Newutilities Sample Clauses

Newutilities. (i) The Contractor shall allow, subject to the permission from the Authority and such conditions as the Authority may specify, access to, and use of the Site for laying telephone lines, water pipes, electricity lines/ cables or other public utilities. Where such access or use causes any financial loss to the Contractor, it may require the user of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner relieve the Contractor of its obligation to construct and maintain the Project Highway in accordance with this Agreement and any damage caused by such use shall be restored forthwith at the cost of theAuthority.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Newutilities. (i) The Contractor shall allow, subject to the permission from the Authority and such Km) of NH-02 in the state of Manipur in the year 2022-2023 on EPC mode” Aug,2022 conditions as the Authority may specify, access to, and use of the Site for laying telephone lines, water pipes, electricity lines/ cables or other public utilities. Where such access or use causes any financial loss to the Contractor, it may require the user of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner relieve the Contractor of its obligation to construct and maintain the Project Highway in accordance with this Agreement and any damage caused by such use shall be restored forthwith at the cost of theAuthority.
Sample 1
Newutilities. (i) The Contractor shall allow, subject to the permission from the Authority and such conditions as the Authority may specify, access to, and use of the Site for laying Contract AgreementPage 60 of 153 “Widening / Improvement to 4 (Four) Lane with Paved Shoulder configuration of existing single lane road from Kachukhana Harichara Paglagaunj to Dhubri - Phulbari Bridge approach (Package-II) of Srirampur - Dhubri Section of NH-127B from existing Km 28.050 to Km 55.060 (Design Km 27.650 to Km 54.154), (Design Length=26.504 Km) on EPC Mode in the State of Assam under JICA - ODA loan assistance.” Mar 2022
Sample 1
Newutilities. (i) The Contractor shall allow, subject to the permission from the Authority and such conditions as the Authority may specify, access to, and use of the Site for laying telephone lines, water pipes, electricity lines/ cables or other public utilities. Where such access or use causes any financial loss to the Contractor, it may require the user of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner relieve the Contractor of its obligation to construct and maintain the Project Highway in accordance with this Agreement and any damage caused by such use shall be restored forthwith at the cost of theAuthority. (ii) The Authority may, by notice, require the Contractor to connect any adjoining road to theProjectHighway,andtheconnectingportionthereoffallingwithintheSite shallbe constructed by the Contractor at the Authority’s cost in accordance with Article10. Draft Contract AgreementPage 56 of 146 “Construction of two lane with paved shoulders road from Tamenglong to Mahur (NH-137) in the State of Manipur from km 43.480 near Phelong Village to km 54.180 near Azuram Village (Length- 10.700 km) (Package-4) on EPC mode.” May 2021 (iii) The Authority may by notice require the Contractor to connect, through a paved road, any adjoining service station, hotel, motel or any other public facility or amenity to the Project Highway, whereupon the connecting portion thereof that falls within the Site shall be constructed by the Contractor on payment of the cost. The cost to be paid by the Authority to the Contractor shall be determined by the Authority’s Engineer. For the avoidance of doubt, in the event such road is to be constructed for the benefit of any entity, the Authority may require such entity to make an advance deposit with the Contractor or the Authority, as the case may be, of an amount equal to the estimated cost as determined by the Authority’s Engineer and such advance shall be adjusted against the cost of construction as determined by the Authority’s Engineerhereunder. (iv) IntheeventconstructionofanyWorksisaffectedbyanewutilityorworksundertaken in accordance with this Clause 9.3, the Contractor shall be entitled to a reasonable Time Extension as determined by the Authority’sEngineer. 9.4
Sample 1
