Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever. (ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties. (iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority. (iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i). (v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party. (vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway. (vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Description of the service 10.1.1 Automatic transfer service implies a transfer by the bank of the funds from the client’s account without further consent of the client, on the basis of fixed amount determined by the client in its application form or of information provided by the client’s creditor to the bank on the client’s debt. 10.1.2 The parties agree that the payment order created (generated) by the bank for the purposes of automatic transfer services shall have the legal force equal to the document having been printed on the paper and executed by the person(s) authorized to manage of the account. 10.1.3 The bank shall carry out the automatic transfer services in accordance with requirements and conditions stipulated in this agreement, the application on registration for automatic transfer service and the sources disseminated by the bank. 10.1.4 For the purposes of obtaining automatic transfer services the client shall apply to the bank with the application as per paragraph 1.2 of this agreement.
Liability of the Servicer Notwithstanding any Subservicing Agreement, any of the provisions of this Agreement relating to agreements or arrangements between the Servicer and a Subservicer or reference to actions taken through a Subservicer or otherwise, the Servicer shall remain obligated and primarily liable to the Trustee for the servicing and administering of the Mortgage Loans in accordance with the provisions of Section 3.01 without diminution of such obligation or liability by virtue of such Subservicing Agreements or arrangements or by virtue of indemnification from the Subservicer and to the same extent and under the same terms and conditions as if the Servicer alone were servicing and administering the Mortgage Loans. The Servicer shall be entitled to enter into any agreement with a Subservicer for indemnification of the Servicer by such Subservicer and nothing contained in this Agreement shall be deemed to limit or modify such indemnification.
Description of the Services 1.1 The scope of the service to be rendered is described more fully in the Annexures and Schedules referred to below: ❑ Annexure A – Scope / Specification ❑ Annexure C – Pricing Schedule The Deliverables, due for completion by and governed by this Schedule 1. In the event that the Service Provider fails to meet the delivery dates as agreed, the following penalties will be imposed:
MAINTENANCE OF THE SAID BUILDING APARTMENT / PROJECT
Liability of the Seller The Seller shall be liable in accordance herewith only to the extent of the obligations in this Agreement specifically undertaken by the Seller and with respect to its representations and warranties expressly set forth hereunder.
Liability of the Subadviser (a) In the absence of willful misfeasance, bad faith, gross negligence or reckless disregard of obligations or duties ("disabling conduct") hereunder on the part of the Subadviser (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Subadviser) the Subadviser shall not be subject to liability to the Adviser (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Adviser) or to the Trust (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Trust) for any act or omission in the course of, or connected with, rendering services hereunder, including without limitation, any error of judgment or mistake of law or for any loss suffered by any of them in connection with the matters to which this Agreement relates, except to the extent specified in Section 36(b) of the Act concerning loss resulting from a breach of fiduciary duty with respect to the receipt of compensation for services. Except for such disabling conduct, the Adviser shall indemnify the Subadviser (and its officers, directors, partners, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Subadviser) from any and all losses, claims, damages, liabilities or litigation (including reasonable legal and other expenses) arising from Subadviser's rendering of services under this Agreement. (b) The Subadviser agrees to indemnify and hold harmless the Adviser (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Adviser) and/or the Trust (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Trust) against any and all losses, claims, damages, liabilities or litigation (including reasonable legal and other expenses), to which the Adviser and/or the Trust and their affiliates or such directors/trustees, officers or controlling person may become subject under the Act, the 1933 Act, under other statutes, common law or otherwise, which arise from the Subadviser's disabling conduct, including but not limited to any material failure by the Subadviser to comply with the provisions and representations and warranties set forth in Section 1 of this Agreement; provided, however, that in no case is the Subadviser's indemnity in favor of any person deemed to protect such other persons against any liability to which such person would otherwise be subject by reasons of willful misfeasance, bad faith, or gross negligence in the performance of his, her or its duties or by reason of his, her or its reckless disregard of obligations and duties under this Agreement.
Access to the Site 22.1 The Contractor shall allow the Engineer and any person authorized by the Engineer access to the Site, to any place where work in connection with the Contract is being carried out or is intended to be carried out and to any place where materials or plant are being manufactured / fabricated / assembled for the works.
