Provision of the Services The Supplier acknowledges and agrees that the Customer relies on the skill and judgment of the Supplier in the provision of the Services and the performance of its obligations under this Call Off Contract. The Supplier shall ensure that the Services: comply in all respects with the description of the Services in Call Off Schedule 2 ( Services) or elsewhere in this Call Off Contract; and are supplied in accordance with the provisions of this Call Off Contract (including the Call Off Tender) and the Tender. The Supplier shall perform its obligations under this Call Off Contract in accordance with: all applicable Law; Good Industry Practice; the Standards; the Security Policy; the ICT Policy (if so required by the Customer); and the Supplier's own established procedures and practices to the extent the same do not conflict with the requirements of Clauses 7.1.3(a) to 7.1.3(e). The Supplier shall: at all times allocate sufficient resources with the appropriate technical expertise to supply the Deliverables and to provide the Services in accordance with this Call Off Contract; subject to Clause 22.1 (Variation Procedure), obtain, and maintain throughout the duration of this Call Off Contract, all the consents, approvals, licences and permissions (statutory, regulatory contractual or otherwise) it may require and which are necessary for the provision of the Services; ensure that any services recommended or otherwise specified by the Supplier for use by the Customer in conjunction with the Deliverables and/or the Services shall enable the Deliverables and/or the Services to meet the requirements of the Customer; ensure that the Supplier Assets will be free of all encumbrances (except as agreed in writing with the Customer); ensure that the Services are fully compatible with any Customer Property or Customer Assets described in Call Off Schedule 4 (Implementation Plan) (or elsewhere in this Call Off Contract) or otherwise used by the Supplier in connection with this Call Off Contract; minimise any disruption to the Sites and/or the Customer's operations when providing the Services; ensure that any Documentation and training provided by the Supplier to the Customer are comprehensive, accurate and prepared in accordance with Good Industry Practice; co-operate with the Other Suppliers and provide reasonable information (including any Documentation), advice and assistance in connection with the Services to any Other Supplier and, on the Call Off Expiry Date for any reason, to enable the timely transition of the supply of the Services (or any of them) to the Customer and/or to any Replacement Supplier; assign to the Customer, or if it is unable to do so, shall (to the extent it is legally able to do so) hold on trust for the sole benefit of the Customer, all warranties and indemnities provided by third parties or any Sub-Contractor in respect of any Deliverables and/or the Services. Where any such warranties are held on trust, the Supplier shall enforce such warranties in accordance with any reasonable directions that the Customer may notify from time to time to the Supplier; provide the Customer with such assistance as the Customer may reasonably require during the Call Off Contract Period in respect of the supply of the Services; deliver the Services in a proportionate and efficient manner; ensure that neither it, nor any of its Affiliates, embarrasses the Customer or otherwise brings the Customer into disrepute by engaging in any act or omission which is reasonably likely to diminish the trust that the public places in the Customer, regardless of whether or not such act or omission is related to the Supplier’s obligations under this Call Off Contract; and gather, collate and provide such information and co-operation as the Customer may reasonably request for the purposes of ascertaining the Supplier’s compliance with its obligations under this Call Off Contract. An obligation on the Supplier to do, or to refrain from doing, any act or thing shall include an obligation upon the Supplier to procure that all Sub-Contractors and Supplier Personnel also do, or refrain from doing, such act or thing. This Clause 8 shall apply if any Services have been included in Annex 1 of Call Off Schedule 2 (Services).
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Description of the Services 1.1 The scope of the service to be rendered is described more fully in the Annexures and Schedules referred to below: ❑ Annexure A – Scope / Specification ❑ Annexure C – Pricing Schedule The Deliverables, due for completion by and governed by this Schedule 1. In the event that the Service Provider fails to meet the delivery dates as agreed, the following penalties will be imposed:
Scope of the Services UNOPS intends to retain the Contractor for the implementation of the Services, and the Contractor intends to provide the Services. The Contractor has represented to UNOPS that it has the appropriate experience, expertise, licences, and resources to undertake the Services and has agreed to undertake the Services in accordance with the Contract. In reliance on the Contractor’s representations UNOPS has entered into the Contract. The Contract sets out the terms and conditions upon which the Contractor will undertake the Services.
