Mandatory Notice of Delay Sample Clauses

Mandatory Notice of Delay. Not later than seven days after the start of any delay in the performance of the Work, regardless of the cause of the delay, and regardless of whether the delay is then ongoing, the Contractor must provide written notice of the delay to the District and the Architect (“Notice of Delay”). In any case that the Contractor fails to timely provide a Notice of Delay: (i) if it thereafter gives a Notice of Delay, the Contractor shall be deemed and construed to have waived and released any and all rights to an extension of time or additional compensation with respect to any time more than seven days prior to the date the District actually receives the Notice of Delay; and (ii) the District may hold the Contractor responsible for any delays and/or increased costs that the District reasonably might have mitigated had the District received a timely Notice of Delay. A Notice of Delay must set forth the cause(s) of the delay and be accompanied by documentation reasonably evidencing and supporting the Contractor’s position with respect to the cause(s) of the delay. The District or the Architect may request that the Contractor provide any additional or more detailed information regarding the delay, which the Contractor must provide within five days of request. THE GIVING OF A NOTICE OF DELAY IN CONNECTION WITH A DELAY SHALL BE DEEMED AND CONSTRUED AS A MANDATORY PREREQUISITE FOR ANY EXTENSION OF TIME AND/OR ADDITIONAL COMPENSATION TO THE CONTRACTOR ON ACCOUNT OF SUCH DELAY.
Sample 1
AutoNDA by SimpleDocs
Mandatory Notice of Delay. Not later than five days after the start of any delay in the performance of the Work, regardless of the cause of the delay, and regardless of whether the delay is then ongoing, the Contractor must provide written notice of the delay to the District and the Architect (“Notice of Delay”). In any case that the Contractor fails to timely provide a Notice of Delay: (i) if it thereafter gives a Notice of Delay, the Contractor shall be deemed and construed to have waived and released any and all rights to an extension of time or additional compensation with respect to any time more than five days prior to the date the District actually receives the Notice of Delay; and (ii) the District may hold the Contractor responsible for any delays and/or increased costs that the District reasonably might have mitigated had the District received a timely
Sample 1

Related to Mandatory Notice of Delay

  • Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.

  • NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.

  • Notification of Delay The Design Professional shall immediately notify the City in writing if Design Professional experiences or anticipates experiencing a delay in performing the Professional Services within the time frames set forth in the Task Order. The written notice shall include an explanation of the cause for, and a reasonable estimate of the length of, the delay. If in the opinion of the City, the delay affects a material part of the Task, the City may exercise its rights under Sections 2.5-2.7 of this Agreement.

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • Notice of lay off shall not apply where the Employer can establish that the lay-off results from an act of God, fire or flood.

  • Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:

  • Notice of Layoff The Employer shall make every reasonable effort under the circumstances to provide affected employees with at least fourteen (14) calendar days’ notice prior to the contemplated effective date of a layoff.

  • Notice of Nonpayment The Trustee shall notify the Grantor and the NDEQ Director by certified mail, return receipt requested, within 10 days following the expiration of the 30-day period after the anniversary of the establishment of the Trust, if no payment is received by the Grantor during that period. After the pay-in period is completed, the Trustee shall not be required to send a notice of nonpayment. Section 16.

  • STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.

  • Notice of Lay-off All regular employees shall be given in writing the following notice of lay-off or salary in lieu of notice:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!