Final Inspection and Final Acceptance Sample Clauses

Final Inspection and Final Acceptance. A. Upon notification from the Contractor that the Project is complete and ready for inspection, the Town shall complete a final inspection to verify that the Project is complete. The Contractor shall schedule the final inspection at a time and date acceptable to the Town.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Final Inspection and Final Acceptance. 12.15 When the Design-Builder considers the entire Work, or an agreed-upon portion thereof, to be complete, he shall certify, in writing, that the Work is complete and request a letter granting Final Acceptance. Within 30 days after receipt of the Design-Builder’s certification, the City will inspect the Work, and the lead designer shall certify that it has reviewed the Work, and, upon recommendation by the lead designer, the City will notify the Design-Builder, in writing, of Final Acceptance or of all particulars in which this inspection reveals that the Work is incomplete or Defective. The Design-Builder shall immediately take such measures as are necessary to remedy such deficiencies and allow an additional 30 days for the City to complete another inspection of the Work. Issuance of Final Acceptance by the City shall not constitute (1) a waiver of any right or remedy of the City under the Contract or Law or (2) approval of or acquiescence to any breach of this Contract. The Design-Builder’s certification shall be preceded or accompanied by all documentation called for in this Contract, including but not limited to:
Sample 1Sample 2
Final Inspection and Final Acceptance. At the end of the guarantee period and upon written request of the Contractor, the Parks and Forestry Asset Manager and/or City Landscape Architect will inspect all guaranteed work for final acceptance. The request shall be received at least 5 days before the anticipated date for final inspection. Upon completion and re-inspection of all repairs or renewals necessary in the judgment of the Parks and Forestry Asset Manager and/or City Landscape Architect at that time, the Parks and Forestry Asset Manager and/or City Landscape Architect shall certify, in writing, that the project has received final acceptance.
Sample 1
Final Inspection and Final Acceptance. 12.15 When the Design-Builder considers the entire Work, or an agreed-upon portion thereof, to be complete, he shall certify, in writing, that the Work is complete and request a letter granting Final Acceptance. Within 30 days after receipt of the Design-Builder’s certification, the City will inspect the Work and will notify the Design-Builder, in writing, of Final Acceptance or of all particulars in which this inspection reveals that the Work is incomplete or Defective. The Design- Builder shall immediately take such measures as are necessary to remedy such deficiencies and allow an additional 30 days for the City to complete another inspection of the Work. Issuance of Final Acceptance by the City shall not constitute (1) a waiver of any right or remedy of the City under the Contract or Law or (2) approval of or acquiescence to any breach of this Contract. The DESIGN-BUILD GENERAL CONDITIONS PAGE 36 Design-Builder’s certification shall be preceded or accompanied by all documentation called for in this Contract, including but not limited to:
Sample 1
Final Inspection and Final Acceptance. 12.16 When Contractor considers the entire Work subject to a GMP Amendment, or an agreed-upon portion thereof, to be complete, Contractor shall certify, in writing, that portion of the Work is complete and request a letter granting Final Acceptance. Within 30 days after receipt of Contractor’s certification, Owner will inspect the Work and will notify Contractor, in writing, of Final Acceptance or of all particulars in which this inspection reveals that the Work is incomplete or Defective. Contractor shall immediately take such measures as are necessary to remedy such deficiencies and allow an additional 30 days for Owner to complete another inspection of the Work. Issuance of Final Acceptance by Owner shall not constitute (1) a waiver of any right or remedy of Owner under the Contract or Law or (2) approval of or acquiescence to any breach of this Contract. Contractor’s certification shall be preceded or accompanied by all documentation called for in this Contract, including but not limited to:
Sample 1

Related to Final Inspection and Final Acceptance

  • Inspection and Final Acceptance District may, at its discretion, inspect and accept or reject any of Consultant’s work under this Agreement, either during performance or when within sixty (60) days after submitted to District. If District does not reject work by a timely written explanation, Consultant’s work shall be deemed to have been accepted. District’s acceptance shall be conclusive as to such work except with respect to latent defects, fraud and such gross mistakes as amount to fraud. Acceptance of any of Consultant’s work by District shall not constitute a waiver of any of the provisions of this Agreement including, but not limited to indemnification and insurance provisions.

  • Inspection and Testing Each Constructing Entity shall cause inspection and testing of the Interconnection Facilities that it constructs in accordance with the provisions of this section. The Construction Parties acknowledge and agree that inspection and testing of facilities may be undertaken as facilities are completed and need not await completion of all of the facilities that a Constructing Entity is building.

  • Inspection and Tests 3.8.1 The Procuring entity or its representative shall have the right to inspect and/or to test the goods to confirm their conformity to the Contract specifications. The Procuring entity shall notify the tenderer in writing in a timely manner, of the identity of any representatives retained for these purposes.