Newutilities. The MDO shall allow, subject to such conditions as HPGCL may specify, access to,and use of the Site for laying telephone lines, water pipes, electric cables or otherpublic utilities, but only if it does not affect the operations of the Mines. Where suchaccessorusecausesanyfinanciallosstotheMDO,itmayrequiretheuseroftheSite to pay compensation or Damages as per Applicable Laws. For the avoidance ofdoubt, it is agreed that use of the Site under this Clause 11.4 shall not in any mannerrelieve the MDO of its obligation to operate and maintain the Mines in accordancewiththisAgreementandanydamagecausedbysuchuseshallberestoredforth with. ******
Sample 1
Newutilities. (i) The Contractor shall allow, subject to the permission from the Authority and such conditions as the Authority may specify, access to, and use of the Site for laying Restoration & Rehabilitation of Imphal-Jiribam Road from Km 103.00 to Km 133.00 (Length: 30 Km) on NH-37 in the state of Manipur in the year 2021-2022 on EPC Sept.,2021 telephone lines, water pipes, electricity lines/ cables or other public utilities. Where such access or use causes any financial loss to the Contractor, it may require the user of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner relieve the Contractor of its obligation to construct and maintain the Project Highway in accordance with this Agreement and any damage caused by such use shall be restored forthwith at the cost of theAuthority.
Sample 1
Newutilities. (i) The Contractor shall allow, subject to the permission from the Authority and such conditions as the Authority may specify, access to, and use of the Site for laying telephone lines, water pipes, electricity lines/ cables or other public utilities. Where such access or use causes any financial loss to the Contractor, it may require the user Drafit Contract Agreement Construction of North East Regional Office of National Highways & Infrastructure Development Corporation Ltd. at Guwahati, Assam on EPC mode (Balance Work) Sept 2023 of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner relieve the Contractor of its obligation to construct and maintain the Project in accordance with this Agreement and any damage caused by such use shall be restored forthwith at the cost of theAuthority.
Sample 1
AutoNDA by SimpleDocs
Newutilities. (i) The Contractor shall allow, subject to the permission from the Authority and such conditions as the Authority may specify, access to, and use of the Site for laying Contract AgreementPage 59 of 153 “Widening / Improvement to 4 (Four) Lane with Paved Shoulder configuration of existing single lane road from Kachukhana Harichara Paglagaunj to Dhubri - Phulbari Bridge approach (Package-II) of Srirampur - Dhubri Section of NH-127B from existing Km 28.050 to Km 55.060 (Design Km 27.650 to Km 54.154), (Design Length=26.504 Km) on EPC Mode in the State of Assam under JICA - ODA loan assistance.” Mar 2022 telephone lines, water pipes, electricity lines/ cables or other public utilities. Where such access or use causes any financial loss to the Contractor, it may require the user of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner relieve the Contractor of its obligation to construct and maintain the Project Highway in accordance with this Agreement and any damage caused by such use shall be restored forthwith at the cost of the Authority. (ii) The Authority may, by notice, require the Contractor to connect any adjoining road to theProjectHighway,andtheconnectingportionthereoffallingwithintheSite shallbe constructed by the Contractor at the Authority’s cost in accordance with Article10. Contract AgreementPage 60 of 153 “Widening / Improvement to 4 (Four) Lane with Paved Shoulder configuration of existing single lane road from Kachukhana Harichara Paglagaunj to Dhubri - Phulbari Bridge approach (Package-II) of Srirampur - Dhubri Section of NH-127B from existing Km 28.050 to Km 55.060 (Design Km 27.650 to Km 54.154), (Design Length=26.504 Km) on EPC Mode in the State of Assam under JICA - ODA loan assistance.” Mar 2022 (iii) The Authority may by notice require the Contractor to connect, through a paved road, any adjoining service station, hotel, motel or any other public facility or amenity to the Project Highway, whereupon the connecting portion thereof that falls within the Site shall be constructed by the Contractor on payment of the cost. The cost to be paid by the Authority to the Contractor shall be determined by the Authority’s Engineer. For the avoidance of doubt, in the event such road is to be constructed for the benefit of any entity, the Authority may require such entity to make an advance deposit with the Contractor or the Authori...
Sample 1

