MITIGATION CREDIT PRICING Sample Clauses

MITIGATION CREDIT PRICING. Upon permit approval mitigation credit fees will be collected from permittees and deposited into the MARS ILF Program Account. Mitigation fees will fund the ILF Program Account and its constituent sub-accounts: Statewide Program Administration Account, Contingency Account, Long-Term Management Account, and Mitigation Account. Credit prices will reflect full-cost accounting to implement all aspects of planning, establishment and long-term management of compensatory mitigation projects undertaken by the Statewide ILF Mitigation Program. Mitigation fees will be apportioned to program accounts according to the following ratios: Cost Category Percent of Fee Elements of Credit Fee* Mitigation Account 50% All costs associated with implementation of mitigation projects, as described below in credit pricing formulas. Contingency Account 20% Unanticipated costs associated with planning or implementation of the mitigation project. Can be used as Financial Assurance. Long-Term Management Account 15% Adaptive management and remediation of mitigation site, including defense of protections and financial assurances. Can be used as Financial Assurance. Program Administration Account 15% Administration and management of the statewide ILF Program, including legal, accounting, and consulting fees. Total Credit Price 100% * Refer to Section IV.C – Program Account, for costs associated with each account. XXXX will establish a price per unit of wetland mitigation credit and stream mitigation credit that will be sufficient to fund all accounts described in the Funding Provisions section of this document, including: Statewide Program Administration Account, Contingency Account, Long-Term Management Account, and Mitigation Account. 33 CFR 332.8(o)(5)(ii) (2008) states: For in-lieu fee programs, the cost per unit of credit must include the expected costs associated with the restoration, establishment, enhancement and/or preservation of aquatic resources in that Service Area. These costs must be based on full cost accounting, and include, as appropriate, expenses such as land acquisition or protection, project planning and design, construction, plant materials, labor, legal fees, monitoring, and remediation or adaptive management activities, as well as administration of the in-lieu fee program. The price of stream and wetland mitigation credits will be determined using one of the following formulas:
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs

Related to MITIGATION CREDIT PRICING

  • OFFSET CREDIT/COOPERATION This Contract has been entered into in direct support of LOCKHEED XXXXXX'x international offset programs. All offset benefit credits resulting from this Contract are the sole property of LOCKHEED XXXXXX to be applied to the offset program of its choice. SELLER shall assist LOCKHEED XXXXXX in securing appropriate offset credits from the respective country government authorities.

  • Service Level Commitment IBM provides the following service level commitment (“SLA”) for the Cloud Service, after IBM makes the Cloud Service available to you.

  • Mitigation Obligations Replacement of Lenders (a) If any Lender requests compensation under Section 2.15, or if the Borrower is required to pay any additional amount to any Lender or any Governmental Authority for the account of any Lender pursuant to Section 2.17, then such Lender shall use reasonable efforts to designate a different lending office for funding or booking its Loans hereunder or to assign its rights and obligations hereunder to another of its offices, branches or affiliates, if, in the judgment of such Lender, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 2.15 or 2.17, as the case may be, in the future and (ii) would not subject such Lender to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Lender. The Borrower hereby agrees to pay all reasonable costs and expenses incurred by any Lender in connection with any such designation or assignment.

  • OGS Centralized Contract Modifications OGS, an Authorized User, or the Contractor may suggest modifications to the Centralized Contract or its Appendices. Except as specifically provided herein, modifications to the terms and conditions set forth herein may only be made with mutual written agreement of the Parties. Modifications may take the form of an update or an amendment. “

  • CENTRALIZED CONTRACT MODIFICATIONS A. OGS, an Authorized User, or the Contractor may suggest modifications to the Centralized Contract or its Appendices. Except as specifically provided herein, modifications to the terms and conditions set forth herein may only be made with mutual written agreement of the Parties. Modifications may take the form of an update or an amendment. “

  • Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.

  • Product Availability Under no circumstances shall Company be responsible to Representative or anyone else for its failure to fill accepted orders, or for its delay in filling accepted orders, when such failure or delay is due to strike, accident, labor trouble, acts of nature, freight embargo, war, civil disturbance, vendor problems or any cause beyond Company's reasonable control.

  • Letter of Credit Fees The Borrower shall pay to the Administrative Agent for the account of each Revolving Credit Lender in accordance, subject to Section 2.16 with its Applicable Revolving Credit Percentage a Letter of Credit fee (the “Letter of Credit Fee”) for each Letter of Credit equal to the Applicable Rate times the daily amount available to be drawn under such Letter of Credit. For purposes of computing the daily amount available to be drawn under any Letter of Credit, the amount of such Letter of Credit shall be determined in accordance with Section 1.06. Letter of Credit Fees shall be (i) due and payable on the first Business Day after the end of each March, June, September and December, commencing with the first such date to occur after the issuance of such Letter of Credit, on the Letter of Credit Expiration Date and thereafter on demand and (ii) computed on a quarterly basis in arrears. If there is any change in the Applicable Rate during any quarter, the daily amount available to be drawn under each Letter of Credit shall be computed and multiplied by the Applicable Rate separately for each period during such quarter that such Applicable Rate was in effect. Notwithstanding anything to the contrary contained herein, upon the request of the Required Revolving Lenders, while any Event of Default exists, all past due Letter of Credit Fees shall accrue at the Default Rate.

  • Commitment Charge; Credit; Maturity Premium (a) The Borrower shall pay a commitment charge on the unwithdrawn amount of the Loan at the rate and on the terms specified in the Loan Agreement.

  • Enhancement Budget Enhancements refer to additional functionality and deliverables unknown to the Authorized User at the time of Mini-Bid release. An Authorized User is permitted to include an enhancement budget, as included in the Mini-Bid (up to 10%). The total cost of the project including the enhancement budget shall not exceed the Lot threshold from which the award was made. An Authorized User shall use Appendix F, Attachment 3, Enhancement Request Template to reflect such modifications. Mini-Bid/Statement of Work documents will define specific criteria and method of reimbursement for the enhancement budget. Written approval of the Enhancement Budget Request is required from both the Authorized User and the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!