Equipment Maintenance If this Contract involves computer or telecommunications hardware or other mechanical or electrical Equipment maintenance (use of the word "Equipment" means all the foregoing) as a Deliverable, then, during the warranty period and during any period covered by annual maintenance, the Contractor will provide Equipment maintenance to keep the Equipment in or restore the Equipment to good working order. This maintenance will include preventative and remedial maintenance, installation of safety changes, and installation of engineering changes based upon the specific needs of the individual item of Equipment. This maintenance will also include the repair, replacement, or exchange deemed necessary to keep the Equipment in good working order. For purposes of this Contract, Equipment restored to good working condition means Equipment that performs in accordance with the manufacturer's published specifications. The Contractor will exert its best efforts to perform all fault isolation and problem determination attributed to the Equipment covered under this Contract. The following services are outside the scope of this Contract:
1. Repair and replacement work or increase in maintenance time as a result of damage or loss resulting from accident, casualty, neglect, misuse, or abuse if such is the State's fault (and beyond normal wear and tear), damage resulting from improper packing or failure to follow prescribed shipping instruction (If such is done by the State), failure of electrical power, air conditioning or humidity control, use of supplies not approved by the original manufacturer of the Equipment as describe or included in the Contractor's proposal, or causes other than ordinary use of Equipment.
2. All information necessary for the State to perform the maintenance, including but not limited to logic diagrams, maintenance manuals and system and unit schematics with all changes noted.
3. A listing of spare parts and their recommended replacement schedule that will enable the State to create a centralized inventory of spare parts.
Installation and Maintenance Except for the bi‐directional and production metering equipment owned by the City, all equipment on Customer’s side of the delivery point, including the required disconnect device, shall be provided and maintained in satisfactory operating condition by Customer and shall remain the property and responsibility of the Customer. The City will bear no responsibility for the installation or maintenance of Customer’s equipment or for any damage to property as a result of any failure or malfunction thereof. The City shall not be liable, directly or indirectly for permitting or continuing to allow the interconnection of the Facility or for the acts or omissions of Customer or the failure or malfunction of any equipment of Customer that causes loss or injury, including death, to any party.
System Maintenance The Trust understands that USBFS will perform periodic maintenance to the System(s), which may cause temporary service interruptions. To the extent possible, USBFS shall notify the Trust of all planned outages and will perform any necessary maintenance during non-business hours.
Supply and Maintenance of Equipment It is the responsibility of the Employer to furnish and maintain all equipment, machinery and supplies required by employees in the performance of their duties. Employees shall not suffer any loss in salary in the event that they cannot carry out their normal duties by reason of the Employer failing to properly maintain equipment, machinery or supplies or by reason of power failures or other circumstances not attributable to the employees.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Aircraft Maintenance Operator shall, at its own expense, cause the Aircraft to be inspected, maintained, serviced, repaired, overhauled, and tested in accordance with FAR Part 91 so that the Aircraft will remain in good operating condition and in a condition consistent with its airworthiness certification and shall take such requirements into account in scheduling the Aircraft hereunder, including but not limited compliance with applicable airworthiness directives and service bulletins. Performance of maintenance, preventive maintenance or inspection shall not be delayed or postponed for the purpose of scheduling the Aircraft unless such maintenance or inspection can safely be conducted at a later time in compliance with applicable laws, regulations and requirements, and such delay or postponement is consistent with the sound discretion of the pilot-in-command. In the event that any non-standard maintenance is required during the term and will interfere with User’s requested or scheduled flights, Operator, or Operator’s pilot-in-command, shall notify User of the maintenance required, the effect on the ability to comply with User’s requested or scheduled flights and the manner in which the parties will proceed with the performance of such maintenance and conduct of such flight(s). In no event shall Operator be liable to User or any other person for loss, injury or damage occasioned by the delay or failure to furnish the Aircraft under this Agreement, whether or not maintenance-related.
Planned Maintenance (a) Subject to any modification or amendment of this Agreement made pursuant to Section 4.2(c) or Section 7.3(d), Planned Maintenance occurring during the Delivery Term shall be coordinated and scheduled in accordance with this Section 9.6. Seller shall perform all Planned Maintenance (including Major Planned Maintenance) in a manner that optimizes the generation and benefits to Buyer of the Contract Energy, Storage Energy, and other Products (e.g., during off-peak periods and low-irradiance periods) and, without limiting the foregoing, either
(i) outside of Daylight Hours or (ii) during the months of October and November only, during Daylight Hours; provided, however, that the foregoing restrictions shall not apply to any Planned Maintenance that Seller is required to perform pursuant to any applicable manufacturer warranty that cannot reasonably be performed by Seller subject to such restrictions.
