Significant Incidents In addition to notifying the appropriate authorities, Grantee will submit notice to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx and Substance Use Xxxxxxxx@xxxx.xxxxx.xx.xx significant incidents involving substantial disruption of Grantee’s program operation or affecting or potentially affecting the health, safety or welfare of the System Agency funded clients or participants within three (3) calendar days of discovery.
Catastrophic Leave The County will administer a Catastrophic Leave procedure designed to permit individual donations of annual leave, vacation, healthcare leave (8 hours maximum per fiscal year), compensatory and/or PIP leave time to an employee who is required to be on an extended unpaid leave due to a catastrophic medical condition or other serious circumstances.
Catastrophic Leave Program Leave credits, as defined below, may be transferred from one (1) or more employees to another employee, on an hour-for-hour basis, in accordance with departmental policies upon the request of both the receiving employee and the transferring employee and upon approval of the employee's appointing authority, under the following conditions:
A. The receiving employee is required to be absent from work due to injury or the prolonged illness of the employee, employee's spouse, registered domestic partner, a domestic partner listed on an “Affidavit for Enrollment of Domestic Partners,” submitted to employee benefits, parent or child, has exhausted all earned leave credits, including but not limited to sick leave, compensatory time, holiday credits and disability leave and is therefore facing financial hardship.
B. The transfers must be for a minimum of four (4) hours and in whole hour increments thereafter.
C. Transfers shall be allowed to cross-departmental lines in accordance with the policies of the receiving department.
D. The total maximum leave credits received by an employee shall normally not exceed five hundred twenty (520) hours; however, if approved by his/her appointing authority, the total leave credits may be up to one thousand forty (1,040) hours. Total leave credits in excess of one thousand forty (1,040) hours will be considered on a case-by-case basis by the appointing authority subject to the approval of the Chief Administrative Officer.
E. The transfers are irrevocable, and will be indistinguishable from other leave credits belonging to the receiving employee. Transfers will be subject to all taxes required by law.
F. Leave credits that may be transferred under this program are defined as the transferring employee’s vacation credits or up to twenty-four (24) hours of sick leave per fiscal year.
G. Transfers shall be administered according to the rules and regulations of the Auditor and Controller, and made on a form prescribed by the Auditor and Controller. Approvals of the receiving and donating employee, the donating employee's appointing authority and the receiving employee's appointing authority (in the case of an interdepartmental transfer) will be provided for on such form.
H. This program is not subject to the Grievance Procedure of this Agreement.
ACCIDENT PREVENTION T h i s p r o v i s i o n i s applicable to all Federal-aid construction contracts and to all related subcontracts.
1. In the performance of this contract the contractor shall comply with all applicable Federal, State, and local laws governing safety, health, and sanitation (23 CFR 635). The contractor shall provide all safeguards, safety devices and protective equipment and take any other needed actions as it determines, or as the contracting officer may determine, to be reasonably necessary to protect the life and health of employees on the job and the safety of the public and to protect property in connection with the performance of the work covered by the contract.
2. It is a condition of this contract, and shall be made a condition of each subcontract, which the contractor enters into pursuant to this contract, that the contractor and any subcontractor shall not permit any employee, in performance of the contract, to work in surroundings or under conditions which are unsanitary, hazardous or dangerous to his/her health or safety, as determined under construction safety and health standards (29 CFR 1926) promulgated by the Secretary of Labor, in accordance with Section 107 of the Contract Work Hours and Safety Standards Act (40 U.S.C. 3704).
3. Pursuant to 29 CFR 1926.3, it is a condition of this contract that the Secretary of Labor or authorized representative thereof, shall have right of entry to any site of contract performance to inspect or investigate the matter of compliance with the construction safety and health standards and to carry out the duties of the Secretary under Section 107 of the Contract Work Hours and Safety Standards Act (40 U.S.C.3704).
Critical Illness Three (3) days per year, with pay, shall be granted in the case of a critical illness or accident to a member of the employee's immediate family as defined in Section 9.4.2. A statement by the physician verifying the need for the employee to be present with the immediate family member shall be attached to the absence form.
