Department’s Designated Representative Sample Clauses

Department’s Designated Representative. The Department designates the individual(s) identified in Exhibit I as its representative with express authority to bind the Department with respect to all matters requiring the Department’s approval or authorization. Subject to the limitations on their authority specified in Exhibit I, these representative(s) shall have the exclusive authority to make decisions on behalf of the Department concerning estimates and schedules, construction budgets, changes in the Work, and execution of Change Orders, Contract Modifications or Change Directives, and shall render such decisions promptly and furnish information expeditiously, so as to avoid unreasonable delay in the services or performance of the Work of the Design-Builder. In order for the Department to effectively manage the Project and assure that the Design-Builder does not receive conflicting instructions regarding the Work, the Design-Builder shall promptly notify the Department’s representative upon receiving any instructions or other communication in connection with the Design-Builder’s Work from any employee of the Department or other purported agent of the Department other than the Department’s designated representative.
Sample 1Sample 2Sample 3See All (31)
AutoNDA by SimpleDocs
Department’s Designated Representative. The Department designates the individual(s) identified in Exhibit E as its representative with express authority to bind the Department with respect to all matters requiring the Department’s approval or authorization; provided, however, a duly authorized contracting officer shall have the express authority to bind the Department for matters that are administrative in nature or of a value no greater than One Hundred Thousand Dollars ($100,000). Subject to the limitations on their authority specified in Exhibit E, these representative(s) shall have the exclusive authority to make decisions on behalf of the Department concerning estimates and schedules, construction budgets, changes in the Work, and execution of Change Orders or Change Directives, and shall render such decisions promptly and furnish information expeditiously, so as to avoid unreasonable delay in the services or Work of the Design-Builder. In order for the Department to effectively manage the Project and assure that the Design-Builder does not receive conflicting instructions regarding the Work, the Design-Builder shall promptly notify the Department’s representative upon receiving any instructions or other communication in connection with the Design-Builder’s Work from any employee of the Department or other purported agent of the Department other than the Department’s representative.
Sample 1Sample 2Sample 3See All (7)
Department’s Designated Representative. The Department designates Xxxxx X. Xxxxxx, Director, Department of General Services, as its representative with express authority to bind the Department with respect to all matters requiring the Department’s approval or authorization; provided, however, the Department’s Associate Director, Contracts & Procurement Division, shall have the express authority to bind the Department for matters that are administrative in nature or of a value no greater than One Hundred Thousand Dollars ($100,000). These representatives shall have the exclusive authority to make decisions on behalf of the Department concerning estimates and schedules, construction budgets, changes in the Work, and execution of Change Orders or Change Directives, and shall render such decisions promptly and furnish information expeditiously, so as to avoid unreasonable delay in the services or Work of the Contractor. In order for the Department to effectively manage the Project and assure that the Contractor does not receive conflicting instructions regarding the Work, the Contractor shall promptly notify the Department’s representative upon receiving any instructions or other communication in connection with the Contractor’s Work from any employee of the Department or other purported agent of the Department other than the Department’s representative.
Sample 1Sample 2
Department’s Designated Representative. The Department’s representatives for this Project will be: Xxxxxx Xxxxx Chief Contracting Officer Department of General Services 0000 00xx Xxxxxx, XX Xxxxxxxxxx, XX 00000 xxxxxx.xxxxx@xx.xxx Xxxxxxxx Xxxxxx Contracting Officer Department of General Services 0000 X Xxxxxx, XX 0xx Xxxxx Xxxxxxxxxx, XX 00000 Xxxxxxxx.Xxxxxx0@xx.xxx Although day-to-day communications with the A/E shall be routed through the Program Manager, only the individuals specified in this Section 1.9 have the authority to alter the terms of this Agreement; Without limiting the generality of the foregoing, it is understood and agreed that the Program Manager shall not have the authority to: (i) increase the A/E’s fee or the not-to- exceed amount established herein; (ii) authorize any additional work; or (iii) increase the overall Project budget or the specified design-to-budget.
Sample 1Sample 2
Department’s Designated Representative. The Department designates Xxxxxx Xxxxx, Associate Director, Xxxxxx Xxxxx, Chief Contracting Officer, Contract & Procurement Division, as its representatives with express authority to bind the Department with respect to all matters requiring the Department’s approval or authorization. These representatives shall have the exclusive authority to make decisions on behalf of the Department concerning estimates and schedules, construction budgets, changes in the Work, and execution of Change Orders or Change Directives, and shall render such decisions promptly and furnish information expeditiously, so as to avoid unreasonable delay in the services or Work of the Contractor. In order for the Department to effectively manage the Project and assure that the Contractor does not receive conflicting instructions regarding the Work, the Contractor shall promptly notify the Department’s representative upon receiving any instructions or other communication in connection with the Contractor’s Work from any employee of the Department or other purported agent of the Department other than the Department’s representative.
Sample 1
Department’s Designated Representative. The Department designates the individual(s) identified in Exhibit H as its representative with express authority to bind the Department with respect to all matters requiring the Department’s approval or authorization. Subject to the limitations on their authority specified in Exhibit H, these representative(s) shall have the exclusive authority to make decisions on behalf of the Department concerning estimates and schedules, construction budgets, changes in the Work, and execution of Change Orders or Change Directives, and shall render such decisions promptly and furnish information expeditiously, so as to avoid unreasonable delay in the services or performance of the Work of the Contractor. In order for the Department to effectively manage the Project and assure that the Contractor does not receive conflicting instructions regarding the Work, the Contractor shall promptly notify the Department’s representative upon receiving any instructions or other communication in connection with the Contrator’s Work from any employee of the Department or other purported agent of the Department other than the Department’s designated representative.
Sample 1

