Limitation because of undefinitized work Sample Clauses

Limitation because of undefinitized work. Notwithstanding any provision of this Contract, progress payments shall not exceed 80 percent on work accomplished on undefinitized Contract actions. A “Contract action” is any action resulting in a Contract, as defined in FAR Subpart 2.1.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Limitation because of undefinitized work. Notwithstanding any provision of this Contract, progress payments shall not exceed 80 percent on work accomplished on undefinitized Contract actions. A “Contract action” is any action resulting in a Contract, as defined in FAR Subpart 2.1. Suspension of Work (FAR 52.242-14 - Apr 1984)‌ A. The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government. B. If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract. C. A claim under this clause shall not be allowed— 1. For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and 2. Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract. Stop-Work Order (FAR 52.242-15 - Aug 1989) A. The Contracting Officer may, at any time, by written order to the Contractor, require the Contractor to stop all, or any part, of the work called for by this contract for a period of 90 days after the order is delivered to the Contractor, and for any further period to which the parties may agree. The order shall be specifically identified as a stop-work order issued under this clause. Upon receipt of the order, the Contractor shal...
Sample 1

Related to Limitation because of undefinitized work

  • COMMENCEMENT OF WORK UNDER A SOW AGREEMENT Commencement of work as a result of the SOW-RFP process shall be initiated only upon issuance of a fully executed SOW Agreement and Purchase Order.

  • Variation of period of parental leave Unless agreed otherwise between the employer and employee, an employee may apply to their employer to change the period of parental leave on one occasion. Any such change to be notified at least four weeks prior to the commencement of the changed arrangements.

  • COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.

  • Definition of Grievance A grievance shall be defined as any difference arising out of the interpretation, application, administration, or alleged violation of the Collective Agreement.

  • Obligation after the termination of personal data processing services

  • Definition of Force Majeure For the purposes of this section, an event of force majeure shall mean any cause beyond the control of the affected Interconnection Party or Construction Party, including but not restricted to, acts of God, flood, drought, earthquake, storm, fire, lightning, epidemic, war, riot, civil disturbance or disobedience, labor dispute, labor or material shortage, sabotage, acts of public enemy, explosions, orders, regulations or restrictions imposed by governmental, military, or lawfully established civilian authorities, which, in any of the foregoing cases, by exercise of due diligence such party could not reasonably have been expected to avoid, and which, by the exercise of due diligence, it has been unable to overcome. Force majeure does not include (i) a failure of performance that is due to an affected party’s own negligence or intentional wrongdoing; (ii) any removable or remediable causes (other than settlement of a strike or labor dispute) which an affected party fails to remove or remedy within a reasonable time; or (iii) economic hardship of an affected party.

  • VARIATION OF AGREEMENT 6.1 Subject to clauses 3.2, 6.2 and 6.3, this Agreement may be varied at any time if agreed between the Administrator and the Sector Association. 6.2 The facilities to which this Agreement applies may be varied in accordance with Rules 9 and 10. 6.3 This Agreement may be varied at any time by the Administrator to take account of changes to the terms specified in the Regulations.

  • Are There Distribution Rules That Apply After Death Special rules apply in the case of the divorce or death of a beneficiary of a Xxxxxxxxx Education Savings Account. In particular, any balances to the credit of a beneficiary must, within 30 days of death, be either: (i) rolled over to another beneficiary’s Xxxxxxxxx Education Savings Account according to the requirements of Section (4) (in which case the distribution will not be subject to tax) or (ii) distributed to a death beneficiary or the beneficiary’s estate (in which case the distribution will be subject to tax).

  • Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.

  • Cessation and Resumption of Work 24.15.1 At the time employees cease work due to inclement weather the employer or the employers representative on site and the employee’s representative shall agree and note the time of cessation of work. 24.15.2 After the period of inclement weather has clearly ended the employees shall resume work and the time shall be similarly agreed and noted.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!