Extension Term The Term of this Lease of all of the Premises may be extended for the Extension Term by unconditional written notice from Tenant to Landlord at least nine (9) (but not more than twelve (12)) months before the end of the Initial Term, time being of the essence. If Tenant does not timely exercise this option, or if on the date of such notice or at the beginning of the Extension Term (i) a default by Tenant exists, or (ii) Tenant is not leasing one hundred percent (100%) of the Premises, or (iii) Tenant has made any Transfer under Article 13 (other than a Related Party Transfer), at Landlord’s option upon written notice to Tenant, Tenant’s right to extend the Term of this Lease shall irrevocably lapse and be void and of no further force and effect, Tenant shall have no further right to extend, and this Lease shall expire at the end of the Initial Term. If Tenant fails to timely exercise its rights hereunder, then within seven (7) days of Landlord’s request therefor, Tenant shall execute and deliver to Landlord a certification, in recordable form, confirming the Tenant’s failure to exercise (or waiver of) such right, and Tenant’s failure to so execute and deliver such certification shall (without limiting Landlord’s remedies on account thereof) entitle Landlord to execute and deliver to any third party, and record, an affidavit confirming the failure or waiver, which affidavit shall be binding on Tenant and may be conclusively relied on by third parties. All references to the Term shall mean the [Initial] Term as it may be extended by the Extension Term. The Extension Term shall be on all the same terms and conditions except that the Base Rent for the Extension Term shall be as set forth below.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Extended Term Tenant shall have the option to extend the Term for two (2) consecutive five (5) year periods (the "FIRST EXTENDED TERM" and "SECOND EXTENDED TERM", respectively) on all the terms and conditions contained in this Lease including, without limitation, continuation of the adjustment of the Base Rent on an annual basis as provided in Section 3.3 below (provided only that upon commencement of the First Extended Term the only remaining option to extend the Term shall be the Second Extended Term and upon exercise of the option with respect to the Second Extended Term, no further right to extend the Term shall exist). Tenant shall deliver, if at all, written notice of its exercise of the option ("OPTION NOTICE") to Landlord at least six (6) months but not more than one (1) year before the expiration of the Term or First Extended Term, as the case may be. In the event Tenant fails to deliver the applicable Option Notice within the time allowed, Landlord shall deliver written notice to Tenant of Tenant's failure to deliver the Option Notice, and Tenant shall then have thirty (30) days from receipt of such notice within which to deliver the Option Notice, if at all, to Landlord. In the event (and only in the event) that, Tenant fails to deliver an Option Notice to Landlord within such thirty (30) days, Tenant shall be considered to have elected not to extend the Term of this Lease and thereafter, Tenant shall have no further right to extend the Term of this Lease. References in this Lease to the "Term" shall include the initial Term of fifteen (15) years and shall, in addition, include the First Extended Term and the Second Extended Term, if applicable.
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans; the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Term Commencement Date A. The date that Sublandlord delivers possession of the Additional Subleased Premises to Subtenant shall be the “Delivery Date.” It is presently anticipated, but not guaranteed, that Sublandlord will deliver possession of the Additional Subleased Premises to Subtenant on or before July 18, 2015 (the “Estimated Delivery Date”). Sublandlord agrees to use commercially reasonable efforts to obtain timely possession of the Additional Subleased Premises from the current occupant. If delivery of possession is delayed or does not otherwise occur by the Estimated Delivery Date, this Second Amendment shall not be void or voidable (except as set forth below), nor shall Sublandlord be liable to Subtenant for any loss or damage resulting therefrom. Notwithstanding anything to the contrary set forth in this Second Amendment, in the event Sublandlord is unable to deliver the Additional Subleased Premises to Subtenant by January 1, 2016, Subtenant shall have the right to terminate this Second Amendment by providing Sublandlord with written notice within ten (10) business days of such date.
B. Commencing on the Delivery Date and continuing thereafter until the Additional Subleased Premises Commencement Date (as defined below), Subtenant may access the Additional Subleased Premises solely for the purpose of preparing the Additional Subleased Premises for Subtenant’s occupancy (including the installation of telecommunications wiring, cabling and furniture), without the payment of Base Rent or Additional Rent, provided that all other provisions of the Sublease shall be in full force and effect.
C. Subject to the provisions of Section 4.A above, the Term of the Sublease for the Additional Subleased Premises (“Additional Subleased Premises Term”) shall commence on the earlier of (i) forty-five (45) days following the Delivery Date, or (ii) the date that Subtenant commences business operations from the Additional Subleased Premises (the “Additional Subleased Premises Commencement Date”). The Additional Subleased Premises Term shall expire simultaneously with the expiration of the Term for the Original Subleased Premises under the Original Sublease.
D. Following the Additional Subleased Premises Commencement Date, Sublandlord may prepare and deliver to Subtenant a commencement letter in the form of Exhibit B attached hereto (the “Commencement Letter”), confirming the Additional Subleased Premises Commencement Date, the Base Rent payable for the Additional Subleased Premises Term and certain other sublease terms with respect to the Additional Subleased Premises. Subtenant shall acknowledge and confirm the Additional Subleased Premises Commencement Date and other sublease terms by executing a copy of the Commencement Letter and returning it to Sublandlord within ten (10) business days after Subtenant’s receipt of the Commencement Letter. If Subtenant fails to sign and return the Commencement Letter to Sublandlord within such ten (10) business day period, the Commencement Letter as sent by Sublandlord shall be deemed to have correctly set forth the Additional Subleased Premises Commencement Date and the other matters addressed in the Commencement Letter. Sublandlord’s failure to send the Commencement Letter shall have no effect on the Additional Subleased Premises Commencement Date.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
