Interference with Tests on Completion Sample Clauses
The 'Interference with Tests on Completion' clause defines the rules and consequences when one party disrupts or prevents the proper execution of completion tests for a project or deliverable. Typically, this clause outlines what constitutes interference, such as obstructing access to the site, withholding necessary information, or otherwise impeding the testing process. It may specify that if interference occurs, the affected party is entitled to an extension of time or compensation for delays. The core function of this clause is to ensure that completion tests can be conducted fairly and without obstruction, thereby protecting the integrity of the testing process and providing remedies if interference occurs.
POPULAR SAMPLE Copied 4 times
Interference with Tests on Completion. If the Contractor is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer is responsible, the Employer shall be deemed to have taken over the Works or Section (as the case may be) on the date when the Tests on Completion would otherwise have been completed. The Engineer shall then issue a Taking-Over Certificate accordingly, and the Contractor shall carry out the Tests on Completion as soon as practicable, before the expiry date of the Defects Notification Period. The Engineer shall require the Test on Completion to be carried out by giving 14 days’ notice and in accordance with the relevant provisions of the Contract. If the Contractor suffers delay and /or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor’s Claims] to: an extension of time for any such delay, if completion is our will be delayed, under Sub-Clause 8.4 [Extension of Time for Completion], and payment of any such Cost plus reasonable profit, which shall be included in the Contract Price. After receiving this notice, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine these matters.
Interference with Tests on Completion. In the first paragraph, second line, after the word “responsible”, substitute the remainder of the sentence with the words “the Works shall be regarded as suspended.” Delete the first sentence of the second paragraph. Delete the third and fourth paragraphs including sub-paragraphs (a) and (b).
Interference with Tests on Completion. If the Contractor suffers delay or is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer is responsible and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer and shall be entitled subject to clause 20 [Claims and Disputes] to:
(a) an extension of time for any such delay, if completion is or will be delayed, under sub-clause 8.4 [Extension of Time for Completion]; and
(b) payment of any such Cost plus Profit, which shall be included in the Contract Price. After receiving this notice, the Engineer shall proceed in accordance with sub-clause 3.5 [Determinations] to agree or determine these matters.
Interference with Tests on Completion. If the Contractor is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Contract Awarder is responsible, the Contractor shall carry out the Tests on Completion as soon as practicable. If the Contractor suffers delay and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Contract Awarder and shall be entitled subject to Sub-Clause 20.1 [Contractor's Claims] to:
(a) an extension of time for any such delay, if completion is or will be delayed, under SubClause 8.4 [Extension of Time for Completion], and
(b) payment of any such Cost plus reasonable profit, which shall be added to the Contract Price. After receiving this notice, the Contract Awarder shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine these matters.
Interference with Tests on Completion. If the Contractor suffers delay or is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer is responsible and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer and shall be entitled subject to clause 20 [Claims, Disputes and Arbitration] to:
Interference with Tests on Completion certified bears to the value of the Works or Section (as the case may be) as a whole. The Engineer shall proceed in accordance with Sub- Clause 3.5 [Determinations] to agree or determine these proportions. The provisions of this paragraph shall only apply to the daily rate of delay damages under Sub-Clause 8.7 [Delay Damages], and shall not affect the maximum amount of these damages. If the Contractor is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer is responsible, the Employer shall be deemed to have taken over the Works or Section (as the case may be) on the date when the Tests on Completion would otherwise have been completed. The Engineer shall then issue a Taking-Over Certificate accordingly, and the Contractor shall carry out the Tests on Completion as soon as practicable, before the expiry date of the Defects Notification Period. The Engineer shall require the Tests on Completion to be carried out by giving 14 days’ notice and in accordance with the relevant provisions of the Contract. If the Contractor suffers delay and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor’s Claims] to:
(a) an extension of time for any such delay, if completion is or will be delayed, under Sub- Clause 8.4 [Extension of Time for Completion], and
(b) Payment of any such Cost plus profit, which shall be included in the Contract Price. After receiving this notice, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine these matters.
Interference with Tests on Completion. If the Contractor is prevented, for more than fourteen (14) days, from carrying out the Tests on Completion by a cause for which the Employer is responsible, the Contractor shall carry out the Tests on Completion as soon as practicable.
Interference with Tests on Completion. In Sub-Clause 10.3, delete the first and second paragraphs. Add the following after Sub-Clause 10.4:
Interference with Tests on Completion. If the Contractor is prevented, for more than 14 (Fourteen) days, from carrying out the Tests on Completion by a cause for which the Employer/s is/are responsible, the Contractor shall carry out the Tests on Completion as soon as practicable. If the Contractor suffers delay and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Employer/s and the financial institution providing the funding for the Project/s and shall be entitled, subject to Sub-Clause
25.1 [Contractor's Claims] to:
(a) an extension of time for any such delay, if completion is or will be delayed, under Sub-Clause 8.4 [Extension of Time for Completion], and
(b) payment of any such Cost-plus reasonable profit, which shall be added to the Contract Price, upon notice to the financial institution providing the funding for the Project/s. After receiving this notice, the Employer/s shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine these matters.