Common use of MUTUAL RESPONSIBILITY Clause in Contracts

MUTUAL RESPONSIBILITY. 6.2.1 Contractor shall be responsible for affording Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor shall schedule and coordinate its construction and operations with the construction and operations of Separate Contractors as required by the Contract Documents. 6.2.2 If a portion of the Work is dependent upon the proper execution or results of other construction or operations by Separate Contractors, Contractor shall inspect such other construction or operations before proceeding with its portion of the Work. Contractor shall promptly report to City apparent discrepancies or defects which render the other construction or operations unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been corrected. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City or Separate Contractors is suitable to receive the Work, except as to defects not then reasonably discoverable. 6.2.3 In the event of Delays, improperly timed activities or Defective Work by the Contractor or the Separate Contractors, the costs of such occurrences shall be borne by the party responsible therefor. 6.2.4 If Contractor wrongfully causes damage to completed or partially completed construction or to property of City or Separate Contractors, Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General Conditions. 6.2.5 If a dispute, or other matters in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 of the General Conditions. Contractor shall immediately notify the Construction Manager in writing of such occurrences.

MUTUAL RESPONSIBILITY. ‌ 6.2.1 Contractor shall be responsible for affording Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor shall schedule and coordinate its construction and operations with the construction and operations of Separate Contractors as required by the Contract Documents. 6.2.2 If a portion of the Work is dependent upon the proper execution or results of other construction or operations by Separate Contractors, Contractor shall inspect such other construction or operations before proceeding with its that portion of the Work. Contractor shall promptly report to City District apparent discrepancies or defects which render the other construction or operations unsuitable to receive the Contractor’s Work. Unless otherwise directed by CityDistrict, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been corrected. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City or Separate Contractors is suitable to receive the Work, except as to defects not then reasonably discoverable.acknowledgment 6.2.3 In the event of Delays, improperly timed activities or Defective Work by the Contractor or the Separate ContractorsWork, the costs of such occurrences shall be borne by the party responsible therefortherefore. 6.2.4 If Contractor wrongfully causes damage to completed or partially completed construction or to property of City District or Separate Contractors, Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General Conditionsdamage. 6.2.5 If a dispute, or other matters in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 14 (Dispute Resolution) of the General ConditionsConstruction Contract. Contractor shall immediately notify the Construction Manager in writing and within seventy-two (72) hours of such occurrences.

MUTUAL RESPONSIBILITY. 6.2.1 The Contractor shall be responsible for affording Separate Contractors afford the Owner and separate contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor activities and shall schedule connect and coordinate its the Contractor's construction and operations with the construction and operations of Separate Contractors theirs as required by the Contract Documents. 6.2.2 If a portion part of the Contractor's Work is dependent upon the depends for proper execution or results of other upon construction or operations by Separate Contractorsthe Owner or a separate contractor, the Contractor shall inspect such other construction or operations before shall, prior to proceeding with its that portion of the Work. Contractor shall , promptly report to City the Architect and ARS apparent discrepancies or defects which render the in such other construction or operations that would render it unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been correctedfor such proper execution and results. Failure of the Contractor so to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other Owner's or separate contractors' completed or partially completed construction or operations by City or Separate Contractors is suitable fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable. 6.2.3 In the event of Delays, Costs caused by delays or by improperly timed activities or Defective Work by the Contractor or the Separate Contractors, the costs of such occurrences defective construction shall be borne by the party responsible therefor. 6.2.4 If The Contractor wrongfully causes shall promptly remedy damage caused by the Contractor to completed or partially completed construction or to property of City the Owner of separate contractors as provided in Subparagraph 10.2.5. 6.2.5 Should the Contractor cause damage to the work or Separate Contractorsproperty of any separate contractor and/or in the event of any other claim, dispute or matter in question between the Contractor and any separate contractor, the Contractor shall promptly remedy attempt to settle with such other contractor by agreement, or otherwise to resolve the dispute. In any event, the Contractor shall indemnify, defend and hold harmless the Owner and the other indemnitees as to damage to any such work or property it causes to the full extent as provided in agreed to under Paragraph 12.2 11.8 of these General Conditions. 6.2.5 If a dispute, or other matters 6.2.6 The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are described for the Contractor in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 of the General Conditions. Contractor shall immediately notify the Construction Manager in writing of such occurrencesParagraph 3.14.

