Expansion Premises (a) In consideration of the rents, terms, provisions and covenants of this Amendment and the Lease, Landlord hereby leases unto Tenant and Tenant hereby rents and accepts from Landlord the Expansion Premises. The Expansion Premises is more particularly described on Exhibit A attached hereto. The Expansion Premises is contiguous to the Replacement Premises.
(b) Tenant covenants, as a material part of the consideration for the Lease, as amended hereby, to keep and perform each and all of said terms, covenants and conditions for which Tenant is liable and that this Amendment is made upon the condition of such performance. On and after the Second Renewal Term Commencement Date, all of the terms and provisions of the Lease, as amended hereby, shall apply to both the Replacement Premises and the Expansion Premises. From and after the Second Renewal Term Commencement Date, each and every reference in the Lease and in this Amendment to “Premises” shall be and mean the Replacement Premises and the Expansion Premises, collectively. The Replacement Premises and Expansion Premises consist of a total of approximately 12,103 rentable square feet. The Expansion Premises shall be known as Suite 246.
(c) At Landlord’s request, Tenant shall execute a Commencement Date Memorandum in the form attached hereto as Exhibit B acknowledging, among other things, the (i) Second Renewal Term Commencement Date, (ii) scheduled termination date of the Lease and (iii) Tenant’s acceptance of the Expansion Premises. Tenant’s failure to execute the Commencement Date Memorandum shall not affect Tenant’s liability hereunder.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Use of the Leased Premises (a) Lessor, in consideration of the rents to be paid and covenants herein contained, hereby leases to Lessee the Leased Premises.
(b) Lessee may use the Leased Premises for the operation of the station, and, in connection therewith, for the installation, repair, maintenance, operation, housing and removal of its Improvements and other related broadcasting equipment (together comprising the “Installations”). Lessee is fully familiar with the physical condition of the Land and has received the same in good order and condition, and agrees that the Land complies in all respects with all requirements of this Agreement. Lessee shall use the Land exclusively for purposes associated with the operation of the station.
(c) Lessee shall have the right from time to time to substitute Installations of similar kind and character for those hereinabove specified, including without limitation, the rebuilding and reconfiguring of the towers on the Real Property, provided such changes shall be approved in advance by Lessor, and Lessor shall not unreasonably delay or withhold its approval. In the event Lessee submits any such changes for Lessor’s approval and Lessor does not respond within thirty (30) days after Lessor’s receipt thereof, then such changes shall be deemed approved by Lessor, so long as such changes otherwise comply with this Agreement.
(d) Lessee shall have access to the Leased Premises twenty-four (24) hours per day, seven (7) days per week, for the purpose of installing, maintaining and repairing its Installations, provided that the contractors performing such work are reasonably acceptable to Lessor.
(e) Lessor shall not be responsible for repairs or maintenance to the Installations, except for repairs occasioned by the negligence of Lessor, its agents, employees or contractors.
(f) Lessee shall not use or permit the Leased Premises to be used by any dangerous, toxic, noxious or offensive trade or business, or for any unlawful purpose.
(g) Lessee shall not directly or indirectly create or permit to be created or to remain, and will discharge any mortgage, lien, security interest, encumbrance or charge on, pledge of or conditional sale or other title retention agreement with respect to the Real Property or any part thereof or Lessee’s interest therein other than (i) this Agreement, (ii) any lien, including a mortgage on the leasehold interest of Lessee, which may be approved by the Lessor in writing, which approval shall not be unreasonably withheld, (iii) liens for impositions not yet payable, or payable without the addition of any fine, penalty, interest or cost for non-payment, or being contested as permitted by Paragraph 3(d), below, and (iv) liens of mechanics, materialmen, suppliers or vendors, or rights thereto, incurred in the ordinary course of business for sums which under the terms of the related contracts are not at the time due, provided that adequate provision for the payment thereof shall have been made.
Existing Premises Notwithstanding anything to the contrary in the Lease as hereby amended, Tenant shall continue to pay Base Rent for the Existing Premises in accordance with the terms of the Lease.
