Joint Funded Project with the Ohio Department of Transportation In the event that the Recipient does not have contracting authority over project engineering, construction, or right-of-way, the Recipient and the OPWC hereby assign certain responsibilities to the Ohio Department of Transportation, an authorized representative of the State of Ohio. Notwithstanding Sections 4, 6(a), 6(b), 6(c), and 7 of the Project Agreement, Recipient hereby acknowledges that upon notification by the Ohio Department of Transportation, all payments for eligible project costs will be disbursed by the Grantor directly to the Ohio Department of Transportation. A Memorandum of Funds issued by the Ohio Department of Transportation shall be used to certify the estimated project costs. Upon receipt of a Memorandum of Funds from the Ohio Department of Transportation, the OPWC shall transfer funds directly to the Ohio Department of Transportation via an Intra- State Transfer Voucher. The amount or amounts transferred shall be determined by applying the Participation Percentages defined in Appendix D to those eligible project costs within the Memorandum of Funds. In the event that the Project Scope is for right-of-way only, notwithstanding Appendix D, the OPWC shall pay for 100% of the right-of-way costs not to exceed the total financial assistance provided in Appendix C.
Electrical connections Equipment requiring electrical connections for operation shall either be hard wired to the Authorized User's provided connections or the Contractor shall be responsible for a male electrical union. All connections shall be made by the Contractor and accomplished in accordance with National Electrical Code requirements. Electrically operated equipment shall be available in the following volts and phases: 208 volt 1 or 3 phase, 60 HZ 220 volt 1 or 3 phase, 60 HZ 440 volt 1 or 3 phase, 60 HZ
Drainage Systems (1) Clear culvert inlets, outlets, and sediment catching basins.
(2) Maintain waterbars, drainage dips, and other water diversion measures.
(3) During active use, patrol and maintain functional drainage.
(4) Repair damaged culvert ends.
Transportation Management Tenant shall fully comply with all present or future programs intended to manage parking, transportation or traffic in and around the Building, and in connection therewith, Tenant shall take responsible action for the transportation planning and management of all employees located at the Premises by working directly with Landlord, any governmental transportation management organization or any other transportation-related committees or entities.
Environmental Services 1. Preparation of Environmental Documentation (CEQA/NEPA) including but not limited to the following:
a. Initial Study
b. Categorical Exemption (CE)
c. Notice of Exemption (XXX)
d. Negative Declaration (ND)
e. Mitigated Negative Declaration (MND)
f. Notice of Preparation (NOP)
g. Environmental Impact Report (EIR)
i. Initial Document (Screen Check/Administrative Draft) ii. Addendum iii. Supplemental
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Environmental Monitoring (a) Borrower shall give prompt written notice to Lender of (i) any proceeding or inquiry by any party (including any Governmental Authority) with respect to the presence of any Hazardous Substance on, under, from or about the Property, (ii) all claims made or threatened by any third party (including any Governmental Authority) against Borrower or the Property or any party occupying the Property relating to any loss or injury resulting from any Hazardous Substance, and (iii) Borrower’s discovery of any occurrence or condition on any real property adjoining or in the vicinity of the Property that could cause the Property to be subject to any investigation or cleanup pursuant to any Environmental Law. Upon becoming aware of the presence of mold or fungus at the Property, Borrower shall (i) undertake an investigation to identify the source(s) of such mold or fungus and, to the extent required by applicable law, shall develop and implement an appropriate remediation plan to eliminate the presence of any Toxic Mold, (ii) perform or cause to be performed all acts reasonably necessary for the remediation of any Toxic Mold (including taking any action necessary to clean and disinfect any portions of the Property affected by Toxic Mold, including providing any necessary moisture control systems at the Property), and (iii) provide evidence reasonably satisfactory to Lender of the foregoing. Borrower shall permit Lender to join and participate in, as a party if it so elects, any legal or administrative proceedings or other actions initiated with respect to the Property in connection with any Environmental Law or Hazardous Substance, and Borrower shall pay all reasonable attorneys’ fees and disbursements incurred by Lender in connection therewith.
(b) If Lender, on its good faith judgment, determines that reasonable cause exists for the performance of an environmental inspection or audit of the Property, at any time and from time to time upon Lender’s request, Borrower shall provide such inspection or audit of the Property prepared by a licensed hydrogeologist, licensed environmental engineer or qualified environmental consulting firm approved by Lender assessing the presence or absence of Hazardous Substances on, in or near the Property, and if Lender in its good faith judgment determines that reasonable cause exists for the performance of such environmental inspection or audit, then the cost and expense of such audit or inspection shall be paid by Borrower. Such inspections and audit may include soil borings and ground water monitoring. If Borrower fails to provide any such inspection or audit within thirty (30) days after such request, Lender may order same, and Borrower hereby grants to Lender and its employees and agents access to the Property and a license to undertake such inspection or audit.
(c) If any environmental site assessment report prepared in connection with such inspection or audit recommends that an operations and maintenance plan be implemented for any Hazardous Substance, whether such Hazardous Substance existed prior to the ownership of the Property by Borrower, or presently exists or is reasonably suspected of existing, Borrower shall cause such operations and maintenance plan to be prepared and implemented at its expense upon request of Lender, to the extent required by applicable law, and with respect to any Toxic Mold, Borrower shall, to the extent required by applicable law, take all action necessary to clean and disinfect any portions of the Improvements affected by Toxic Mold in or about the Improvements, including providing any necessary moisture control systems at the Property. If any investigation, site monitoring, containment, cleanup, removal, restoration or other work of any kind is reasonably necessary under an applicable Environmental Law (“Remedial Work”), Borrower shall commence all such Remedial Work within thirty (30) days after written demand by Lender and thereafter diligently prosecute to completion all such Remedial Work within such period of time as may be required under applicable law. All Remedial Work shall be performed by licensed contractors approved in advance by Lender and under the supervision of a consulting engineer approved by Lender which approval shall not be unreasonably withheld or delayed. All costs of such Remedial Work shall be paid by Borrower, including Lender’s reasonable attorneys’ fees and disbursements incurred in connection with the monitoring or review of such Remedial Work. If Borrower does not timely commence and diligently prosecute to completion the Remedial Work, Lender may (but shall not be obligated to) cause such Remedial Work to be performed at Borrower’s expense. Notwithstanding the foregoing, Borrower shall not be required to commence such Remedial Work within the above specified time period: (x) if prevented from doing so by any Governmental Authority, (y) if commencing such Remedial Work within such time period would result in Borrower or such Remedial Work violating any Environmental Law, or (z) if Borrower, at its expense and after prior written notice to Lender, is contesting by appropriate legal, administrative or other proceedings, conducted in good faith and with due diligence, the need to perform Remedial Work. Borrower shall have the right to contest the need to perform such Remedial Work, provided that, (1) Borrower is permitted by the applicable Environmental Laws to delay performance of the Remedial Work pending such proceedings, (2) neither the Property nor any part thereof or interest therein will be sold, forfeited or lost if Borrower fails to promptly perform the Remedial Work being contested, and if Borrower fails to prevail in contest, Borrower would thereafter have the opportunity to perform such Remedial Work, (3) Lender would not, by virtue of such permitted contest, be exposed to any risk of any civil liability for which Borrower has not furnished additional security as provided in clause (4) below, or to any risk of criminal liability, and neither the Property nor any interest therein would be subject to the imposition of any Lien for which Borrower has not furnished additional security as provided in clause (4) below, as a result of the failure to perform such Remedial Work and (4) Borrower shall have furnished to Lender additional security in respect of the Remedial Work being contested and the loss or damage that may result from Borrower’s failure to prevail in such contest in such amount as may be reasonably requested by Lender but in no event less than the cost of such Remedial Work as estimated by Lender and Borrower or Lender’s Consultant and any loss or damage that may result from Borrower’s failure to prevail in such contest.
(d) Borrower shall not install or permit to be installed on the Property any underground storage tank.
Transportation Transportation expenses include, but are not limited to, airplane, train, bus, taxi fares, rental cars, parking, mileage reimbursement, and tolls that are reasonably and necessarily incurred as a result of conducting State business. Each State agency shall determine the necessity for travel, and the mode of travel to be reimbursed.
Pipelines Developer shall have no interest in the pipeline gathering system, which gathering system shall remain the sole property of Operator or its Affiliates and shall be maintained at their sole cost and expense.
Foreign-Owned Companies in Connection with Critical Infrastructure If Texas Government Code, Section 2274.0102(a)(1) (relating to prohibition on contracts with certain foreign-owned companies in connection with critical infrastructure) is applicable to this Contract, pursuant to Government Code Section 2274.0102, Contractor certifies that neither it nor its parent company, nor any affiliate of Contractor or its parent company, is: (1) majority owned or controlled by citizens or governmental entities of China, Iran, North Korea, Russia, or any other country designated by the Governor under Government Code Section 2274.0103, or (2) headquartered in any of those countries.