(b) Seller shall deliver to Buyer a proposed schedule for Planned Maintenance in respect of each Contract Year (“Planned Maintenance Schedule”) no later than ninety (90) Days before the start of such Contract Year. Planned Maintenance Schedules submitted by Seller shall
(i) comply with the second sentence of Section 9.6(a) and (ii) include reasonably detailed descriptions of the Planned Maintenance to be performed, the Days and times in which each type of Planned Maintenance is scheduled to be performed, the estimated amount(s) of Contract Capacity and Storage Capacity that will be unavailable due to Planned Maintenance and the total number of hours that Seller expects that the Contract Capacity and Storage Capacity will be unavailable due to Planned Maintenance. The general form for the Planned Maintenance Schedule is set forth in Schedule 9.6. (The Planned Maintenance descriptions reflected in the general form set forth in Schedule 9.6 are provided for indicative purposes only, and are not necessarily representative of the detail, time periods, or certainty required for a Planned Maintenance Schedule hereunder.)
(c) Buyer shall have the right to disapprove, in its reasonable discretion (provided that Buyer shall have the right to disapprove, in its sole and absolute discretion, any Planned Maintenance proposed by Seller that is inconsistent with the terms of this Agreement), any Planned Maintenance set out in any Planned Maintenance Schedule proposed by Seller for any Contract Year, except for any Planned Maintenance that (i) is scheduled to occur outside of Daylight Hours or during Daylight Hours during the months of October and November or (ii) Seller is required to perform pursuant to any applicable manufacturer warranty and that is scheduled to occur in compliance with Section 9.6(a). If Seller submits its Planned Maintenance Schedule for a Contract Year in accordance with the requirements of this Agreement and Buyer does not disapprove of any Planned Maintenance set out in such Planned Maintenance Schedule by sixty (60) days after submission, then such Planned Maintenance Schedule shall be deemed approved. If Buyer, in the exercise of its discretion as set forth above, disapproves any Planned Maintenance in such Planned Maintenance Schedule within the applicable time period specified above after its submission, Buyer shall notify Seller and the Parties shall use Commercially Reasonable Efforts to agree upon and finalize a mutually acceptable Planned Maintenance Schedule for the applicable Contract Year. Seller shall conduct Planned Maintenance during such Contract Year only in accordance with an agreed Planned Maintenance Schedule; provided, however, that Seller may (A) move Planned Maintenance included in an agreed Planned Maintenance Schedule that is not Major Planned Maintenance, so long as such move is consistent with the terms of this Agreement (including the second sentence of Section 9.6(a)) or, with respect to Major Planned Maintenance, if such Major Planned Maintenance is scheduled to occur outside of Daylight Hours or during Daylight Hours during the months of October and November and (B) schedule and perform Planned Maintenance not reflected in the Planned Maintenance Schedule so long as such Planned Maintenance is scheduled to be performed outside of Daylight Hours or during Daylight Hours during the months of October and November and Seller provides Buyer at least two (2) weeks’ prior written notice of such Planned Maintenance; provided further that Buyer shall have the right to advise Seller of periods when Buyer prefers, based on solar irradiance, supply, market and other conditions, that any Major Planned Maintenance be deferred, and Seller shall use Commercially Reasonable Efforts to comply with such request.
(d) Seller shall use Commercially Reasonable Efforts to complete any Planned Maintenance and place the Facility back into full commercial operation as soon as reasonably possible. If Seller determines that any Planned Maintenance scheduled in an agreed Planned Maintenance Schedule no longer needs to be completed or will not consume the entire time scheduled therefor in the agreed Planned Maintenance Schedule, Seller shall provide (i) a Generation Forecast to Buyer reflecting the forecasted amount of Delivered Energy during each affected interval that takes into account such change and (ii) in the case of any Major Planned Maintenance, a written notice declaring the cessation and termination of the applicable Major Planned Maintenance period (in which event, the Major Planned Maintenance period shall terminate in accordance with the terms of such Generation Forecast and written notice).
Maintenance and Repairs (1) Except for matters specified under Paragraph 4 above and Paragraph 8A(3) below as being Landlord's obligation, Tenant shall, at Tenant's sole cost and expense, maintain the Premises in good order, condition and repair, ordinary wear and tear and damage by fire and casualty excepted, including: the interior surfaces of the ceilings, walls and floors; all doors and interior windows; furnishings installed within the Premises; all equipment installed by or at the expense of Tenant; and all plumbing, heating, ventilating, electrical and lighting facilities and fixtures; all landscaping, parking lots, fences and signs located within the Premises.