Related to Newutilities

  • Utilities The Landlord shall provide the following utilities and services to the Tenant: _ _. Any other utilities or services not mentioned will be the responsibility of the Tenant.

  • New utilities (i) The Contractor shall allow, subject to the permission from the Authority and such conditions as the Authority may specify, access to, and use of the Site for laying telephone lines, water pipes, electricity lines/ cables or other public utilities. Where such access or use causes any financial loss to the Contractor, it may require the user of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner relieve the Contractor of its obligation to construct and maintain the Project Highway in accordance with this Agreement and any damage caused by such use shall be restored forthwith at the cost of the Authority.

  • COMMON UTILITIES Expenses for serving/supply of common facilities and utilities and all charges incidental thereto.

  • Services and Utilities Landlord agrees to furnish services and utilities to the Premises during normal business hours on generally recognized business days, including the hours between 8:00 a.m. and 1:00 p.m. on Saturdays, subject to the Rules and Regulations of the Building or Project and provided that Tenant is not in default hereunder. Services and utilities shall include reasonable quantities of electricity (for the Common Area), heating, ventilation and air conditioning (HVAC) as required in Landlord’s reasonable judgment for the comfortable use and occupancy of the Premises, and in the event the HVAC is used during the respective overtime hours there shall be a charge of seventy-five dollars ($75.00) per hour of additional usage subject to change, based on Landlords costs to provide such services; window washing and janitor services in a manner that such services are customarily furnished to comparable office buildings in the area. Landlord shall supply common area water for drinking, cleaning and restroom purposes only and elevator services Tenant, at Tenant’s sole cost and expense, shall supply all paper and other products used, within the Premises. Upon Tenant’s request, Landlord shall replace light bulbs and ballasts in the Premises, and Tenant shall pay Landlord for the cost of such light bulbs and ballasts plus Landlord’s reasonable administrative and labor costs associated with light bulb and ballast replacement. During normal business hours on generally recognized business days, Landlord shall also maintain and keep lighted the common stairs, common entries and restrooms in the Building and shall furnish elevator service and restroom supplies. If Tenant desires HVAC or other services at any other time, Landlord shall use reasonable efforts to furnish such service upon reasonable notice from Tenant, and Tenant shall pay Landlord’s charges therefor on demand. Landlord may provide telecommunications lines and systems as discussed in Section 35 hereof. Tenant shall be entitled through the transmission facilities installed in the Premises, to have access to electric energy, at Tenant’s expense as provided for in this Paragraph, in the Premises in such reasonable quantity as shall be sufficient to meet Tenant’s ordinary business needs for lighting and the operation of its ordinary business machines, including without limitation, photocopy equipment, telephone equipment, microwaves, coffee machines, and computer and data processing equipment. Tenant shall pay to Landlord from and after the Commencement Date, as Additional Rent in accordance with Section 6.1., a sum to reimburse Landlord for all electricity used by Tenant to power the lights and electricity outlets located in the Premises (the Tenant Electric Amount). The Tenant Electric Amount shall be based on a separate meter survey conducted by a licensed independent electrical engineer selected by Landlord with respect to such parties reasonable estimate of Tenant’s usage. The Tenant Electric Amount shall be adjusted from time to time during the Term if (i) there is an increase in electric energy rates, (ii) Tenant installs additional fixtures, appliances or equipment, with or without Landlord’s consent, or (iii) Tenant otherwise uses a disproportionate or increased amount of electric energy, as determined by a separate meter survey conducted by a licensed independent electrical engineer selected by Landlord. Periodically, Landlord shall conduct an energy usage survey by a qualified energy surveyor. The cost of any and all such surveys shall be paid by Landlord, unless requested by Tenant, in which event, Tenant shall pay for such cost within twenty (20) days after Landlord’s demand. Notwithstanding anything to the contrary contained herein, Landlord may, at its option, at any time during the Term, arrange to have electric usage directly metered or submetered to the Premises, in which event Tenant will pay the utility company (or Landlord in the event of submetering without any profit or xxxx-up to Landlord) for such usage. Landlord may choose, in Landlord’s reasonable discretion, the company or companies that will provide all electricity (or any other utility) to the Project, and, in such event, Tenant shall pay for electric current supplied to, or used, in the Premises at the rate prevailing for Tenant’s class of use as established by such company or companies. Electric current shall be measured in a consistent, commercially reasonable manner and shall be billed by Landlord as Additional Rent and paid by Tenant on a monthly basis. If permitted by law, Landlord shall have the right, in Landlord’s reasonable discretion, at any time and from time to time during the Term, to contract for the provision of electricity (or any other utility) with, and to switch from, any company providing such utility. Tenant shall cooperate with Landlord and any such utility provider at all times, and, as reasonably necessary, Tenant shall allow such parties access to the electric (or other utility) lines, feeders, risers, wiring and other machinery located within the Premises. Landlord shall not be in default hereunder or be liable for any damages directly or indirectly resulting from, nor shall Rent be abated by reason of (a) the installation, use or interruption of use of any equipment in connection with the furnishing of any of the foregoing services, or (b) failure to furnish or delay in furnishing any such services where such failure or delay is caused by accident or any condition or event beyond the reasonable control of Landlord, or by the making of necessary repairs or improvements to the Premises, Building or Project, or (c) any change, failure, interruption, disruption or defect in the quantity or character of the electricity (or other utility) supplied to the Premises or Project, or (d) the limitation, curtailment or rationing of, or restrictions on, use of water, electricity, gas or any other form of energy serving the Premises, Building or Project. Landlord shall not be liable under any circumstances for a loss of or injury to property or business, however occurring, through, in connection with or incidental to the failure to furnish any such services. Notwithstanding anything contained herein to the contrary, if Tenant is granted the right to purchase electricity from a provider other than the company or companies used by Landlord, Tenant shall indemnify, defend, and hold harmless Landlord from and against all losses, claims, demands, expenses and judgments caused by, or directly or indirectly arising from, the acts or omissions of Tenant’s electricity provider (including, but not limited to, expenses and/or fines incurred by Landlord in the event Tenant’s electricity provider fails to provide sufficient power to the Premises, as well as damages resulting from the improper or faulty installation or construction of facilities or equipment in or on the Premises by Tenant or Tenant’s electricity provider. Nothing contained in this Section shall restrict Landlord’s right to require at any time separate metering of utilities furnished to the Premises. Landlord shall separate, meter for the Premises for electricity consumption and the cost of any such meter and its installation, maintenance and repair shall be paid by Landlord Accounts for all such separately metered utilities shall be in Tenant’s name and paid for by Tenant. If Tenant uses machines or equipment that generates excessive heat in the Premises that affects the temperature otherwise maintained by the HVAC system, Landlord reserves the right to install supplementary air conditioning units in the Premises and the cost thereof, including the cost of installation, operation and maintenance thereof, shall be paid by Tenant to Landlord within thirty (30) days of demand therefor.

