Design Development An interim step in the design process. Design Development documents consist of plans, elevations, and other drawings and outline specifications. These documents will fix and illustrate the size and character of the entire project in its essentials as to kinds of materials, type of structure, grade elevations, sidewalks, utilities, roads, parking areas, mechanical and electrical systems, and such other work as may be required.
Technology Access Contractor expressly acknowledges that state funds may not be expended in connection with the purchase of an automated information system unless that system meets certain statutory requirements relating to accessibility by persons with visual impairments. Accordingly, Contractor represents and warrants to System Agency that the technology provided to System Agency for purchase (if applicable under this Contract or any related Solicitation) is capable, either by virtue of features included within the technology or because it is readily adaptable by use with other technology, of: • providing equivalent access for effective use by both visual and non-visual means; • presenting information, including prompts used for interactive communications, in formats intended for non-visual use; and • being integrated into networks for obtaining, retrieving, and disseminating information used by individuals who are not blind or visually impaired. For purposes of this Section, the phrase “equivalent access” means a substantially similar ability to communicate with or make use of the technology, either directly by features incorporated within the technology or by other reasonable means such as assistive devices or services which would constitute reasonable accommodations under the Americans With Disabilities Act or similar state or federal laws. Examples of methods by which equivalent access may be provided include, but are not limited to, keyboard alternatives to mouse commands and other means of navigating graphical displays, and customizable display appearance. In accordance with Section 2157.005 of the Texas Government Code, the Technology Access Clause contract provision remains in effect for any contract entered into before September 1, 2006.
Design Development Phase INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.6.1. The ARCHITECT/ENGINEER shall prepare from the approved Schematic Design Studies, the Design Development Documents consisting of drawings (including at least architectural, landscaping, civil, structural, mechanical and electrical plans, building sections; and finish schedule), outline specifications following the Construction Specification Institute "CSI" Format and other necessary documents to fix and describe the size and character of the entire Project as to its site, structural, mechanical, and electrical systems, materials and other such essentials as may be appropriate, for and until approved by the State. 1.1.6.2. The ARCHITECT/ENGINEER shall conduct meetings with the State, Efficiency Vermont, and relevant members of the design team, to review the Design Development Documents for the purposes of furthering the energy efficiency objectives of the Project. 1.1.6.3. The ARCHITECT/ENGINEER shall prepare for the State a revised accounting of how the Project is responding to LEED criteria. 1.1.6.4. The ARCHITECT/ENGINEER shall submit to the State a revised Statement of Probable Construction Cost based thereon for and until approved by the State.
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK
Design and Drawings (i) Design and Drawings shall be developed in conformity with the Specifications and Standards set forth in Schedule-D. In the event, the Contractor requires any relaxation in design standards due to restricted Right of Way in any section, the alternative design criteria for such section shall be provided for review and approval of the Authority’s Engineer. (ii) The Contractor shall appoint a proof check consultant (the “Proof Consultant”) after proposing to the Authority a panel of three (3) names of qualified and experienced firms from whom the Authority may choose one (1) to be the Proof Consultant. Provided, however, that if the panel is not acceptable to the Authority and the reasons for the same are furnished to the Contractor, the Contractor shall propose to the Authority a revised panel of three (3) names from the firms empanelled as proof consultants by the [Ministry of Road Transport and Highways] for obtaining the consent of the Authority. The Contractor shall also obtain the consent of the Authority for two (2) key personnel of the Proof Consultant who shall have adequate experience and qualifications in highways and bridges respectively. The Authority shall, within 15 (fifteen) days of receiving a proposal from the Contractor hereunder, convey its decision, with reasons, to the Contractor, and if no such decision is conveyed within the said period, the Contractor may proceed with engaging of the Proof Consultant. (iii) The Proof Consultant shall: (a) evolve a systems approach with the Design Director so as to minimise the time required for final designs and construction drawings; and (b) proof check the detailed calculations, drawings and designs, which have been approved by the Design Director. (iv) In respect of the Contractor’s obligations with respect to the design and Drawings of the Project Highway as set forth in Schedule-I, the following shall apply: (a) The Contractor shall prepare and submit, with reasonable promptness and in such sequence as is consistent with the Project Completion Schedule, three (3) copies each of the design and Drawings, duly certified by the Proof Consultant, to the Authority’s Engineer for its approval. Provided, however, that in respect of Major Xxxxxxx and Structures, the Authority’s Engineer may require additional drawings for approval in accordance with Good Industry Practice. (b) by submitting the Drawings for review and approval