General Responsibilities of the Parties 1. The Parties will work together in a spirit of cooperation and partnership, with the responsibilities and accountabilities set out in this Agreement, to implement the Programme Documents in full in a timely, efficient, and effective, manner.
2. The Parties agree to carry out their respective responsibilities in accordance with the provisions of this Agreement, including the Programme Documents.
3. The Parties shall keep each other informed of all relevant activities pertaining to the implementation of the Programme Documents, and shall hold consultations when either Party considers it appropriate, including any circumstance that may affect the achievement of the results of the Programme and the Programme Documents.
4. The Parties shall fulfill their commitments with the fullest regard for the terms and conditions of this Agreement and the principles of the United Nations.
General Responsibilities Issuer hereby engages Distributor to act as exclusive distributor of the shares of each class of the Funds. The Funds subject to this Agreement as of the date hereof are identified on SCHEDULE A, which may be amended from time to time in accordance with Section 11 below. Sales of a Fund's shares shall be made only to investors residing in those states in which such Fund is registered. After effectiveness of each Fund’s registration statement, Distributor will hold itself available to receive, as agent for the Fund, and will receive by mail, telex, telephone, or such other method as may be agreed upon between Distributor and Issuer, orders for the purchase of Fund shares, and will accept or reject such orders on behalf of the Fund in accordance with the provisions of the applicable Fund’s prospectus. Distributor will be available to transmit orders, as promptly as possible after it accepts such orders, to the Fund’s transfer agent for processing at the shares’ net asset value next determined in accordance with the prospectuses.
Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
Contractor’s General Responsibilities The Contractor, regardless of any delegation or subcontract entered by the Contractor, shall be responsible for the following when providing information technology staff augmentation services:
3.1 The Contractor is responsible for the comprehensive management of Staff. Staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment and the Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of Staff.
3.2 The Contractor shall provide Staff in accordance with Customer Requests for Quote (RFQ), and as described in Contract Exhibit J, Job Family Descriptions document. Customers may include detailed scopes of work, specific requirements of the work to be performed, and any requirements of Staff within the Request for Quote.
3.3 The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified Staff to perform the services requested by the Customer.
3.4 The Contractor shall provide Customers with Staff who have sufficient skill and experience to perform the services assigned to them.
3.5 The Contractor is responsible for ensuring that all information technology staff augmentation services furnished under the Contract meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances.
3.6 The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s Staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market.
3.7 The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s Staff.
3.8 The Contractor, throughout the term of the Contract, shall maintain all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required for Contractor and Staff to perform the information technology staff augmentation services.
3.9 Contractor shall be responsible for all costs associated with the administration of this Contract.
3.10 The Contractor shall adhere to all work policies, procedures, and standards established by the Department and Customer.
3.11 The Contractor shall ensure that Staff conform with the Customer’s policies in all respects while on the Customer’s premises, and is responsible for obtaining all rules, regulations, policies, etc.
3.12 Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks.
Custodial Responsibilities (a) Each Custodian shall provide access to the Mortgage Loan Documents in possession of the applicable Custodian regarding the related Mortgage Loans and REO Property and the servicing thereof to the Trustee, the Certificateholders, the FDIC, and the supervisory agents and examiners of the FDIC, such access being afforded only upon reasonable prior written request and during normal business hours at the office of the applicable Custodian. Each Custodian shall allow representatives of the above entities to photocopy any of the records and documentation and shall provide equipment for that purpose at the expense of the person requesting such access.
(b) Each Custodian may resign from its obligations hereunder upon 60 days' prior written notice to the Trustee, the Depositor, the Securities Administrator and the Servicers. Such resignation shall take effect upon (i) the appointment of a successor Custodian reasonably acceptable to the Depositor within such 60 day period; and (ii) delivery of all Mortgage Loan Files to the successor Custodian. The Trustee shall have the right, but not the obligation, to become the successor Custodian. If no successor Custodian is appointed within 60 days after written notice of such Custxxxxx'x xesignation is received by the Trustee, the applicable Custxxxxx xxx petition a court of competent jurisdiction to appoint a successor Custodian. Upon such resignation and appointment of succesxxx Xxxxxdian, the applicable Custodian shall, at such Custodian's expense, xxxxxxxx transfer to the successor Custodian, as directed in writing by the Trustee, all applicable Mortgage Files being administered under this Agreement. Notwithstanding the foregoing, the Trust Fund, not the applicable Custodian, shall bear the costs relating to the transfer of Mortgage Files if such Custodian shall resign with cause (including such Custodian's resignation due to the failure of such Custodian to be paid xxx xxxx due to such Custodian hereunder).
