Determination of Market Rent If Tenant timely and appropriately objects to the Market Rent in Tenant’s Acceptance, Landlord and Tenant shall attempt to agree upon the Market Rent using their best good-faith efforts. If Landlord and Tenant fail to reach agreement within twenty-one (21) days following Tenant’s Acceptance (“Outside Agreement Date”), then each party shall make a separate determination of the Market Rent which shall be submitted to each other and to arbitration in accordance with the following items (i) through (vii):
Landlord’s Election If Tenant desires to assign its interest under the Lease or to sublet all or part of the Leased Premises (a “Proposed Transfer”), Tenant must first notify Landlord, in writing, of such Proposed Transfer, at least fifteen (15) business days in advance of the date it intends to close the Proposed Transfer, specifying (a) the size of the space to be so transferred, (b) the duration of the term of such Proposed Transfer and (c) the terms of the Proposed Transfer, including the name of the proposed assignee or sublessee, the proposed assignee’s or sublessee’s intended use of the Leased Premises, current financial statements (including a balance sheet, income statement and statement of cash flow, all prepared in accordance with generally accepted accounting principles) of such proposed assignee or sublessee, the form of documents to be used in effectuating such assignment or subletting and such other information as Landlord may reasonably request. Landlord shall have a period of fifteen (15) business days following receipt of such notice and the required information to consent or decline to consent to the Proposed Transfer. If Landlord does not respond within such fifteen (15) business day period, Landlord shall be deemed to have approved the Proposed Transfer. If Landlord declines to consent to the Proposed Transfer, Landlord shall notify Tenant in writing, specifying the reasons under this Lease that such refusal is justified. During such fifteen (15) business day period, Tenant covenants and agrees to supply to Landlord, promptly upon request, all necessary or relevant information which Landlord may reasonably request respecting such proposed assignment or subletting and/or the proposed assignee or sublessee.
LANDLORD’S NONLIABILITY Landlord, its agents, and any and all affiliates of Landlord, shall not be liable to Tenant, its employees, agents and/or invitees, and Tenant hereby waives all claims against Landlord, its agents, and any and all affiliates of Landlord, for and knowingly assumes the risk of loss of or damage to any property, or loss or interruption of business or income, or any other loss, cost, damage, injury or liability whatsoever (including without limitation any consequential damages and lost profit or opportunity costs), resulting from, but not limited to, Acts of God, acts of civil disobedience or insurrection, acts or omissions of third parties and/or of other tenants within the Project or their agents, employees, contractors, guests or invitees, fire, explosion, falling plaster, steam, gas, electricity, water or rain which may leak or flow from or into any part of the Premises, mold, or from the breakage, leakage, obstruction or other defects of the pipes, sprinklers, wires, appliances, plumbing, air conditioning, electrical works, roof, windows or other fixtures in the Building (whether the damage or injury results from conditions arising in the Premises or in other portions of the Building), regardless of the negligence of Landlord, its agents or any and all affiliates of Landlord in connection with any of the foregoing. It is understood that any such condition may require the temporary evacuation or closure of all or a portion of the Building. Landlord shall have no liability whatsoever (including without limitation consequential damages and lost profit or opportunity costs) and, except as provided in Sections 11.1 and 12.1 below, there shall be no abatement of rent, by reason of any injury to or interference with Tenant’s business arising from the making of any repairs, alterations or improvements to any portion of the Building, including repairs to the Premises, nor shall any related activity by Landlord constitute an actual or constructive eviction. In making repairs, alterations or improvements, however, Landlord shall interfere as little as reasonably practicable with the conduct of Tenant’s business in the Premises. Should Tenant elect to receive any service or products from a concessionaire, licensee or third party tenant of Landlord, Landlord shall have no liability for any services or products so provided or for any breach of contract by such third party provider. Neither Landlord nor its agents shall be liable for interference with light or other similar intangible interests. Tenant shall immediately notify Landlord in case of fire or accident in the Premises, the Building or the Project and of defects in any improvements or equipment.
Landlord’s Expenses In the event Tenant shall assign this Lease or sublet the Premises or request the consent of Landlord to any Transfer, then Tenant shall pay Landlord's reasonable costs and expenses incurred in connection therewith, including, but not limited to, attorneys', architects', accountants', engineers' or other consultants' fees.
Net Rent It is the intent of the Landlord and Tenant that this Lease shall yield, net to Landlord, the Base Rent specified and all Additional Rent and charges in each month during the term of the Lease, and that all costs, expenses and obligations of every kind relating to the Leased Premises shall be paid by the Tenant, unless expressly assumed by the Landlord.
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Landlord Repairs Notwithstanding anything contrary herein, Landlord shall repair, replace and restore the foundation, exterior and interior load-bearing walls, roof structure and roof covering and tuckpointing of the Property; provided, however, that (i) all costs and expenses so incurred by Landlord to repair, replace and restore the above items shall constitute Operating Expenses; provided, however, that with respect to any costs incurred in the replacement context, those costs shall not constitute an Operating Expense except to the extent that such costs so qualify under SECTION 3.1.1(vii); and (ii) notwithstanding (i) above, in the event that any such repair, replacement or restoration is necessitated by any or all of the matters set forth in SECTIONS 13.1(a) through (d) above (collectively, "TENANT NECESSITATED REPAIRS"), then Tenant shall be required to reimburse Landlord for all costs and expenses that Landlord incurs in order to perform such Tenant Necessitated Repairs, and such reimbursement shall be paid, in full, within 10 days after Landlord's delivery of demand therefor. Landlord agrees to commence the repairs, replacements or restoration described in this SECTION 13.2 within a reasonable period of time after receiving from Tenant written notice of the need for such repairs.
Fair Market Rent In the event that it becomes necessary to determine the Fair Market Rent of any Facility for any purpose of this Master Lease, and the parties cannot agree among themselves on such Fair Market Rent within twenty (20) days after the first request made by one of the parties to do so, then either party may notify the other of a person selected to act as appraiser (such person, and each other person selected as provided herein, an “Appraiser”) on its behalf. Within fifteen (15) days after receipt of any such Notice, the other party shall by notice to the first party appoint a second person as Appraiser on its behalf. The Appraisers thus appointed, each of whom must be a member of The Appraisal Institute/American Institute of Real Estate Appraisers (or any successor organization thereto, or, if no such organization exists, a similarly nationally recognized real estate appraisal organization) with at least ten (10) years of experience appraising properties similar to the Facilities, shall, within forty-five (45) days after the date of the notice appointing the first appraiser, proceed to appraise the applicable Facility to determine the Fair Market Rent thereof as of the relevant date; provided, that if one Appraiser shall have been so appointed, or if two Appraisers shall have been so appointed but only one such Appraiser shall have made such determination within fifty (50) days after the making of the initial appointment, then the determination of such Appraiser shall be final and binding upon the parties. If two (2) Appraisers shall have been appointed and shall have made their determinations within the respective requisite periods set forth above and if the difference between the amounts so determined shall not exceed ten percent (10%) of the lesser of such amounts, then the Fair Market Rent shall be an amount equal to fifty percent (50%) of the sum of the amounts so determined. If the difference between the amounts so determined shall exceed ten percent (10%) of the lesser of such amounts, either party may request the appointment of Experts pursuant to Article XXXIV.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Common Area Operating Expenses Lessee shall pay to Lessor during the term hereof, in addition to the Base Rent, Lessee's Share (as specified in Paragraph 1.6(b)) of all Common Area Operating Expenses, as hereinafter defined, during each calendar year of the term of this Lease, in accordance with the following provisions:
