Consultant Consultant agrees to indemnify, defend, and shall hold harmless Client, its directors, employees and agents, and defend any action brought against same with respect to any claim, demand, cause of action, debt or liability, including reasonable attorneys' fees, to the extent that such an action arises out of the gross negligence or willful misconduct of Consultant.
Employment of Consultant CONSULTANT will perform as an independent contractor all services under this Contract to the prevailing professional standards consistent with the level of care and skill ordinarily exercised by members of its profession, both public and private, currently practicing in the same locality under similar conditions, including reasonable, informed judgments and prompt, timely action. If CONSULTANT is representing that it has special expertise in one or more areas to be utilized in this Contract, then CONSULTANT agrees to perform those special expertise services to the appropriate local, regional or national professional standards.
Engagement of Consultant The Company hereby engages Consultant to ------------------------- assist the Company in programming services.
Labor Management Labor/management meetings will be held at the request of either party as needed/monthly.
Compensation for Consulting Services For each quarter (i.e., three-month period) that Executive provides consulting services to MediciNova pursuant to the option of MediciNova contained in Section 9 above, MediciNova shall pay Executive a sum equal to fifteen percent (15%) of Executive’s annual Base Compensation which shall be applicable at the time of Executive’s termination of employment with MediciNova (prorated for any period of less than a quarter). The parties expressly agree that when Executive is performing consulting services for MediciNova, Executive is acting as an independent contractor. Therefore, Executive shall be solely liable for Social Security and income taxes that result from Executive’s compensation as a consultant. In addition, Executive shall not be entitled to any other benefits including, without limitation, such group medical, life and disability insurance and other benefits as may be provided to employees and/or executives of MediciNova.
Labor-Management Cooperation When an Appointing Authority initiates a planning process or management study which is anticipated to result in layoff, the Appointing Authority will meet and confer with the Local Union during the decision planning phase and again during the implementation planning phase. The Appointing Authority and the Local Union shall enter into negotiations regarding a Memoranda of Understanding upon request of either party to modify this Agreement regarding the implementation plans which shall include, but are not limited to, the following: • Length of layoff notice; • Job and retraining opportunities; • Alternative placement methods; • Early retirement options pursuant to M.S. 43A.24, Subd. 2(i); • Bumping/vacancy options for part-time employees to preserve their insurance eligibility or contribution; and • Other methods of mitigating layoff or their effect on employees.
Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows:
(a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge.
(b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request.
(c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor.
(d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.
Employment of Consultants Part A General Consultants’ services shall be procured in accordance with the provisions of the Introduction and Section IV of the "Guidelines: Selection and Employment of Consultants by World Bank Borrowers" published by the Bank in January 1997 and revised in September 1997 (the Consultant Guidelines) and the following provisions of Section II of this Schedule. Part B: Quality- and Cost-based Selection Except as otherwise provided in Part C of this Section, consultants’ services shall be procured under contracts awarded in accordance with the provisions of Section II of the Consultant Guidelines, paragraph 3 of Appendix 1 thereto, Appendix 2 thereto, and the provisions of paragraphs 3.13 through 3.18 thereof applicable to quality- and cost-based selection of consultants. Part C: Other Procedures for the Selection of Consultants
1. Selection Based on Consultants Qualifications Services estimated to cost less than $100,000 equivalent per contract may be procured under contracts awarded in accordance with the provisions of paragraphs 3.1 and 3.7 of the Consultant Guidelines.
Labor Cooperation The Parties shall enhance their communication and cooperation on labor, social security and environment issues through Memorandum of Understanding on Labor Cooperation between the Government of the People's Republic of China and the Government of the Republic of Peru.
TRAINING AND EMPLOYEE DEVELOPMENT 9.1 The Employer and the Union recognize the value and benefit of education and training designed to enhance an employee’s ability to perform their job duties. Training and employee development opportunities will be provided to employees in accordance with Employer policies and available resources.
9.2 Attendance at employer-required training will be considered time worked. The Employer will make reasonable attempts to schedule employer-required training during an employee’s regular work shift. The Employer will pay the registration and associated travel costs in accordance with Article 23, Travel, for employer-required training.
