Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
(a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv);
(b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13);
(c) occurrence of a Force Majeure Event;
(d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and
(e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement.
(ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder.
(iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim.
(iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension.
(v) If the event or circumstance giving rise to the notice has a continuing effect:
(a) a fully detailed claim shall be considered as interim;
(b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and
(c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
BIDDING DEPOSIT Subject to Clause 5.1 below, all intending bidders shall deposit with the Auctioneer, prior to the auction sale, a bank draft or cashier’s order drawn in favour of AmBank (M) Berhad for the a/c of IKHMAS JAYA SDN BHD, a Bidding Deposit equivalent to ten per cent (10%) of the Reserve Price or a minimum of RM2,000.00 whichever is higher. Online Bidders are subject to the provisions of Clause(s) 2.4, 2.5 and 2.6 of the Terms and Conditions on xxxx.xxxxxxxx.xxx.xx for the manner of payment of the deposit.
CONTRACT COMPLETE This Contract represents the complete agreement between the parties. No other understanding regarding this Contract, whether written or oral, may be used to bind either party. For any conflict between the attached Proposal and the terms set out in Articles 1-22 of this Contract, the terms of Articles 1-22 will govern.
Contract Closeout The Provider Agency shall comply with all requirements of Policy Circular P7.01, Contract Closeout, including the timely submittal of the Final Report of Expenditures and any other financial or programmatic reports required by the Department. All required documentation is due within 120 Days of Contract Expiration, Non-renewal or Termination.
Expectations Regarding Advance Notices Within ten (10) days after the commencement of each calendar quarter occurring subsequent to the commencement of the Commitment Period, the Company must notify the Investor, in writing, as to its reasonable expectations as to the dollar amount it intends to raise during such calendar quarter, if any, through the issuance of Advance Notices. Such notification shall constitute only the Company's good faith estimate and shall in no way obligate the Company to raise such amount, or any amount, or otherwise limit its ability to deliver Advance Notices. The failure by the Company to comply with this provision can be cured by the Company's notifying the Investor, in writing, at any time as to its reasonable expectations with respect to the current calendar quarter.
Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Patent Extensions Subject to the remainder of this Section 6.6, if any election for patent term restoration or extension, supplemental protection certificate or any of their equivalents may be made with respect to any Patent within the Licensed IP, after consultation with Celgene, the Parties will discuss and seek to reach mutual agreement whether or not to take such action. If the Parties are not able to reach mutual agreement, (a) Celgene will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to Specific Patents and Patents within the Collaboration IP licensed to Celgene hereunder and (b) Bluebird will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to all other Patents within the Licensed IP.
Order Rejections 53.11.1 CenturyLink shall reject and return to CLEC any order that CenturyLink cannot provision, due to technical reasons, missing information, or jeopardy conditions resulting from CLEC ordering service at less than the standard order interval.
53.11.2 When an order is rejected, CenturyLink will, in its reject notification, describe the existing reasons for which the order was rejected.
