Maintenance and Warranty Services Sample Clauses

Maintenance and Warranty Services. The cost of maintenance and warranty services for each year of the performance period in this Agreement are:
Sample 1
AutoNDA by SimpleDocs
Maintenance and Warranty Services. Except as otherwise provided in Section 10(b) of this Agreement, Ameresco will provide the following maintenance and warranty services on the equipment listed below (installed under this Project) during the Term and at the cost to Customer as set forth in Section 4 and Attachment G of this Agreement. Detailed terms and conditions relating to this maintenance and warranty service are included in this Attachment [ ] The installation of under the Agreement has/have been reviewed and found to be substantially complete. The date of Substantial Completion of the forgoing ECM(s) is hereby established as: The date of Substantial Completion of an ECM is the date certified by Customer when such ECM is sufficiently complete in accordance with the Agreement so that Customer derives beneficial use thereof. The Substantial Completion date set forth above is the date of commencement of applicable warranties for such ECM(s), as required by the Agreement. A list of items to be completed or corrected is identified below as punch list items. The failure to include any items on such punch list does not alter the responsibility of Ameresco to complete all work in accordance with the Agreement. AUTHORIZED SIGNATURE: DATE: NAME: (type or print) CUSTOMER: [CUSTOMER [ADDRESS[ AUTHORIZED SIGNATURE: DATE: NAME: (type or print) Attach additional page(s) as necessary. Number of pages attached . ATTACHMENT K STANDARDS OF SERVICE & COMFORT‌ Typical Operating Hours Area Description Total Annual Dark Hours of Operation (1) Typical Roadway Lighting Initial Dimming and Off Hours Dimming Factor for Roadway Lighting Xx. Xxx Xxxxxxxxx Vice President Ameresco, Inc.
Sample 1
Maintenance and Warranty Services. Supplier shall provide Maintenance and Warranty Services for the Products (collectively, “Support Services”) in accordance with the provisions of this Exhibit D at the rates specified in Schedule 1.
Sample 1

Related to Maintenance and Warranty Services

  • WARRANTY – SERVICES The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City’s rights under this section. C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source.

  • Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

  • Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).

  • Maintenance Services Subject to Client’s timely payment of the applicable maintenance fees, Accenture will make available the following maintenance services (“Maintenance Services”):

  • TAX SUPPORT SERVICES BNY Mellon shall provide the following tax support services for each Fund:  Provide various data and reports as agreed upon in the SLDs to support TRP’s tax reporting and tax filing obligations, including: · Wash sales reporting; · QDI reporting; · DRD reporting; · PFIC analysis; · Straddle analysis; · Paydown adjustments; · Equalization debit adjustments · Tax compliance under §851, §817(h); · Foreign bond sale analysis (§988); · Troubled debt analysis; · Estimation of income for excise tax purposes; · Swap analysis; · Inflation adjustments; · §1256 adjustments; · Market discount analysis; OID adjustments; · CPDI analysis; · Shareholder tax reporting information (e.g. FTC, UGG income, foreign source income by country, exempt income by state);  Provide data, and reports based on such data, maintained by BNY Mellon on its fund accounting platform as reasonably requested by TRP to support TRP’s obligations to comply with requests from tax authorities and TRP’s tax reporting and tax filing obligations.  Assist with other tax-related data needs as mutually agreed upon in writing from time-to-time.

  • Laboratory Services Covered Services include prescribed diagnostic clinical and anatomic pathological laboratory services and materials when authorized by a Member's PCP and HPN’s Managed Care Program.

  • Warranty Service In-home 07/13

  • TRANSPORT SERVICES Upon the conclusion of such multilateral negotiations, the Parties shall conduct a review for the purpose of discussing appropriate amendments to this Agreement so as to incorporate the results of such multilateral negotiations.

  • Maintenance of Services A. Reseller will adopt and adhere to the standards contained in the applicable BellSouth Work Center Interface Agreement regarding maintenance and installation of service. B. Services resold under the Company’s Tariffs and facilities and equipment provided by the Company shall be maintained by the Company. C. Reseller or its end users may not rearrange, move, disconnect, remove or attempt to repair any facilities owned by the Company, other than by connection or disconnection to any interface means used, except with the written consent of the Company. D. Reseller accepts responsibility to notify the Company of situations that arise that may result in a service problem. E. Reseller will be the Company's single point of contact for all repair calls on behalf of Reseller’s end users. The parties agree to provide one another with toll-free contact numbers for such purposes. F. Reseller will contact the appropriate repair centers in accordance with procedures established by the Company. G. For all repair requests, Reseller accepts responsibility for adhering to the Company's prescreening guidelines prior to referring the trouble to the Company. H. The Company will xxxx Reseller for handling troubles that are found not to be in the Company's network pursuant to its standard time and material charges. The standard time and material charges will be no more than what BellSouth charges to its retail customers for the same services. I. The Company reserves the right to contact Reseller’s customers, if deemed necessary, for maintenance purposes.

  • Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!