Improvements by the Airline Sample Clauses

Improvements by the Airline. 10.09.1 The Airline may construct and install, consistent with the terms and provisions of this Agreement and at its sole expense, Airline Operating Facilities and improvements in its Exclusive, Preferential, and if any, Joint Use Premises as the Airline deems to be necessary for its operations; provided, however, that the plans and specifications, location, and construction schedule for such Airline Operating Facilities and improvements must be approved by the Authority in writing prior to the commencement of any and all such construction or installation. No reduction or abatement of rentals, fees, and charges due to the Authority hereunder shall be allowed for any interference by such construction with the Airline's operations hereunder. 10.09.2 Prior to the commencement of construction of any such Airline Operating Facilities and improvements, the Airline shall obtain or cause to be obtained a contract surety bond in a sum equal to the full amount of any construction contract. Said bond shall (i) be drawn in a form and from such company reasonably acceptable to the Authority; (ii) shall guarantee the faithful performance of necessary construction and completion of improvements in accordance with the Authority's approved final plans and detailed specifications; and, (iii) shall protect the Authority against any losses and liability, damages, expenses, claims, liens, and judgments caused by or resulting from the failure to perform completely the work described. The Airline shall further acquire, or cause to be acquired, a payment bond with any contractor or contractors of the Airline as principal, in a sum equal to the full amount of the construction contract awarded by the Airline for the improvements and shall require its contractor to acquire similar bond from its subcontractors. Said bond shall guarantee payment of all wages for labor and services engaged, and of all bills for materials, supplies and equipment used in the performance of said construction contract. The Airline shall assure that any work associated with such construction or installation shall not unreasonably interfere with the operation of the Airports, or otherwise unreasonably interfere with the permitted activities of other Airport tenants and users. The Airline shall within five (5) working days discharge any lien filed against its property or Premises by posting a bond or other adequate security. 10.09.3 The Airline shall require contractors to furnish satisfactory evidence of sta...
AutoNDA by SimpleDocs
Improvements by the Airline. ‌ 10.09.1 The Airline may construct and install, consistent with the terms and provisions of this Agreement and at its sole expense, Airline Operating Facilities and improvements in its Exclusive, Preferential, and if any, Joint Use Premises as the Airline deems to be necessary for its operations; provided, however, that the plans and specifications, location, and construction schedule for such Airline Operating Facilities and improvements must be approved by the Authority in writing prior to the commencement of any and all such construction or installation. No reduction or abatement of rentals, fees, and charges due to the Authority hereunder shall be allowed for any interference by such construction with the Airline's operations hereunder. 10.09.2 Prior to the commencement of construction of any such Airline Operating Facilities and improvements, the Airline shall obtain or cause to be obtained a contract surety bond in a sum equal to the full amount of any construction contract. Said bond shall (i) be drawn in a form and from such company reasonably acceptable to the Authority; (ii) shall guarantee the faithful performance of necessary construction and completion of improvements in accordance with the

Related to Improvements by the Airline

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

  • Condition of the Contractor’s Property or Equipment The Contractor shall make the Property and/or equipment available to the Judicial Council, pursuant to the terms and conditions set forth in this Agreement. The Contractor shall immediately remedy any problem with the Property’s physical plant or equipment that impairs or diminishes the quality of the Program. The Contractor shall ensure the appropriate hot water, heating, and ventilation is provided at the Property during the Program, inclusive in the prices set forth herein.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!