Autism Services This plan covers the following services for the treatment of autism spectrum disorders. • Applied behavior analysis when provided and/or supervised by an individual licensed by the state in which the service is rendered. See the Summary of Medical Benefits for the amount that you pay. • Physical therapy, occupational therapy, and speech therapy services when rendered as part of the treatment of autism spectrum disorder. A benefit limit will not apply to these services. • Psychological and psychiatric services, and prescription drugs are also covered. See Behavioral Health Services and Prescription Drugs and Diabetic Equipment or Supplies for additional information. Coverage for autism spectrum disorders does not affect any obligation of a school district, a state or other governmental entity to provide services to an individual under an individualized family service plan, an individualized education program, or similar services required under state or federal law. Services related to autism that are furnished by school personnel are not covered under this plan.
General Services JHSS shall be responsible for administering and/or performing the customary services of a transfer agent and dividend disbursing agent; acting as service agent in connection with dividend and distribution functions; and for performing shareholder account and administrative agent functions in connection with the issuance, transfer and redemption or repurchase (including coordination with the Custodian) of Shares of each Fund, as more fully described in Schedule 1 - Duties of JHSS attached hereto and made part hereof, and in accordance with the terms of the Prospectus and Statement of Additional Information of the Fund, applicable laws and the procedures established from time to time between the Fund and JHSS.
Legal Services If this Agreement is for legal services, this section is applicable. Contractor shall: (i) adhere to legal cost and billing guidelines designated by the JBE; (ii) adhere to litigation plans designated by the JBE, if applicable; (iii) adhere to case phasing of activities designated by the JBE, if applicable; (iv) submit and adhere to legal budgets as designated by the JBE; (v) maintain legal malpractice insurance in an amount not less than the amount designated by the JBE; and (vi) submit to legal bill audits and law firm audits if so requested by the JBE, whether conducted by employees or designees of the JBE or by any legal cost-control provider retained by the JBE for that purpose. Contractor may be required to submit to a legal cost and utilization review as determined by the JBE. If (a) the Contract Amount is greater than $50,000, (b) the legal services are not the legal representation of low- or middle-income persons, in either civil, criminal, or administrative matters, and (c) the legal services are to be performed within California, then Contractor agrees to make a good faith effort to provide a minimum number of hours of pro xxxx legal services, or an equivalent amount of financial contributions to qualified legal services projects and support centers, as defined in section 6213 of the Business and Professions Code, during each year of the Agreement equal to the lesser of either (A) thirty (30) multiplied by the number of full time attorneys in the firm’s offices in California, with the number of hours prorated on an actual day basis for any period of less than a full year or (B) the number of hours equal to ten percent (10%) of the Contract Amount divided by the average billing rate of the firm. Failure to make a good faith effort may be cause for nonrenewal of this Agreement or another judicial branch or other state contract for legal services, and may be taken into account when determining the award of future contracts with a Judicial Branch Entity for legal services.