Location of Improvements; No Encroachments All improvements which were considered in determining the Appraised Value of the Mortgaged Property lay wholly within the boundaries and building restriction lines of the Mortgaged Property, and no improvements on adjoining properties encroach upon the Mortgaged Property. No improvement located on or being part of the Mortgaged Property is in violation of any applicable zoning law or regulation;
Use of the Site You understand that, except for information, products or services clearly identified as being supplied by Penderbrook Golf Club, Penderbrook Golf Club does not operate, control or endorse any information, products or services on the Internet in any way. Except for Penderbrook Golf Club- identified information, products or services, all information, products and services offered through the Site or on the Internet generally are offered by third parties, that are not affiliated with Penderbrook Golf Club a. You also understand that Penderbrook Golf Club cannot and does not guarantee or warrant that files available for downloading through the Site will be free of infection or viruses, worms, Trojan horses or other code that manifest contaminating or destructive properties. You are responsible for implementing sufficient procedures and checkpoints to satisfy your particular requirements for accuracy of data input and output, and for maintaining a means external to the Site for the reconstruction of any lost data. YOU ASSUME TOTAL RESPONSIBILITY AND RISK FOR YOUR USE OF THE SITE AND THE INTERNET. Penderbrook Golf Club PROVIDES THE SITE AND RELATED INFORMATION “AS IS” AND DOES NOT MAKE ANY EXPRESS OR IMPLIED WARRANTIES, REPRESENTATIONS OR ENDORSEMENTS WHATSOEVER (INCLUDING WITHOUT LIMITATION WARRANTIES OF TITLE OR NONINFRINGEMENT, OR THE IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE) WITH REGARD TO THE SERVICE, ANY MERCHANDISE INFORMATION OR SERVICE PROVIDED THROUGH THE SERVICE OR ON THE INTERNET GENERALLY, AND Penderbrook Golf Club SHALL NOT BE LIABLE FOR ANY COST OR DAMAGE ARISING EITHER DIRECTLY OR INDIRECTLY FROM ANY SUCH TRANSACTION. IT IS SOLELY YOUR RESPONSIBILITY TO EVALUATE THE ACCURACY, COMPLETENESS AND USEFULNESS OF ALL OPINIONS, ADVICE, SERVICES, MERCHANDISE AND OTHER INFORMATION PROVIDED THROUGH THE SERVICE OR ON THE INTERNET GENERALLY. Penderbrook Golf Club DOES NOT WARRANT THAT THE SERVICE WILL BE UNINTERRUPTED OR ERROR-FREE OR THAT DEFECTS IN THE SERVICE WILL BE CORRECTED. YOU UNDERSTAND FURTHER THAT THE PURE NATURE OF THE INTERNET CONTAINS UNEDITED MATERIALS SOME OF WHICH ARE SEXUALLY EXPLICIT OR MAY BE OFFENSIVE TO YOU. YOUR ACCESS TO SUCH MATERIALS IS AT YOUR RISK. Penderbrook Golf Club HAS NO CONTROL OVER AND ACCEPTS NO RESPONSIBILITY WHATSOEVER FOR SUCH MATERIALS. LIMITATION OF LIABILITY IN NO EVENT WILL Penderbrook Golf Club BE LIABLE FOR (I) ANY INCIDENTAL, CONSEQUENTIAL, OR INDIRECT DAMAGES (INCLUDING, BUT NOT LIMITED TO, DAMAGES FOR LOSS OF PROFITS, BUSINESS INTERRUPTION, LOSS OF PROGRAMS OR INFORMATION, AND THE LIKE) ARISING OUT OF THE USE OF OR INABILITY TO USE THE SERVICE, OR ANY INFORMATION, OR TRANSACTIONS PROVIDED ON THE SERVICE, OR DOWNLOADED FROM THE SERVICE, OR ANY DELAY OF SUCH INFORMATION OR SERVICE. EVEN IF Penderbrook Golf Club OR ITS AUTHORIZED REPRESENTATIVES HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES, OR (II) ANY CLAIM ATTRIBUTABLE TO ERRORS, OMISSIONS, OR OTHER INACCURACIES IN THE SERVICE AND/OR MATERIALS OR INFORMATION DOWNLOADED THROUGH THE SERVICE. BECAUSE SOME STATES DO NOT ALLOW THE EXCLUSION OR LIMITATION OF LIABILITY FOR CONSEQUENTIAL OR INCIDENTAL DAMAGES, THE ABOVE LIMITATION MAY NOT APPLY TO YOU. IN SUCH STATES, Penderbrook Golf Club LIABILITY IS LIMITED TO THE GREATEST EXTENT PERMITTED BY LAW. Penderbrook Golf Club makes no representations whatsoever about any other web site which you may access through this one or which may link to this Site. When you access a non-Penderbrook Golf Club web site, please understand that it is independent from Penderbrook Golf Club, and that Penderbrook Golf Club has no control over the content on that web site. In addition, a link to a Penderbrook Golf Club web site does not mean that Penderbrook Golf Club endorses or accepts any responsibility for the content, or the use, of such web site.