to the Authority’s Engineer, the Contractor shall be deemed to have represented that it has determined and verified that the design and engineering, including field construction criteria related thereto, are in conformity with the Scope of the Project, the Specifications and Standards and the Applicable Laws; (c) within 15 (fifteen) days of the receipt of the Drawings, the Authority’s Engineer shall review the same and convey its approval/observations to the Contractor with particular reference to their conformity or otherwise with the Scope of the Project and the Specifications and Standards. Provided, however that in case of a major bridge or structure, the aforesaid period of 15 (fifteen) days may be extended up to 30 (thirty) days; (d) if the aforesaid observations of the Authority’s Engineer indicate that the Drawings are not in conformity with the Scope of the Project or the Specifications and Standards, such Drawings shall be revised by the Contractor in conformity with the provisions of this Agreement and resubmitted to the Authority’s Engineer for review and approval. The Authority’s Engineer shall give its observations, if any, within 10 (ten) days of receipt of the revised Drawings. In the event the Contractor fails to revise and resubmit such Drawings to the Authority’s Engineer for review/approval as aforesaid, the Authority’s Engineer may withhold the payment for the affected works in accordance with the provisions of Clause 19.5 (iv). If the Contractor disputes any decision, direction or determination of the Authority’s Engineer hereunder, the Dispute shall be resolved in accordance with the Dispute Resolution Procedure; (e) no review/approval and/or observation of the Authority’s Engineer and/or its failure to review/approval and/or convey its observations on any Drawings shall relieve the Contractor of its obligations and liabilities under this Agreement in any manner nor shall the Authority’s Engineer or the Authority be liable for the same in any manner; and if errors, omissions, ambiguities, inconsistencies, inadequacies or other Defects are found in the Drawings, they and the construction works shall be corrected at the Contractor's cost, notwithstanding any approval under this Article 10; (f) the Contractor shall be responsible for delays in submitting the Drawing as set forth in Schedule-I caused by reason of delays in surveys and field investigations, and shall not be entitled to seek any relief in that regard from the Authority; and (g) the Contractor warrants that its designers, including any third parties engaged by it, shall have the required experience and capability in accordance with Good Industry Practice and it shall indemnify the Authority against any damage, expense, liability, loss or claim, which the Authority might incur, sustain or be subject to arising from any breach of the Contractor’s design responsibility and/or warranty set out in this Clause. (h) the Contractor shall ensure that all the designs and drawings shall be approved from the Authority’s Engineer within 90 days (ninety) from the Appointed Date. (v) Any cost or delay in construction arising from review/approval by the Authority’s Engineer shall be borne by the Contractor. (vi) Works shall be executed in accordance with the Drawings provided by the Contractor in accordance with the provisions of this Clause 10.2 and the approval of the Authority’s Engineer thereon as communicated pursuant to the provisions of sub- Clause (c) & (d) of Clause 10.2 (iv). Such Drawings shall not be amended or altered without prior written notice to the Authority’s Engineer. If a Party becomes aware of an error or defect of a technical nature in the design or Drawings, that Party shall promptly give notice to the other Party of such error or defect. (vii) Within 90 (ninety) days of the Project Completion Date, the Contractor shall furnish to the Authority and the Authority’s Engineer a complete set of as- built Drawings, in 2 (two) hard copies and in micro film form or in such other medium as may be acceptable to the Authority, reflecting the Project Highway as actually designed, engineered and constructed, including an as-built survey illustrating the layout of the Project Highway and setback lines, if any, of the buildings and structures forming part of Project Facilities.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Design Development Documents See Section 2, Part 1, Article 2.1.5.
Scope of Works (a) Users with an appropriate licence type may be able to create and access Scope of Works. (b) The parties acknowledge and agree that: (i) any wording contained in a Scope of Works is established by the Customer, is customisable and within the Customer's absolute control; (ii) Users make decisions within ProcurePro on how to draft Scope of Works and ProcurePro is not responsible for those decisions; (iii) the Supplier is not liable for the Customer's use or reliance upon any Scope of Works; and (iv) the Supplier is not responsible for controlling the use, copying, modification or export of a Scope of Works by any User to which the Customer allows access to that Scope of Works.
Curriculum Development This includes the analysis and coordination of textual materials; constant review of current literature in the field, some of which are selected for the college library collection, the preparation of selective, descriptive materials such as outlines and syllabi; conferring with other faculty and administration on curricular problems; and, the attendance and participation in inter and intra-college conferences and advisory committees.
Software Development Software designs, prototypes, and all documentation for the final designs developed under this agreement must be made fully transferable upon direction of NSF. NSF may make the software design, prototype, and documentation for the final design available to competitors for review during any anticipated re-competition of the project.