Related to Department’s Designated Representative

  • Designated Representative A. Contractor designates as contract agent with primary responsibility for the performance of this contract. In case this contract agent is replaced by another for any reason, the Contractor will designate another contract agent within seven (7) calendar days of the time the first terminates his or her employment or responsibility using the procedure set for in Section O, Notices.

  • Designated Representatives (a) With the delivery of this Agreement, the Subordination Agent shall furnish to each Liquidity Provider and each Trustee, and from time to time thereafter may furnish to each Liquidity Provider and each Trustee, at the Subordination Agent’s discretion, or upon any Liquidity Provider’s or any Trustee’s request (which request shall not be made more than one time in any 12-month period), a certificate (a “Subordination Agent Incumbency Certificate”) of a Responsible Officer of the Subordination Agent certifying as to the incumbency and specimen signatures of the officers of the Subordination Agent and the attorney-in-fact and agents of the Subordination Agent (the “Subordination Agent Representatives”) authorized to give Written Notices on behalf of the Subordination Agent hereunder. Until each Liquidity Provider and each Trustee receives a subsequent Subordination Agent Incumbency Certificate, it shall be entitled to rely on the last Subordination Agent Incumbency Certificate delivered to it hereunder.

  • Owner’s Designated Representative Prior to the start of construction, Owner will identify the Owner’s Designated Representative (ODR), who has the express authority to act and bind the Owner to the extent and for the purposes described in the Contract, including responsibilities for general administration of the Contract.

  • Authorized Representatives No amendment of this Agreement shall be effective unless by written instrument duly executed by the Parties’ authorized representatives. For the purposes of this section, an authorized person refers to individuals designated as such by Parties in their respective corporate by-laws.

  • Association Representatives Authorized representatives of the Association shall be permitted to transact Association business on and with school property at all reasonable times provided that such activities shall not interfere with normal school operations.

  • Association Representative 5.3.1.1 Management recognizes that one of the prime functions of the Council is to represent bargaining unit members and investigate complaints of members of the bargaining unit.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!