Family Medical Leave or Critical Illness Leave a) Family Medical Leave or Critical Illness leaves granted to a permanent teacher, long-term occasional teacher or teacher hired into a term position under this Article shall be in accordance with the provisions of the Employment Standards Act, as amended.
b) The teacher will provide to the employer such evidence as necessary to prove entitlement under the Employment Standards Act.
c) A teacher contemplating taking such leave(s) shall notify the employer of the intended date the leave is to begin and the anticipated date of return to active employment.
d) Seniority and experience continue to accrue during such leave(s).
e) Where a teacher is on such leave(s), the Employer shall continue to pay its share of the benefit premiums, where applicable. To maintain participation and coverage under the Collective Agreement, the teacher must agree to provide for payment for the teacher’s share of the benefit premiums, where applicable.
f) In order to receive pay for such leaves, a teacher must access Employment Insurance and the Supplemental Employment Benefit (SEB) in accordance with g) to j), if allowable by legislation. An employee who is eligible for E.I. is not entitled to benefits under a school board’s sick leave and short term disability plan.
g) The Employer shall provide for permanent teachers, long-term occasional teachers and teachers hired into a term position who access such Leaves, a SEB plan to top up their E.I.
Critical Illness Leave (i) An Employee who has completed at least ninety (90) days of employment, and is a family member of a critically ill child or a critically ill qualified adult relative, is entitled to leave of absence without pay or benefits: • for a period of up to thirty-six (36) weeks to care for their critically ill child; or, • for a period of up to sixteen (16) weeks to care for a critically ill qualified adult relative.
Post-Accident Testing All Employees Post-accident drug and alcohol testing may be conducted by the Employer for any employee when a work-related incident has occurred involving death, serious bodily injury or significant property/environmental damage, or the potential for death, serious bodily injury, or significant property/environmental damage, and when the employee’s action(s) or inaction(s) either contributed to the incident or cannot be completely discounted as a contributing factor. Referral for post-accident testing will be made in accordance with Subsection 22.5 C, above.
Error Incident An Error Incident is a single or series of NAV Errors that results from the same act, omission, or use of incorrect data. NAV Errors will be corrected as follows: · If an NAV Error is less than ½ of 1% of NAV and results in a Net Benefit, the fund will retain the benefit. · If an NAV Error is less than ½ of 1% of NAV and results in a Net Loss, the Net Loss will be paid to the fund by the party responsible for causing the NAV Error. · In the case of a Material NAV Error, shareholder transactions/accounts will be corrected/ reprocessed at the corrected (restated) NAV, subject to a $10 per-account correction minimum threshold; any residual Net Benefit after correction of shareholder accounts will be retained by the fund and any residual Net Loss (resulting from uncorrected accounts below the $10 minimum threshold) will be paid to the fund by the party responsible for causing the error. If an NAV error is not caused by either the fund accounting agent or TRP, both TRP and the fund accounting agent will provide all reasonable assistance to the fund in its attempt to recover all costs from the responsible third party. · Notwithstanding any contractual provisions to the contrary, to the extent a NAV Error was caused by the actions or omissions of the fund’s accounting agent, any Net Loss or residual Net Loss equal to $5,000 or less that results from the same Error Incident will be paid by the accounting agent. TRP will be responsible for summarizing and reporting to the funds’ Audit Committee or Trust Company’s Board (or designated committee), as applicable, all NAV Errors related to the funds/trusts in conjunction with other relevant error statistics on a quarterly basis. The report will include corrected NAV Errors as well as the aggregate effect of any uncorrected NAV Errors. The report will also include information about shareholder accounts that were corrected in the discretion of TRP in the case of an NAV Error that is not a Material NAV Error. The funds’ Audit Committee and the Trust Company’s Board shall have the authority to adjust these procedures with respect to the funds and trusts, respectively, to the extent necessary or desirable to address NAV Errors by providing notice thereof to TRP and the fund’s accounting agent.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