  • Electric If Customer has selected an Electricity Fixed Rate on the Application, Customer’s Price will be based on the Fixed Rate(s) which includes Local and State taxes, Gross Receipts Tax (GRT), PJM Adjustment (defined below) charges and adjustments and Utility applied charges and/or fees related to generation, plus the Administration Charge, which includes, Electricity Balancing Amount and third party utility and billing charges. Customer understands and agrees that included in the Administration Charge is the cost of the Energy Balancing Amount (defined below). Customer understands that in order for RITERATE ENERGY to be able to supply Energy to its existing and prospective customers, RITERATE ENERGY enters into supply arrangements to meet the forecasted consumption of its various groups of customers. These forecasts are based on historical data, load shapes and/or estimates. To the extent that actual pooled consumption of RITERATE ENERGY’s Energy customers varies from supply arrangements and/or Customer’s Utility delivery requirements, RITERATE ENERGY incurs a cost in balancing and settling its supply arrangements with such pooled consumption. To ensure a fixed all-inclusive Rate, RITERATE ENERGY has included in the Administration charge, the Energy Balancing Amount, to balance and settle the variance between pooled consumption and supply arrangements (the “Energy Balancing Amount”). In respect of Electricity, Customer understands that there are certain estimated pass through costs, made up of charges to RITERATE ENERGY by the PJM Interconnection (“PJM”) and/or Customer’s Utility, including but not limited to ancillary service charges, the cost of unaccounted for electricity, capacity charges and any replacement or recharacterization of these charges. In this regard, the “PJM Adjustment”, is included in the Fixed Price Rate. Customer acknowledges and agrees that by entering into this Agreement, Customer will not be eligible to receive any net metering credits and other incentives to which Customer would otherwise be entitled. Further, included in the Rate are the amounts charged or billed to RITERATE ENERGY or Customer by Customer’s Utility, the PUC or any other regulatory or government entity, including any taxes, delivery, regulated transmission, regulated distribution, pipeline, compressor fuel, uplift, congestion, locational marginal pricing, invoice market participant, service, billing, or similar or related changes and any, deposits, interest or late payment fees or other amounts in connection with the supply and delivery of Energy to the Premises (collectively, “Regulatory Charges”). Customer agrees to pay the monthly Administration charge for Energy supply (the “Administration” charge).

