Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows:
(a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge.
(b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request.
(c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor.
(d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.
CONTRACTOR OBLIGATION Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records provided to Enterprise Services that Contractor believes are statutorily exempt from disclosure and identify the precise statutory basis for exemption from disclosure. In addition, if, in Contractor’s judgment, certain portions of such records are not statutorily exempt from disclosure but are sensitive because particular portions of Contractor’s records (NOT including pricing) include highly confidential, proprietary, or trade secret information (or the equivalent) that Contractor protects through the regular use of confidentiality or similar agreements and routine enforcements through court enforcement actions, Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records that include such sensitive information.
Contractor Obligations After receipt of the Notice of Termination and except as otherwise directed by the State, the Contractor shall immediately proceed to:
a. To the extent specified in the Notice of Termination, stop work under the Contract on the date specified.
b. Place no further orders or subcontracts for materials, services, and/or facilities except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated.
c. Terminate and cancel any orders or subcontracts for related to the services, except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated.
d. Transfer to the State all completed or partially completed plans, drawings, information, and other property which, if the Contract had been completed, would be required to be furnished to the State.
e. Take other action as may be necessary or as directed by the State for the protection and preservation of the property related to the contract which is in the possession of the contractor and in which the State has or may acquire any interest.
f. Make available to the State all cost and other records relevant to a determination of an equitable settlement.
Administrative Civil Liability The Settling Respondent hereby agrees to the imposition of an administrative civil liability of $368,940 to resolve the alleged violation set forth in section II as follows:
a. No later than 30 days after the Regional Water Board or its delegate signs this Stipulated Order, the Settling Respondent shall mail a check for State Water Resources Control Board Accounting Office Attn: ACL Payment P.O. Box 1888 Sacramento, CA 95812-1888 The Settling Respondent shall email a copy of the check to the State Water Board, Office of Enforcement (xxx.xxxxxx@xxxxxxxxxxx.xx.xxx), and to the Regional Water Board (xxxxx.xxxxx@xxxxxxxxxxx.xx.xxx).
b. The Parties agree that the remaining $184,470 of the administrative liability shall be paid to the Regional Monitoring Program, care of the San Francisco Estuary Institute (SFEI), for implementation of a supplemental environmental project (SEP) named “High-Speed Mapping of Water Quality Parameters on the Eastern Shoal of South San Francisco Bay” as follows:
i. $184,470 (SEP Amount) shall be paid in the manner described in section III, paragraph 1.b.ii, solely for use toward the SEP. Funding this project will result in high-speed mapping of water quality parameters covering the eastern shoals of South San Francisco Bay monthly over the course of four months. A complete description of the SEP is provided in Attachment B, incorporated herein by reference.
ii. No later than 30 days after the Regional Water Board or its delegate signs this Stipulated Order, the Settling Respondent shall mail a check for $184,470, made payable to “Regional Monitoring Program,” referencing the Order number on page one of this Stipulated Order, to: Regional Monitoring Program c/o San Francisco Estuary Institute 0000 Xxxxxxx Xxxxxx Richmond, CA 94804 The Settling Respondent shall email a copy of the check to the State Water Board, Office of Enforcement (xxx.xxxxxx@xxxxxxxxxxx.xx.xxx), and to the Regional Water Board (xxxxx.xxxxx@xxxxxxxxxxx.xx.xxx).
Company Obligations The Company agrees:
(a) that until such time as Remus Capital no longer meets the Remus Minimum Ownership Threshold, and provided that the Remus Independent Nominee is able and willing to continue to serve on the Board, the Company will include each applicable Remus Independent Nominee in the Company’s slate of director nominees to stand for election to the Board at any meeting of Company stockholders at which directors are to be elected;
(b) that until such time as Xxxxxxxx Xxxx no longer meets the Gaur Minimum Ownership Threshold, and provided that the Gaur Independent Nominee is able and willing to continue to serve on the Board, the Company will include each applicable Gaur Independent Nominee in the Company’s slate of director nominees to stand for election to the Board at any meeting of Company stockholders at which directors are to be elected;
(c) that until such time as RTW no longer meets the RTW Designation Condition, and provided that the RTW Designated Director is able and willing to continue to serve on the Board, the Company will include each applicable RTW Designated Director as a Company Independent Nominee in the Company’s slate of director nominees to stand for election to the Board at any meeting of Company stockholders at which directors are to be elected;
(d) to recommend, support and solicit proxies for each such Gaur Independent Nominee, Remus Independent Nominee or RTW Designated Director as a Company Independent Nominee, in each such case, in substantially the same manner as it recommends, supports and solicits proxies for any other members of such slate of director nominees;
(e) to cause to be nominated a lead Independent Director (the “Lead INED”) of the Board, who shall serve at all times as chair or co-chair of the Board, and who initially shall be Xxxx Xxxxxx. The Company shall cause the Lead INED to be nominated as the Sponsor Nominee; and
(f) from time to time and at all times on or prior to the second (2nd) anniversary of the Closings (as defined in the Business Combination Agreement), to cause Xxxx Xxxxxx to be the Lead INED; provided, that, at the time when such annual or special meeting of stockholders at which an election of directors is held or at the time when such written consent of the stockholders to elect one or more directors is entered into, Xxxx Xxxxxx (i) has not refused and continues to refuse to stand for re-election, (ii) is not unable to discharge the duties of the Lead INED due to death or incapacity or (iii) is not ineligible to serve as the Lead INED.
