Licensed Technology (a) LICENSOR is not aware of any interference, infringement, misappropriation, or other conflict with any intellectual property rights of third parties, and LICENSOR has never received any charge, complaint, claim, demand, or notice alleging any such interference, infringement, misappropriation, or violation (including any claim that LICENSOR must license or refrain from using any intellectual property rights of any third party). To the knowledge of LICENSOR, no third party has interfered with, infringed upon, misappropriated, or otherwise come into conflict with any of the LICENSED TECHNOLOGY.
(b) Exhibit A identifies each patent or registration which has been issued to LICENSOR with respect to any of the LICENSED TECHNOLOGY and identifies each pending patent application or application for registration which LICENSOR has made with respect to any of the LICENSED TECHNOLOGY. LICENSEE acknowledges that LICENSOR has previously made available to LICENSEE correct and complete copies of all such patents, registrations and applications (as amended to-date) in LICENSOR’s possession and has made available to LICENSEE correct and complete copies of all other written documentation in LICENSOR’s possession evidencing ownership and prosecution (if applicable) of each such item.
(c) Exhibit A identifies each item of LICENSED TECHNOLOGY that is assigned to LICENSOR or that LICENSOR uses pursuant to license, sublicense, agreement, or permission. LICENSOR has made available to LICENSEE correct and complete copies of all such licenses, sublicenses, agreements, patent prosecution files and permissions (as amended to-date) in LICENSOR’s possession. With respect to each item of LICENSED TECHNOLOGY required to be identified in Exhibit A and to the knowledge of LICENSOR: (i) the license, sublicense, agreement, or permission covering the item is legal, valid, binding, enforceable, and in full force and effect; (ii) the license, sublicense, agreement, or permission will continue to be legal, valid, binding, enforceable, and in full force and effect on identical terms following the consummation of the transactions contemplated hereby; (iii) no Party to the license, sublicense, agreement, or permission is in breach or default, and no event has occurred which with notice or lapse of time would constitute a breach or default or permit termination, modification, or acceleration thereunder; (iv) no party to the license, sublicense, agreement, or permission has repudiated any provision thereof; (v) the underlying item of LICENSED TECHNOLOGY is not subject to any outstanding lien or encumbrance, injunction, judgment, order, decree, ruling, or charge; (vi) no action, suit, proceeding, hearing, investigation, charge, complaint, claim, or demand is pending or is threatened which challenges the legality, validity, or enforceability of the underlying item of LICENSED TECHNOLOGY; and (vii) except as provided in Exhibit A, LICENSOR has not granted any license or similar right to the LICENSED TECHNOLOGY within the GENERAL FIELD or PARTHENOGENESIS FIELD.
Licensed Materials The materials that are the subject of this Agreement are set forth in Appendix A ("Licensed Materials").
Joint Work Product This Agreement is the joint work product of H-GAC and the Contractor. This Agreement has been negotiated by H-GAC and the Contractor and their respective counsel and shall be fairly interpreted in accordance with its terms and, in the event of any ambiguities, no inferences shall be drawn against any party.
Third Party Materials The Application may display, include, or make available third-party content (including data, information, applications, and other products, services, and/or materials) or provide links to third-party websites or services, including through third- party advertising ("Third-Party Materials"). You acknowledge and agree that Company is not responsible for Third-Party Materials, including their accuracy, completeness, timeliness, validity, copyright compliance, legality, decency, quality, or any other aspect thereof. Company does not assume and will not have any liability or responsibility to you or any other person or entity for any Third-Party Materials. Third-Party Materials and links thereto are provided solely as a convenience to you, and you access and use them entirely at your own risk and subject to such third parties' terms and conditions.
Background Technology List here prior contracts to assign Inventions that are now in existence between any other person or entity and you.
Technical Information The Employer agrees to provide to the Union such information that is available relating to employees in the bargaining unit, as may be required by the Union for collective bargaining purposes.
Licensed Software Computer program(s) provided by Contractor in connection with the Deliverables, subject to Section 14 of this Contract.
Third Party Technology The Company makes use of third party technology to collect information required for traffic measurement, research, and analytics. Use of third party technology entails data collection. We therefore would like to inform clients the Company enables third parties to place or read cookies located on the browsers of users entering the Company’s domain. Said third parties may also use web beacons to collect information through advertising located on the Company’s web site. Please note that you may change your browser settings to refuse or disable Local Shared Objects and similar technologies; however, by doing so you may be disabling some of the functionality of Company’s services.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Product Data Illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by Developer to illustrate a material, product, or system for some portion of the Work.
