Lessor's Failure to Achieve the Lease Effective Date Sample Clauses

Lessor's Failure to Achieve the Lease Effective Date. (a) If the Lease Effective Date has not occurred by the Required Lease Effective Date due to the acts or omissions of Lessor (including the failure of Lessor to satisfy its conditions precedent to the Lease Effective Date set forth in Schedule 5.1) or the failure of Lessor to perform any of its obligations under this Facility Lease or any other Lease Document to which it is a party, then within ninety (90) days after the Required Lease Effective Date, Lessee may deliver to Lessor written notice that Lessee has elected to terminate this Facility Lease (the "Lessee Termination Notice") or to continue this Facility Lease (the "Lessee Continuation Notice").
Sample 1Sample 2
AutoNDA by SimpleDocs
Lessor's Failure to Achieve the Lease Effective Date. (a) If the Lease Effective Date has not occurred by the Required Lease Effective Date due to the acts or omissions of Lessor (including the failure of Lessor to satisfy its conditions precedent to the Lease Effective Date set forth in Schedule 5.1) or the failure of Lessor to perform any of its obligations under this Facility Lease or any other Lease Document to which it is a party, then within one hundred twenty (120) days after the Required Lease Effective Date, Lessee may deliver to Lessor written notice that Lessee has elected to terminate this Facility Lease (the “Lessee Termination Notice”), (ii) to continue this Facility Lease (the “Lessee Continuation Notice”) or (iii) to change the Required Lease Effective Date to a later date which shall be no more than three hundred sixty-five (365) days after the original Required Lease Effective Date; provided that Lessee shall include in its notice (A) Lessee’s response to the Independent Evaluator’s evaluation provided pursuant to Section 5.4 of Exhibit 3.1(a) and (B) a copy of the PSCW’s written approval that its election is reasonable and prudent; provided, further, that Lessee may only once elect to change the Required Lease Effective Date pursuant to Section 5.3(a)(iii).
Sample 1

Related to Lessor's Failure to Achieve the Lease Effective Date

  • Extension Term The Term of the Lease is hereby extended for sixty (60) months and, therefore, the Term Expiration Date is hereby amended to mean January 14, 2023. The period commencing on January 15, 2018 (the “Extension Term Commencement Date”) and ending on the Term Expiration Date shall be referred to herein as the “Extension Term.”

  • Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):

  • Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.

  • Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.

  • Extended Term Tenant shall have the option to extend the Term for two (2) consecutive five (5) year periods (the "FIRST EXTENDED TERM" and "SECOND EXTENDED TERM", respectively) on all the terms and conditions contained in this Lease including, without limitation, continuation of the adjustment of the Base Rent on an annual basis as provided in Section 3.3 below (provided only that upon commencement of the First Extended Term the only remaining option to extend the Term shall be the Second Extended Term and upon exercise of the option with respect to the Second Extended Term, no further right to extend the Term shall exist). Tenant shall deliver, if at all, written notice of its exercise of the option ("OPTION NOTICE") to Landlord at least six (6) months but not more than one (1) year before the expiration of the Term or First Extended Term, as the case may be. In the event Tenant fails to deliver the applicable Option Notice within the time allowed, Landlord shall deliver written notice to Tenant of Tenant's failure to deliver the Option Notice, and Tenant shall then have thirty (30) days from receipt of such notice within which to deliver the Option Notice, if at all, to Landlord. In the event (and only in the event) that, Tenant fails to deliver an Option Notice to Landlord within such thirty (30) days, Tenant shall be considered to have elected not to extend the Term of this Lease and thereafter, Tenant shall have no further right to extend the Term of this Lease. References in this Lease to the "Term" shall include the initial Term of fifteen (15) years and shall, in addition, include the First Extended Term and the Second Extended Term, if applicable.

  • Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans: the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.

  • Base Rent Abatement Provided that no Event of Default is then occurring, then during the period beginning on the Expansion Commencement Date and ending on November 14, 2010 (the “Base Rent Abatement Periods”), Tenant shall not be obligated to pay any Base Rent otherwise attributable to the 6310 Initial Premises for such Base Rent Abatement Period (the “Base Rent Abatement”). Tenant acknowledges and agrees that notwithstanding such Base Rent Abatement, such abatement of Base Rent shall have no effect on the calculation of any future increases in Base Rent, Operating Expenses or Tax Expenses payable by Tenant pursuant to the terms of the Lease (as hereby amended), which increases shall be calculated without regard to such abatement of Base Rent or corresponding abatement periods. Such Base Rent Abatement has been granted to Tenant as additional consideration for entering into this First Amendment, and for agreeing to pay the “rent” and performing the terms and conditions otherwise required under the Lease, as amended. Notwithstanding anything to the contrary set forth in this Section 4.3, to the extent an Event of Default is then occurring, then Landlord may at its option, by notice to Tenant, elect, in addition to any other remedies Landlord may have under the Lease, one or both of the following remedies: (i) that Tenant shall immediately become obligated to pay to Landlord all Base Rent abated hereunder during the Base Rent Abatement Period, with interest as provided pursuant to the Lease from the date such Base Rent would have otherwise been due but for the abatement provided herein, or (ii) that the dollar amount of the unapplied portion of the Base Rent Abatement as of such Event of Default shall be converted to a credit to be applied to the Base Rent applicable to the Premises at the end of the Expansion Term and Tenant shall immediately be obligated to begin paying Base Rent for the entire Premises in full.

  • Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.

  • Sublease Rent Limitation Anything contained in this Lease to the contrary notwithstanding, Lessee shall not sublet the Leased Property on any basis such that the rental to be paid by the sublessee thereunder would be based, in whole or in part, on either (a) the income or profits derived by the business activities of the sublessee, or (b) any other formula such that any portion of the Rent would fail to qualify as “rents from real property” within the meaning of Section 856(d) of the Code, or any similar or successor provision thereto.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!