(c) For so long as reports are required to be filed with the Commission under the Exchange Act with respect to the Trust, each Custodian shall not utilize any Subcontractor for the performance of its duties hereunder if such Subcontractor would be "participating in the servicing function" within the meaning of Item 1122 of Regulation AB without the prior written consent of the Depositor, in its sole discretion.
(d) Each Custodian shall indemnify the Depositor, the Sponsor, the Securities Administrator and any director, officer, employee, agent and affiliate of the Depositor, the Sponsor or the Securities Administrator and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses that any of them may sustain in any way related to (i) the failure of the applicable Custodian to deliver when required any assessment of compliance required to be delivered by the applicable Custodian or (ii) any material misstatement or omission contained in any assessment of compliance provided to be delivered by the applicable Custodian. This indemnity shall survive the termination of this Agreement or the earlier resignation or removal of the applicable Custodian.
(e) Notwithstanding anything in this Agreement to the contrary, no Custodian shall be required to deliver, or to cause to be delivered, an assessment of compliance or accountant's attestation report pursuant to Section 3.23 for any fiscal year of the Trust in which the Custodian's Weighted Average Percentage is 5% or less. The "Custodian's Weighted Average Percentage" means, for each fiscal year of the Trust and each Custodian, the quotient, expressed as a percentage, of (A) the aggregate of the Stated Principal Balance for each Distribution Date in such fiscal year of the Mortgage Loans for which such Custodian acted as Custodian divided by (B) the aggregate of the Pool Stated Principal Balance for each Distribution Date in such fiscal year.
Professional Responsibilities Other activities to support the delivery of the Xxxxxx Xxxxxx Business Plan and Xxxxxx Mission Strategic Plan, as requested by your manager • As an employee, be responsible under the Work Health & Safety Act for the health and safety of all persons they come into contact with, during employment • All hazards and injuries must be reported through the normal process as set out in Xxxxxx Mission’s Work Health, Safety and Rehabilitation Quality Management System and site procedures • Participate in the review and maintenance of industry specific and internal audit processes, as per Xxxxxx Mission’s standard policy and procedures • In relation to Xxxxxx Mission and the Uniting Church in Australia, attend such functions, meetings, seminars, training courses as directed by your supervisor • In relation to Xxxxxx Mission attend worship services as encouraged by your supervisor • Participate on a quarterly basis in Xxxxxx Mission’s Employee contribution and development process • Take responsibility for personal career development and training • Participate in Xxxxxx Mission’s Orientation program, so as to gain an understanding of, and • promote, the application of the EEO, Affirmative Action, Privacy Act, Work Health & Safety Act and other relevant legislation • Administer Xxxxxx Mission’s philosophy of care and other relevant policy documents as appropriate • Demonstrate responsible stewardship of all resources, and willingness to report impropriety in keeping with the values of Xxxxxx Mission • Ensure the reputation and integrity of Xxxxxx Mission is maintained at all times • Maintain confidentiality
Mutual Responsibilities It is recognized by this Agreement to be the duty of the Company to explain fully the terms of this Agreement to all its officers, foremen and others engaged in a supervisory capacity and it is recognized to be the duty of the Union to explain fully to its members, its and their responsibilities and obligations under this Agreement.
Financial Responsibilities The acceptance of a Project Agreement creates a legal duty on the part of the Grantee’s organization to use the funds made available in accordance with the terms and conditions of the Grant. Note: Authority cited: Sections 5001.5 and 5003, Public Resources Code. Reference: Sections 5090.32 and 5090.50, Public Resources Code.
Joint Responsibilities The relationship between SAE ITC, the Activities and its Members shall be, and at all times, advisory only, and no party shall have the authority to enter into any contract or commitment in the name of, or on behalf of, any other party. Nothing in this Agreement shall be construed to confer upon either party the status of employee, agent, partner, joint venturer or legal representative of the other, it being intended by all parties to remain independent legal entities solely responsible for its own actions.
Board of Trustees’ Responsibilities 5.2.1 The Board of Trustees will be responsible for the operational and financial sustainability of the Trust, including:
a) Validation of the sustainability of the respective Plan Design;