OVERSIGHT SERVICES Oversight services for the Fund provided by Price Associates shall include all oversight of BNY Mellon, Delegates and service providers that provide accounting, administrative, and tax support services and not specifically provided for under each Fund’s Investment Management Agreement. Price Associates provides all accounting, administrative, tax and oversight services to the Funds listed on Exhibit A2, including the below. Accounting Services provided by Price Associates shall include, among other things: · oversight of quality control, including processing results related to fund accounting services provided by Delegates or other third party service providers relating to pricing. Such oversight includes, but is not limited to, review of (a) NAV calculations and fund valuations, (b) securities pricing and resolution of pricing exceptions, and (c) calculation and preparation of any financial information or schedules; · end-of-day INAV oversight for ETFs that provide INAV · determining accounting and valuation policies, instructing Delegates and/or other service providers, and/or providing it with such advice that may be reasonably necessary, to properly account for all financial transactions and to maintain the Fund’s accounting procedures and records so as to ensure compliance with generally accepted accounting principles and tax practices and rules; and · calculating and authorizing expense accruals and payments; annual fund expense budgets; accrual analysis; rollforward calculations; payment of expenses; fees for payment to service providers; · facilitating on behalf of the Fund resolution and remediation of fund accounting issues escalated by Delegates and/or other service providers; · preparing daily NAV calculations, including all necessary component services such as valuation and particularly private company investment valuation, corporate actions processing, trade processing, and performing month-end and fiscal-period-end close processes; · recordkeeping as required; and · such other accounting services as agreed to by the parties not otherwise performed by Price Associates under the Investment Management Agreement. Administrative Services provided by Price Associates shall include, among other things: · ensuring maintenance for the Fund of all records that may be reasonably required in connection with the audit performed by the Fund’s independent registered public accountants, or by the Securities and Exchange Commission (“SEC”), the Internal Revenue Service (“IRS”) or such other Federal or state regulatory agencies; · cooperating with the Fund’s independent registered public accountants and taking all reasonable action in the performance of its obligations under the Agreement to assure that the necessary information is made available to such accountants for the expression of their opinion without any qualification as to the scope of their examination including, but not limited to, their opinion included in the Fund’s annual report on Form N-CSR and annual amendment to Form N-1A; · implementing and maintaining the systems, data storage and reporting necessary to perform services outlined herein; · all efforts concerning financial reporting services, including shareholder reports and financial information in regulatory filings; N-PORT and N-CEN; and other financial reporting services as necessary; · determining financial reporting policies, maintaining adequate controls over financial reporting to provide complete and accurate financial information and disclosures that are certified by officers of the Funds. Providing sub-certifications, as requested by officers of the Funds, for the adequacy of such controls and the completeness and accuracy of information included in Form N-CSR or any other form that may require certification; · periodic testing of Internal Revenue Code qualification requirements; · prepare and furnish fund performance information; · prepare and disseminate vendor survey information; · prepare and file Rule 24f-2 notices and payment; and · such other administrative services as agreed to by the parties, not otherwise performed by Price Associates under the Investment Management Agreement.
Outside Services Consultant shall not use the service of any other person, entity, or organization in the performance of Consultant’s duties without the prior written consent of an officer of the Company. Should the Company consent to the use by Consultant of the services of any other person, entity, or organization, no information regarding the services to be performed under this Agreement shall be disclosed to that person, entity, or organization until such person, entity, or organization has executed an agreement to protect the confidentiality of the Company’s Confidential Information (as defined in Article 5) and the Company’s absolute and complete ownership of all right, title, and interest in the work performed under this Agreement.
Administration Services When a medical prescription drug is administered by infusion, the administration of the prescription drug may be covered separately from the prescription drug. See Infusion Therapy - Administration Services in the Summary of Medical Benefits for benefit limits and the amount you pay. Prescription drugs that are self-administered are not covered as a medical benefit but may be covered as a pharmacy benefit. Please see Pharmacy Prescription Drugs and Diabetic Equipment or Supplies – Pharmacy Benefits section above for additional information. For some medical prescription drugs, after the first administration, coverage may be limited to certain locations (for example, a designated outpatient or ambulatory service facility, physician’s office, or your home), provided the location is appropriate based on your medical status. For a list of medical prescription drugs that are subject to this Site of Care Program, visit our website. Preauthorization may be required to determine medical necessity as well as appropriate site of care. If we deny your request for preauthorization, or you disagree with our determination for the appropriate site of care, you can submit a medical appeal. See Appeals in Section 5 for information on how to file a medical appeal.
