Informal Resolution of Disputes 10.5.1 Upon receipt by one Party of notice of a dispute by the other Party pursuant to Section 10.3 or Section 10.4.5, each Party will appoint a knowledgeable, responsible representative to meet and negotiate in good faith to resolve any dispute arising under this Agreement. The location, form, frequency, duration, and conclusion of these discussions will be left to the discretion of the representatives. Upon agreement, the representatives may utilize other alternative Dispute Resolution procedures such as mediation to assist in the negotiations. Discussions and the correspondence among the representatives for purposes of settlement are exempt from discovery and production and will not be admissible in the arbitration described below or in any lawsuit without the concurrence of both Parties. Documents identified in or provided with such communications that were not prepared for purposes of the negotiations are not so exempted, and, if otherwise admissible, may be admitted in evidence in the arbitration or lawsuit.
Informal Procedures A. The grievant should first discuss the matter with his/her principal or administrator or supervisor to whom he/she is directly responsible in an effort to resolve the problem informally.
B. If the grievant is not satisfied with the disposition of the matter, he/she shall have the right to have a representative of his/her choice to assist him/her in further efforts to resolve the problem informally with the principal or other appropriate administrator or supervisor.
Informal Procedure A complaint may be presented informally to the administrator whose decision or action is being contested.
Dispute Resolution Procedures (a) In the event a dispute arises about the interpretation, application, calculation of Loss, or calculation of payments or otherwise with respect to this Single Family Shared-Loss Agreement (“SF Shared-Loss Dispute Item”), then the Receiver and the Assuming Institution shall make every attempt in good faith to resolve such items within sixty (60) days following the receipt of a written description of the SF Shared-Loss Dispute Item, with notification of the possibility of taking the matter to arbitration (the date on which such 60-day period expires, or any extension of such period as the parties hereto may mutually agree to in writing, herein called the “Resolution Deadline Date”). If the Receiver and the Assuming Institution resolve all such items to their mutual satisfaction by the Resolution Deadline Date, then within thirty (30) days following such resolution, any payment due as a result of such resolution shall be made arising from the settlement of the SF Shared-Loss Dispute.
(b) If the Receiver and the Assuming Institution fail to resolve any outstanding SF Shared-Loss Dispute Items by the Resolution Deadline Date, then either party may notify the other of its intent to submit the SF Shared-Loss Dispute Item to arbitration pursuant to the provisions of this Article VII. Failure of either party to submit pursuant to paragraph (c) hereof any unresolved SF Shared-Loss Dispute Item to arbitration within thirty (30) days following the Resolution Deadline Date (the date on which such thirty (30) day period expires is herein called the “Arbitration Deadline Date”) shall extinguish that party’s right to submit the non-submitted SF Shared-Loss Dispute Item to arbitration, and constitute a waiver of the submitting party’s right to dispute such non-submitted SF Shared-Loss Dispute Item (but not a waiver of any similar claim which may arise in the future).
(c) If a SF Shared-Loss Dispute Item is submitted to arbitration, it shall be governed by the rules of the American Arbitration Association (the “AAA”), except as otherwise provided herein. Either party may submit a matter for arbitration by delivering a notice, prior to the Arbitration Deadline Date, to the other party in writing setting forth:
(i) A brief description of each SF Shared-Loss Dispute Item submitted for arbitration;
(ii) A statement of the moving party’s position with respect to each SF Shared-Loss Dispute Item submitted for arbitration;
(iii) The value sought by the moving party, or other relief requested regarding each SF Shared-Loss Dispute Item submitted for arbitration, to the extent reasonably calculable; and
(iv) The name and address of the arbiter selected by the moving party (the “Moving Arbiter”), who shall be a neutral, as determined by the AAA. Failure to adequately include any information above shall not be deemed to be a waiver of the parties right to arbitrate so long as after notification of such failure the moving party cures such failure as promptly as reasonably practicable.
(d) The non-moving party shall, within thirty (30) days following receipt of a notice of arbitration pursuant to this Section 7.1, deliver a notice to the moving party setting forth:
(i) The name and address of the arbiter selected by the non-moving party (the “Respondent Arbiter”), who shall be a neutral, as determined by the AAA;
(ii) A statement of the position of the respondent with respect to each Dispute Item; and
(iii) The ultimate resolution sought by the respondent or other relief, if any, the respondent deems is due the moving party with respect to each SF Shared-Loss Dispute Item. Failure to adequately include any information above shall not be deemed to be a waiver of the non-moving party’s right to defend such arbitration so long as after notification of such failure the non-moving party cures such failure as promptly as reasonably practicable
(e) The Moving Arbiter and Respondent Arbiter shall select a third arbiter from a list furnished by the AAA. In accordance with the rules of the AAA, the three (3) arbiters shall constitute the arbitration panel for resolution of each SF Loss-Share Dispute Item. The concurrence of any two (2) arbiters shall be deemed to be the decision of the arbiters for all purposes hereunder. The arbitration shall proceed on such time schedule and in accordance with the Rules of Commercial Arbitration of the AAA then in effect, as modified by this Section 7.1. The arbitration proceedings shall take place at such location as the parties thereto may mutually agree, but if they cannot agree, then they will take place at the offices of the Corporation in Washington, DC, or Arlington, Virginia.
(f) The Receiver and Assuming Institution shall facilitate the resolution of each outstanding SF Shared-Loss Dispute Item by making available in a prompt and timely manner to one another and to the arbiters for examination and copying, as appropriate, all documents, books, and records under their respective control and that would be discoverable under the Federal Rules of Civil Procedure.