First Aid Allowance An employee who has been trained to render first aid and who is the current holder of appropriate first aid qualifications such as a certificate from the St. John's Ambulance or similar body shall be paid a weekly allowance of $11.50 if appointed by their employer to perform first aid duty.
Tenant Improvement Allowance Commencing as of January 1, 2011, Tenant shall be entitled to use the “Tenant Improvement Allowance”, as defined in Section 2 of this Amendment, for the costs relating to the design and construction of Tenant’s improvements or which are otherwise “Tenant Improvement Allowance items,” as that term is defined in Section 2.2.1, below (collectively, the “Tenant Improvements”). In no event shall Landlord be obligated to make disbursements pursuant to this Tenant Work Letter or otherwise in connection with Tenant’s construction of the Tenant Improvements or any Tenant Improvement Allowance Items, as defined below, in a total amount which exceeds the sum of the Tenant Improvement Allowance. All Tenant Improvements for which the Tenant Improvement Allowance has been made available shall be deemed Landlord’s property under the terms of the Lease; provided, however, Landlord may, by written notice to Tenant given concurrently with Landlord’s approval of the “Final Working Drawings”, as that term is defined in Section 3.3, below, require Tenant, prior to the end of the Lease Term or promptly following any earlier termination of this Lease, at Tenant’s expense, to remove any Tenant Improvements and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to a Building standard general office condition; provided, however, that Landlord shall not require Tenant to remove upon termination or expiration of this Lease, or condition its approval upon Tenant’s agreement to remove upon termination or expiration of this Lease, any Tenant Improvements constructed pursuant to this Tenant Work Letter (including, without limitation, Larc improvements) which constitute standard, non-extraordinary improvements for ordinary office, laboratory and/or Larc uses in biotech facilities. Any portion of the Tenant Improvement Allowance that is not disbursed or allocated for disbursement by December 31, 2013, shall revert to Landlord and Tenant shall have no further rights with respect thereto.
Meal Breaks The timing of meal breaks on any particular job may be discussed between the Employer and the majority of employees at a particular site and varied by agreement. Occupational health and safety considerations will always prevail.
Vacating Premises (i) If the Assuming Bank elects not to purchase any owned Bank Premises, the notice of such election in accordance with Section 4.6(a) shall specify the date upon which the Assuming Bank's occupancy of such premises shall terminate, which date shall not be later than ninety (90) days after the date of the Assuming Bank's notice not to exercise such option. The Assuming Bank promptly shall relinquish and release to the Receiver such premises and the Furniture and Equipment and Fixtures located thereon in the same condition as at Bank Closing, normal wear and tear excepted. By occupying any such premises after the expiration of such ninety (90)-day period, the Assuming Bank shall, at the Receiver's option, (x) be deemed to have agreed to purchase such Bank Premises, and to assume all leases, obligations and liabilities with respect to leased Furniture and Equipment and leased Fixtures located thereon and any ground lease with respect to the land on which such premises are located, and (y) be required to purchase all Furniture and Equipment and Fixtures owned by the Failed Bank and located on such premises as of Bank Closing.
(ii) If the Assuming Bank elects not to accept an assignment of the lease or sublease any leased Bank Premises, the notice of such election in accordance with Section 4.6(b) shall specify the date upon which the Assuming Bank's occupancy of such leased Bank Premises shall terminate, which date shall not be later than the date which is one hundred eighty (180) days after Bank Closing. Upon vacating such premises, the Assuming Bank shall relinquish and release to the Receiver such premises and the Fixtures and the Furniture and Equipment located thereon in the same condition as at Bank Closing, normal wear and tear excepted. By failing to provide notice of its intention to vacate such premises prior to the expiration of the option period specified in Section 4.6(b), or by occupying such premises after the one hundred eighty (180)- day period specified above in this paragraph (ii), the Assuming Bank shall, at the Receiver's option, (x) be deemed to have assumed all leases, obligations and liabilities with respect to such premises (including any ground lease with respect to the land on which premises are located), and leased Furniture and Equipment and leased Fixtures located thereon in accordance with this Section 4.6 (unless the Receiver previously repudiated any such lease), and (y) be required to purchase all Furniture and Equipment and Fixtures owned by the Failed Bank at Fair Market Value and located on such premises as of Bank Closing.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.