  • Response/Compliance with Audit or Inspection Findings A. Grantee must act to ensure its and its Subcontractors’ compliance with all corrections necessary to address any finding of noncompliance with any law, regulation, audit requirement, or generally accepted accounting principle, or any other deficiency identified in any audit, review, or inspection of the Contract and the services and Deliverables provided. Any such correction will be at Grantee’s or its Subcontractor's sole expense. Whether Xxxxxxx's action corrects the noncompliance shall be solely the decision of the System Agency.

  • Final Inspection Contractor shall complete the list of items identified on the pre-final Punchlist prior to requesting a final inspection. Unless otherwise specified, or otherwise agreed in writing by the parties as documented on the Certificate of Substantial Completion, Contractor shall complete and/or correct all Work within thirty (30) days of the Substantial Completion date. Upon completion of the pre-final Punchlist work, Contractor shall give written notice to ODR and A/E that the Work will be ready for final inspection on a specific date. Contractor shall accompany this notice with a copy of the updated pre-final Punchlist indicating resolution of all items. On the date specified or as soon thereafter as is practicable, ODR, A/E and Contractor will inspect the Work. A/E will submit to Contractor a final Punchlist of open items that the inspection team requires corrected or completed before final acceptance of the Work.

  • Final Acceptance When the Project/Service or any portion thereof, as designated by the COUNTY, is ready for its intended use, the COUNTY and any other invited parties shall make an inspection of the Project/Service, to verify its completeness and develop a punch list of items needing completion or correction before final payment will be made. CONTRACTOR shall have ten (10) calendar days to correct all deficiencies. An eighty-dollar ($80.00) re-inspection fee shall be applied for the third inspection and any required re-inspection thereafter. The COUNTY shall have the right to exclude CONTRACTOR from those portions of the work designated as complete after the inspection; provided, however, that CONTRACTOR will have reasonable access for the time allotted by the COUNTY to complete or correct items on the punch list. When the work provided for under this Agreement has been completely performed by CONTRACTOR, and the final inspection has been made by the COUNTY, a final invoice will be prepared by the CONTRACTOR. The amount of this invoice, less any sums that may have been deducted or retained under the provisions of this Agreement, will be paid to CONTRACTOR in accordance with this Agreement, and after CONTRACTOR has agreed in writing to accept the balance due, as determined by the COUNTY, as full settlement of the account under the contract and of all claims in connection therewith. Occupancy by the COUNTY alone does not constitute final acceptance.

  • FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such inspection and, when he or she finds the Work acceptable under the Contract Documents and the Contract fully performed, he or she will promptly issue a final Certificate for Payment stating that to the best of his / her knowledge, information and belief, and on the basis of his or her observations and inspections, the Work has been completed in accordance with the terms and conditions of the Contract Documents and that the entire balance found to be due the Contractor, and noted in said final Certificate, is due and payable. The Architect's final Certificate for Payment will constitute a further representation that the Contractor has fulfilled the conditions entitling him or her to final payment as set forth in Subparagraph 9.9.2 of these General Conditions.

  • Equipment Testing and Inspection 2.1.1 The Interconnection Customer shall test and inspect its Small Generating Facility and Interconnection Facilities prior to interconnection. The Interconnection Customer shall notify the NYISO and the Connecting Transmission Owner of such activities no fewer than five Business Days (or as may be agreed to by the Parties) prior to such testing and inspection. Testing and inspection shall occur on a Business Day. The Connecting Transmission Owner may, at its own expense, send qualified personnel to the Small Generating Facility site to inspect the interconnection and observe the testing. The Interconnection Customer shall provide the NYISO and Connecting Transmission Owner a written test report when such testing and inspection is completed. The Small Generating Facility may not commence parallel operations if the NYISO, in consultation with the Connecting Transmission Owner, finds that the Small Generating Facility has not been installed as agreed upon or may not be operated in a safe and reliable manner.

  • INSPECTION AND ACCEPTANCE (a) LOCKHEED XXXXXX and its customer may inspect all Work at reasonable times and places, including, when practicable, during manufacture and before shipment. SELLER shall provide all information, facilities, and assistance necessary for safe and convenient inspection without additional charge.

  • Inspections and Testing Each Interconnected Entity shall perform routine inspection and testing of its facilities and equipment in accordance with Good Utility Practice as may be necessary to ensure the continued interconnection of the Customer Facility with the Transmission System in a safe and reliable manner. Each Interconnected Entity shall have the right, upon advance written notice, to request reasonable additional testing of an Interconnected Entity’s facilities for good cause, as may be in accordance with Good Utility Practice.

Time is Money Join Law Insider Premium to draft better contracts faster.