Informal Resolution Outcomes a. When a complainant approaches an administrative officer and alleges harassment by another BCTF member, the following shall apply:
i. All discussions shall be solely an attempt to mediate the complaint;
ii. Any and all discussions shall be completely off the record and will not form part of any record;
iii. Only the complainant, respondent, and administrative officer shall be present at such meetings
iv. No discipline of any kind would be imposed on the respondent; and
v. The BCTF and its locals, based on the foregoing, will not invoke the notice of investigation and other discipline provisions of the collective agreement at meetings pursuant to Article E.2.5.a.
b. Should a resolution be reached between the complainant and the respondent at Step One under the circumstances of Article E.2.5.a, it shall be written up and signed by both. Only the complainant and the respondent shall have copies of the resolution and they shall be used only for the purpose of establishing that a resolution was reached. No other copies of the resolution shall be made.
c. In the circumstances where a respondent has acknowledged responsibility pursuant to Article E.
Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager.
2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation.
3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief.
4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
Informal Dispute Resolution (a) Prior to the initiation of formal dispute resolution procedures (i.e., arbitration), the Parties shall first attempt to resolve their dispute at the senior manager level. If that level of dispute resolution is not successful, the Parties shall proceed informally, as follows:
(i) Upon the written request of either Party, each Party shall appoint a designated representative who does not otherwise devote substantially full time to performance under this Agreement, whose task it will be to meet for the purpose of endeavoring to resolve such dispute.
(ii) The designated representatives shall meet as often as the Parties reasonably deem necessary in order to gather and furnish to the other all information with respect to the matter in issue that the Parties believe to be appropriate and germane in connection with its resolution. The representatives shall discuss the problem and attempt to resolve the dispute without the necessity of any formal proceeding.
(iii) During the course of discussion, all reasonable requests made by one Party to another for non-privileged non-confidential information reasonably related to this Agreement shall be honored so that each of the Parties may be fully advised of the other's position.
(iv) The specific format for the discussions shall be left to the discretion of the designated representatives.
(b) Prior to instituting formal proceedings, the Parties will first have their chief executive officers meet to discuss the dispute. This requirement shall not delay the institution of formal proceedings past any statute of limitations expiration or for more than fifteen (15) days.
(c) Subject to Subsection (b), formal proceedings for the resolution of a dispute may not be commenced until the earlier of:
(i) The designated representatives concluding in good faith that amicable resolution through continued negotiation of the matter does not appear likely; or
(ii) Thirty (30) days after the initial written request to appoint a designated representative pursuant to Subsection (a), above, (this period shall be deemed to run notwithstanding any claim that the process described in this Section 11.2 was not followed or completed).
(d) This Section 11.2 shall not be construed to prevent a Party from instituting, and a Party is authorized to institute, formal proceedings earlier to avoid the expiration of any applicable limitations period, or to preserve a superior position with respect to other creditors or as provided in Section 11.6(a).
GRIEVANCE AND ARBITRATION PROCEDURES A. A grievance is a dispute, claim, or complaint arising under this Agreement, filed by either an authorized representative of or an employee in the Bargaining Unit, or the County, involving the interpretation or application of this Agreement. All discipline shall be for just cause.
B. Grievances will be processed in the following manner and strictly in accordance with the following stated time limits:
Step 1. The aggrieved employee shall be accorded fifteen (15) working days from the occurrence of the action or event or when the employee has knowledge or should have had knowledge of the action or the event giving rise to the complaint to seek resolution on an informal basis. The Employee must discuss his alleged grievance with the Airport Fire Chief and the Fire Rescue Division Director. If informal resolution is not accomplished, the employee, if a Union member, must present the proposed grievance in writing to a Union officer on or before the fifteenth (15th) working day for consideration by the Union Grievance committee. If, in the Committee's opinion, no reasonable grievance exists, no further action may be taken.
Step 2. If the Committee wishes to pursue the member's complaint, a written grievance shall be presented to the Director of the Fire Rescue Division or his designee within twenty (20) working days from the occurrence of the action or event giving rise to the grievance or from the date on which the employee reasonably should have had knowledge of that occurrence. A written grievance must be presented on a grievance form provided by the County in Appendix A. Upon receipt of a formal grievance or a class action submitted by the Union, the Fire Rescue Division Director or his designee shall investigate the facts and conduct a meeting within five (5) working days with the aggrieved employee and any other persons possessing knowledge considered critical by the Director. The aggrieved employee may be accompanied at this meeting by a local Union representative. The Fire Rescue Division Director or his designee shall notify the grievant of his decision no later than five (5) working days following the date of the meeting.
Step 3. If the grievance is not resolved at the second step, the aggrieved employee shall present the written grievance within five (5) working days of the Step 2 decision to the Department Head. The Department Head or his designee shall investigate the facts and may conduct a hearing within five
Arbitration Procedures In the event that the teacher and the School Board are unable to resolve any grievance, the grievance may be submitted to arbitration as defined herein:
1. Request: A request to submit a grievance to arbitration must be in writing signed by the aggrieved party, and such request must be filed in the office of the superintendent within ten (10) days following the decision in Level III of the grievance procedure.
Issue Resolution Procedures As soon as possible after any occupational health and safety issue has been reported, the company’s or management representative and elected safety representative must meet to try to resolve the issue. The resolution of the issue must take into account those of the following factors that are relevant: o Whether the hazard or risk can be isolated o The number and location of employees affected o Whether appropriate temporary measures are possible or desirable o Whether environmental monitoring is desirable o The time that may elapse before the hazard or risk is permanently corrected o Who is responsible for performing work and overseeing the removal of the hazard or risk. As soon as possible after the resolution of an issue, details of the agreement must be brought to the attention of affected employees in an appropriate manner. Should the matter not be resolved, the issue shall be dealt with in line with Clause 20 of the VBIA “Safety Disputes Resolution Procedure”.
