condition) shall trigger a day for day prorated Minimum Monthly Rent abatement. The Tenant Improvements shall be subject to a two (2) year warranty, from the Possession Date, with regard to materials, design and workmanship, as provided in more detail in the Work Letter Agreement. Tenant shall reasonably cooperate with Landlord in providing required information as needed for Landlord to pursue vendor warranties on a timely basis, as requested in writing by Landlord. Landlord will pursue any valid warranty claims against its contractor beyond the two (2) year warranty provided that any expenses incurred and/or any recovery obtained shall be treated as either additional Operating Costs or an offset to Operating Costs under Section 5.03(a).

  • Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.

  • DELIVERY AND INSTALLATION Delivery

  • Use of the Premises 8.1. To use the Premises only as a private residence for the occupation of the Tenant and his immediate family.

  • Rentable Area of the Premises The term "Rentable Area of the Premises" shall mean 29,227 square feet, which Landlord and Tenant have stipulated as the Rentable Area of the Premises. Tenant acknowledges that the Rentable Area of the Premises includes the usable area, without deduction for columns or projections, multiplied by a load factor to reflect a share of certain areas, which may include lobbies, corridors, mechanical, utility, janitorial, boiler and service rooms and closets, restrooms and other public, common and service areas of the Building.

  • Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.

Time is Money Join Law Insider Premium to draft better contracts faster.