MUTUAL RESPONSIBILITY. ‌ 6.2.1 Contractor shall be responsible for affording Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor shall schedule and coordinate its construction and operations with the construction and operations of Separate Contractors as required by the Contract Documents. 6.2.2 If a portion of the Work is dependent upon the proper execution or results of other construction or operations by Separate Contractors, Contractor shall inspect such other construction or operations before proceeding with its that portion of the Work. Contractor shall promptly report to City District apparent discrepancies or defects which render the other construction or operations unsuitable to receive the Contractor’s Work. Unless otherwise directed by CityDistrict, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been corrected. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City or Separate Contractors is suitable to receive the Work, except as to defects not then reasonably discoverable.report 6.2.3 In the event of Delays, improperly timed activities or Defective Work by the Contractor or the Separate ContractorsWork, the costs of such occurrences shall be borne by the party responsible therefortherefore. 6.2.4 If Contractor wrongfully causes damage to completed or partially completed construction or to property of City District or Separate Contractors, Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General Conditionsdamage. 6.2.5 If a dispute, or other matters in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 14 (Dispute Resolution) of the General ConditionsConstruction Contract. Contractor shall immediately notify the Construction Manager in writing and within seventy-two (72) hours of such occurrences.

MUTUAL RESPONSIBILITY. 6.2.1 The Contractor shall be responsible for affording Separate Contractors afford the Owner and separate contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor , and shall schedule connect and coordinate its the Contractor's construction and operations with the construction and operations of Separate Contractors theirs as required by the Contract Documents. 6.2.2 If a portion part of the Contractor's Work is dependent upon the depends for proper execution or results of other upon construction or operations operation by Separate Contractorsthe Owner or a separate contractor, the Contractor shall inspect such other construction or operations before shall, prior to proceeding with its that portion of the Work. Contractor shall , promptly report to City the Architect and the Owner apparent discrepancies or defects which render the in such other construction or operations that would render it unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been correctedfor such proper execution and results. Failure of the Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other Owner's or separate contractors' completed or partially completed construction or operations by City or Separate Contractors is suitable fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable. 6.2.3 In the event of Delays, Costs caused by delays or by improperly timed activities or Defective Work by the Contractor or the Separate Contractors, the costs of such occurrences defective construction shall be borne by the party responsible therefor. 6.2.4 If The Contractor wrongfully causes shall promptly remedy damage caused by the Contractor to completed or partially completed construction or to property of City the Owner or Separate Contractors, Contractor shall promptly remedy damage separate contractors as provided in Paragraph 12.2 of these General ConditionsSubparagraph 10.2.5, below. 6.2.5 If a dispute, or Claims and other disputes and matters in question arise between the Contractor and a Separate Contractor, these occurrences separate contractor shall be subject to the provisions of Section 4.2 Paragraph 4.3 above, provided the separate contractor has reciprocal obligations. If such separate contractor initiates legal or any other proceedings against the Owner on account of any damage alleged to have been caused by the Contractor, the Owner shall notify the Contractor, who shall defend such proceedings at its own expense, and 4.3 of if any judgment or award against the General Conditions. Owner arises therefrom, the Contractor shall immediately notify pay or satisfy it, and shall reimburse the Construction Manager Owner for all attorneys' fees and court or other costs which the Owner has incurred over and above those paid for directly by the Contractor. 6.2.6 The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are described for the Contractor in writing of such occurrencesParagraph 3.14, above.