Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
i) acts of God;
ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities;
iii) acts of war (whether declared or undeclared), invasion or civil unrest;
iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement);
v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals;
vi) earthquakes, explosions, accidents, landslides; fire;
vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality;
viii) chemical or radioactive contamination or ionizing radiation; or
ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs;
x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
