CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “
(1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “
(1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.
Matters Involving Third Parties (i) If any third party shall notify any Party (the “Indemnified Party”) with respect to any matter (a “Third Party Claim”) which may give rise to a claim for indemnification against any other Party (the “Indemnifying Party”) under this Article VIII, then the Indemnified Party shall promptly notify each Indemnifying Party thereof in writing; provided, however, that no delay on the part of the Indemnified Party in notifying any Indemnifying Party shall relieve the Indemnifying Party from any obligation hereunder unless (and then solely to the extent) the Indemnifying Party thereby is prejudiced.
(ii) Any Indemnifying Party will have the right to defend the Indemnified Party against the Third Party Claim with counsel of its choice satisfactory to the Indemnified Party so long as (A) the Indemnifying Party notifies the Indemnified Party in writing within ten (10) days after the Indemnified Party has given notice of the Third Party Claim that the Indemnifying Party will indemnify the Indemnified Party from and against the entirety of any Adverse Consequences the Indemnified Party may suffer resulting from, arising out of, relating to, in the nature of, or caused by the Third Party Claim, (B) the Indemnifying Party provides the Indemnified Party with evidence acceptable to the Indemnified Party that the Indemnifying Party will have the financial resources to defend against the Third Party Claim and fulfill its indemnification obligations hereunder, (C) the Third Party Claim involves only money damages and does not seek an injunction or other equitable relief, (D) settlement of, or an adverse judgment with respect to, the Third Party Claim is not, in the good faith judgment of the Indemnified Party, likely to establish a precedential custom or practice adverse to the continuing business interests of the Indemnified Party, and (E) the Indemnifying Party conducts the defense of the Third Party Claim actively and diligently.
(iii) So long as the Indemnifying Party is conducting the defense of the Third Party Claim in accordance with Section 8.4(ii) hereof, (A) the Indemnified Party may retain separate co-counsel at its sole cost and expense and participate in the defense of the Third Party Claim, (B) the Indemnified Party will not consent to the entry of any judgment or enter into any settlement with respect to the Third Party Claim without the prior written consent of the Indemnifying Party, and (C) the Indemnifying Party will not consent to the entry of any judgment or enter into any settlement with respect to the Third Party Claim without the prior written consent of the Indemnified Party.
(iv) In the event any of the conditions in Section 8.4(ii) hereof is or becomes unsatisfied, however, (A) the Indemnified Party may defend against, and consent to the entry of any judgment or enter into any settlement with respect to, the Third Party Claim in any manner it may deem appropriate (and the Indemnified Party need not consult with, or obtain any consent from, any Indemnifying Party in connection therewith), (B) the Indemnifying Parties will reimburse the Indemnified Party promptly and periodically for the costs of defending against the Third Party Claim (including reasonable attorneys’ fees and expenses), and (C) the Indemnifying Parties will remain responsible for any Adverse Consequences the Indemnified Party may suffer resulting from, arising out of, relating to, in the nature of, or caused by the Third Party Claim to the fullest extent provided in this Article VIII.
Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies.
2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.
Your General Obligations 6.1 Full information You must give us any information we reasonably require for the purposes of this contract. The information must be correct, and you must not mislead or deceive us in relation to any information provided to us.
6.2 Updating information You must tell us promptly if information you have provided to us changes, including if your billing address changes or if your use of energy changes (for example, if you start running a business at the premises).
EMPLOYER AND UNION TO ACQUAINT NEW EMPLOYEES
(a) At the time of hire new employees will be advised that a collective agreement is in effect and of the conditions of employment set out in the articles dealing with Union Security and Dues Check-off.
(b) A new employee shall also be provided with:
(1) the name, location and work telephone number of the xxxxxxx; and
(2) an authorization form for union dues check-off.
(c) Upon request, the xxxxxxx shall be advised of the name, location and work telephone number of the new employee.
(d) The xxxxxxx will be given an opportunity to interview each new employee within regular working hours, without loss of pay, for 15 minutes sometime during the first 30 days of employment.
(e) The Union will provide the Employer with an up-to-date list of stewards' names, work locations and work telephone numbers in order that the Employer may meet its obligation in (b)(1) above.
(f) The Union will be provided with a copy of the completed and signed authorization form for dues check-off for all new employees.
Civil Liability If an action or proceeding is brought against any employee or former employee covered by this Agreement for an alleged tort committed by him in the performance of his duties, then:
Trade Union Training Leave Subject to all qualifications in this clause, an employee appointed or elected as an accredited representative of the union to which he/she belongs will, upon application in writing to the Enterprise, be granted up to 5 days leave with pay each calendar year non-cumulative to attend courses conducted or approved by the Union.
Description of Vendor Entity and Vendor's Goods & Services If awarded, this description of Vendor and Vendor's goods and services will appear on the TIPS website for customer/public viewing. Technology solutions value-added reseller and installer of all things technology. Please identify the individual who will be primarily responsible for all TIPS matters and inquiries for the duration of the contract. Xxxx Xxxxxxx Primary Contact Title VP of Sales Please enter a valid email address that will definitely reach the Primary Contact. xxxx@xxxxxxxxxx.xxx Numbers only, no symbols or spaces (Ex. 8668398477). The system will auto-populate your entry with commas once submitted which is appropriate and expected (Ex. 8,668,398,477). Please provide the accurate and current phone number where the individual who will be primarily responsible for all TIPS matters and inquiries for the duration of the contract can be reached directly. 0000000000 Numbers only, no symbols or spaces (Ex. 8668398477). The system will auto-populate your entry with commas once submitted which is appropriate and expected (Ex. 8,668,398,477). 0000000000 Numbers only, no symbols or spaces (Ex. 8668398477). The system will auto-populate your entry with commas once submitted which is appropriate and expected (Ex. 8,668,398,477). 0000000000
State of California Public Liability and Workers’ Compensation Program A. The Judicial Council has elected to be self-insured for its motor vehicle, aircraft liability and general liability exposures.
B. The Judicial Council administers workers’ compensation benefits for its employees through a Third Party agreement.
Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows:
(a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge.
(b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request.
(c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor.
(d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.