(2) In the event that Tenant fails to maintain the Premises in good order, condition and repair as required under this Lease, Landlord shall give Tenant prior written notice to do such acts as are required to so maintain the Premises. In the event that Tenant fails to commence such work within 30 days after written demand by Landlord, and diligently prosecute it to completion, then Landlord shall have the right, but shall not be obligated, to do such acts and expend such funds at the expense of Tenant as are reasonably required to perform such work. Landlord shall have no liability to Tenant for any reasonable damage, inconvenience or interference with Tenant's use of the Premises as a result of performing any such work.
(3) Landlord will maintain, repair and replace all structural components of the Premises and the roof of the Building, and if a repair, replacement or alteration or other change would be considered a capital improvement or replacement to the Premises under generally accepted accounting principles, then it shall be Landlord's responsibility to promptly make and pay for such repair, replacement, alteration or other change. The cost of any such capital improvement shall be amortized over the useful life of such item and Tenant agrees to pay its percentage share (which shall be determined by dividing the square footage of the Building by the square footage of all buildings benefitted by such improvement, including the Building) of the annual amortized amount. Such payment will be made by Tenant as set forth in Paragraph 4 above. Landlord shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating to the Premises, except to the extent that the foregoing are solely a result of Tenant's use of the Premises. Tenant shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating solely to Tenant's use of the Premises. If a repair is required as a result of Tenant's negligence and such repair cost is not covered by insurance proceeds, Tenant will pay for the cost of such repair. Notwithstanding anything in this Lease to the contrary, in the event that the need for repairs or the making of repairs (or both) which Landlord is obligated to effect at Landlord's expense renders a material portion of the Premises unusable for more than three consecutive business days, then Tenant shall be entitled to an abatement of rent commencing with the fourth business day that the same are unusable; provided, however, that Tenant shall not be entitled to a pro rata abatement of rent under the foregoing due to unusability (i) caused directly or indirectly by any act or omission of Tenant or any of Tenant's servants, employees, agents, contractors, visitors or licensees, (ii) where Tenant makes a decoration, alteration, improvement or addition which directly causes such unusability, or (iii) where the repair in question is one which Tenant is obligated to furnish under the provisions of this Lease.
Installation, Maintenance, Testing and Repair Unless otherwise agreed in writing by the Parties, to the extent required by Applicable Law, Interconnection provided by a Party shall be equal in quality to that provided by such Party to itself, any subsidiary, affiliates or third party. If either Party is unable to fulfill its obligations under this Section 14.2, it shall notify the other Party of its inability to do so and will negotiate alternative intervals in good faith. The Parties agree that to the extent required by Applicable Law, the standards to be used by a Party for isolating and clearing any disconnections and/or other outages or troubles shall be at parity with standards used by such Party with respect to itself, any subsidiary, affiliate or third party.
MAINTENANCE AND REPAIR; RULES Tenant will, at its sole expense, keep and maintain the Premises and appurtenances in good and sanitary condition and repair during the term of this Agreement and any renewal thereof. Without limiting the generality of the foregoing, Tenant shall:
(a) Not obstruct the driveways, sidewalks, courts, entry ways, stairs and/or halls, which shall be used for the purposes of ingress and egress only;
(b) Keep all windows, glass, window coverings, doors, locks and hardware in good, clean order and repair;
(c) Not obstruct or cover the windows or doors;
(d) Not leave windows or doors in an open position during any inclement weather;
(e) Not hang any laundry, clothing, sheets, etc. from any window, rail, porch or balcony nor air or dry any of same within any yard area or space;
(f) Not cause or permit any locks or hooks to be placed upon any door or window without the prior written consent of Landlord;
(g) Keep all air conditioning filters clean and free from dirt;
(h) Keep all lavatories, sinks, toilets, and all other water and plumbing apparatus in good order and repair and shall use same only for the purposes for which they were constructed. Tenant shall not allow any sweepings, rubbish, sand, rags, ashes or other substances to be thrown or deposited therein. Any damage to any such apparatus and the cost of clearing stopped plumbing resulting from misuse shall be borne by Tenant;
(i) And Tenant's family and guests shall at all times maintain order in the Premises and at all places on the Premises, and shall not make or permit any loud or improper noises, or otherwise disturb other residents;
(j) Keep all radios, television sets, stereos, phonographs, etc., turned down to a level of sound that does not annoy or interfere with other residents;
(k) Deposit all trash, garbage, rubbish or refuse in the locations provided therefor and shall not allow any trash, garbage, rubbish or refuse to be deposited or permitted to stand on the exterior of any building or within the common elements;
(l) Abide by and be bound by any and all rules and regulations affecting the Premises or the common area appurtenant thereto which may be adopted or promulgated by the Condominium or Homeowners' Association having control over them.