Entities that Discriminate Against Firearm and Ammunition Industries In accordance with Senate Bill 19, Acts 2021, 87th Leg., R.S., pursuant to Section 2274.002 of the Texas Government Code (relating to prohibition on contracts with companies that discriminate against firearm and ammunition industries), Contractor verifies that: (1) it does not, and will not for the duration of the Contract, have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association or (2) the verification required by Section 2274.002 of the Texas Government Code does not apply to the Contract. If circumstances relevant to this provision change during the course of the Contract, Contractor shall promptly notify System Agency.
Civil Liability If an action or proceeding is brought against any employee or former employee covered by this Agreement for an alleged tort committed by him in the performance of his duties, then:
Limited Obligation or Liability In exercising remedies, whether as a secured creditor or otherwise, no Senior Priority Agent shall have any obligation or liability to any Junior Priority Secured Party, or (except as may be separately agreed in writing by and between or among any applicable Senior Priority Agents, in each case on behalf of itself and the Senior Priority Creditors represented thereby) to any other Senior Priority Secured Party, in each case regarding the adequacy of any Proceeds or for any action or omission, save and except solely for an action or omission that breaches the express obligations undertaken by such Senior Priority Agent under the terms of this Agreement. In exercising remedies, whether as a secured creditor or otherwise, no Junior Priority Agent shall have any obligation or liability (except as may be separately agreed in writing by and between or among any applicable Junior Priority Agents, in each case on behalf of itself and the Junior Priority Creditors represented thereby) to any other Junior Priority Secured Party, in each case regarding the adequacy of any Proceeds or for any action or omission, save and except solely for an action or omission that breaches the express obligations undertaken by such Junior Priority Agent under the terms of this Agreement.
Indemnity Obligations (a) Parent shall indemnify and hold harmless SpinCo from and against, and will reimburse SpinCo for, (i) all liability for Taxes allocated to Parent pursuant to Article II, (ii) all Tax Related Costs and Expenses allocated to Parent pursuant to Section 6.7, (iii) all Taxes, Tax Related Costs and Expenses and Tax Related Losses (without duplication) to the extent arising out of, based upon, or relating or attributable to any breach of or inaccuracy in, or failure to perform, as applicable, any representation, covenant or obligation of any member of the Parent Group pursuant to this Agreement and (iv) the amount of any Refund received by any member of the Parent Group that is allocated to SpinCo pursuant to Section 2.5(a).
(b) Without regard to whether a Post-Distribution Ruling or an Unqualified Tax Opinion may have been provided or whether any action is permitted or consented to hereunder and notwithstanding anything to the contrary in this Agreement, SpinCo shall indemnify and hold harmless Parent from and against, and will reimburse Parent for, (i) all liability for Taxes allocated to SpinCo pursuant to Article II, (ii) all Tax Related Costs and Expenses allocated to SpinCo pursuant to Section 6.7, (iii) all liability for Taxes, Tax Related Costs and Expenses and Tax Related Losses (without duplication) arising out of, based upon, or relating or attributable to any breach of or inaccuracy in, or failure to perform, as applicable, any representation, covenant or obligation of any member of the SpinCo Group pursuant to this Agreement, (iv) the amount of any Refund received by any member of the SpinCo Group that is allocated to Parent pursuant to Section 2.5(a) and (v) any Distribution Taxes and Tax Related Losses attributable to a Prohibited Act, or otherwise attributable to a SpinCo Disqualifying Action (regardless of whether the conditions set forth in Section 4.2(c) are satisfied). To the extent that any Tax, Tax Related Costs and Expenses or Tax Related Loss is subject to indemnity pursuant to both Section 5.1(a) and Section 5.1(b), responsibility for such Tax, Tax Related Costs and Expenses or Tax Related Loss shall be shared by Parent and SpinCo according to relative fault as determined by Parent in its sole and absolute discretion. The amount of any liability for Taxes which are indemnifiable pursuant to this Section 5.1(b)(iii) and (v) shall be determined, in Parent’s sole and absolute discretion, without regard to any Tax Attributes of the Parent Group or the Parent Business.
Liability Protection Whenever an action or proceeding for damages is filed against any Bargaining Unit employee arising from his/her act or omission while performing his/her official duties, such employee(s) may request that the Attorney General defend the action or proceeding at the expense of the state. If the Attorney General determines that the employee was acting in good faith and within the course of his or her official duties, the Attorney General will defend the employee. If the body presiding over the action determines that the employee was acting within the scope of his or her official duties and enters a judgment against the employee, the judgment will be satisfied by the state.