  • UTILITIES & SERVICES Landlord shall provide, subject to the terms of this Section 11, water, electricity, heat, air conditioning, light, power, sewer, and other utilities (including gas and fire sprinklers to the extent the Project is plumbed for such services), refuse and trash collection and janitorial services (collectively, “Utilities”). Landlord shall pay, as Operating Expenses or subject to Tenant’s reimbursement obligation, for all Utilities used on the Premises, all maintenance charges for Utilities, and any storm sewer charges or other similar charges for Utilities imposed by any Governmental Authority or Utility provider, and any taxes, penalties, surcharges or similar charges thereon. Landlord shall not cause any Utilities to the Premises which are not currently separately metered to be separately metered. Tenant shall pay directly to the Utility provider, prior to delinquency, any separately metered Utilities and services which may be furnished to Tenant or the Premises during the Term. Tenant shall pay, as part of Operating Expenses, its share of all charges for jointly metered Utilities based upon consumption, as reasonably determined by Landlord. No interruption or failure of Utilities, from any cause whatsoever other than Landlord’s willful misconduct, shall result in eviction or constructive eviction of Tenant, termination of this Lease or the abatement of Rent. Tenant agrees to limit use of water and sewer with respect to Common Areas to normal restroom use. Landlord’s sole obligation for either providing emergency generators or providing emergency back-up power to Tenant shall be: (i) to provide emergency generators with not less than the capacity of the emergency generators located in the Building as of the Commencement Date, and (ii) to contract with a third party to maintain the emergency generators as per the manufacturer’s standard maintenance guidelines. Landlord shall have no obligation to provide Tenant with operational emergency generators or back-up power or to supervise, oversee or confirm that the third party maintaining the emergency generators is maintaining the generators as per the manufacturer’s standard guidelines or otherwise. During any period of replacement, repair or maintenance of the emergency generators when the emergency generators are not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative back-up generator or generators or alternative sources of back-up power. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such emergency generators will be operational at all times or that emergency power will be available to the Premises when needed.

  • Utility Any service provided by an outside source or manufactured in-house that facilitates building operations (e.g., gas, water, electricity, fire suppression water, fire alarm systems).

  • Utility Services Company agrees to pay the full cost and expense associated with its use of all utilities, including but not limited to water, sanitary sewer, electric, storm drainage, and telecommunication services.

  • Underground Utilities Any required ground digging or subsurface work shall be done in accordance with Chapter 556, Florida Statutes. It shall be the responsibility of CONTRACTOR to have all underground utilities located before any work begins (Sunshine State One Call 0-000-000-0000). The repairs of any damaged underground utilities as a result of the work being performed by CONTRACTOR shall be the responsibility of CONTRACTOR. The proper utility company shall be contacted immediately to expedite the repairs, if damage has occurred. CONTRACTOR will notify the COUNTY and provide a written explanation of the incident within two (2) days of the damage to any underground utilities.

Time is Money Join Law Insider Premium to draft better contracts faster.