Observance of Time Limits Sample Clauses

Observance of Time Limits. By mutual agreement and for good cause, reasonable extensions of time will be given either party in writing at any step in the Grievance Procedure. Any grievance that is not appealed to the next step within the specified time limits or extension of time limits will be considered settled on the basis of the last decision given. Any grievance that is not answered by the Company within the time limits as specified in Step will be considered as having automatically moved to Step of the Grievance Procedure. The Company shall not have the right to invoke the time limits under this Agreement to disallow a grievance because of late appeal unless the Union Representative responsible for advancing the case to the next step is first notified of its intention at least three (3)working days (72 hours) prior to the effectiveness of such disallowance. Any Grievance that is not answered in writing or extended as provided above within the time limits specified at Step and Step of the Grievance Procedure shall be considered settled in favour of the Union with an appropriate remedy. The Union shall not invoke the time limits under this Agreement unless the Company representative responsible for answering the Grievance is notified in writing at least three (3) days (72hours) prior to the effectiveness of such forfeiture.
Sample 1
AutoNDA by SimpleDocs
Observance of Time Limits. Page Minutes and Grievance Record R e g u l a r A r b i t r a t i o n E x p e d i t e d A r b i t r a t i o n Retroactivity of Rewards and S e t t l e m e n t s Right to Process Grievances for L e g a l H e i r s , P e n d i n g G r i e v a n c e s P r i o r P r o p o s a l s . . Discharge and Disciplinary Procedure Procedure. . . . . . . . . . . . . . . . . . . . . . .
Sample 1
Observance of Time Limits. By mutual agreement and for good cause, reasonable extensions of time will be given either party in writing at any step in the Grievance Procedure. Any grievance that is not appealed to the next step within the specified time limits or extension of time will be considered settled on the basis of the last decision given. Any grievance that is not answer. The Company shall not have the right to invoke the time limits under this Agreement to disallow a grievance because of late appeal unless the Union Representative responsible for advancing the case to the next step is first notified of its intention at least three working days hours) prior to the effectiveness of such disallowance. Any Grievance that is not answered in writing or extended as provided above within the time limits specified at Step 2 and Step 3 of the Grievance Procedure shall be considered settled in favour of the Union with an appropriate remedy. The Union not invoke the time limits under this Agreement unless the Company representative responsible for answering the Grievance is notified in writing at least three working days hours) prior to the effectiveness of such forfeiture.
Sample 1
Observance of Time Limits. The parties may agree in writing to extend the time limits at any step in the grievance procedure including Article 8.
Sample 1

Related to Observance of Time Limits

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • OBSERVANCE OF THE LAW The Contractor shall comply with all laws, ordinances, rules, and regulations bearing upon the performance of its obligations under the terms of this Contract.

  • Observance of Laws Observe all laws, rules and/or regulations and further ensure that under no circumstances, the Promoter are held responsible or liable for any liability, whatsoever, for the same.

  • Observance of Legal Requirements Observe and comply in all material respects, and cause each Subsidiary so to do, with all laws, ordinances, orders, judgments, rules, regulations, certifications, franchises, permits, licenses, directions and requirements of all Governmental Authorities, which now or at any time hereafter may be applicable to it or to such Subsidiary, a violation of which could reasonably be expected to have a Material Adverse effect.

  • Observance of Law Tenant shall not use the Premises or permit anything to be done in or about the Premises which will in any way conflict with any law, statute, ordinance or governmental rule or regulation now in force or which may hereafter be enacted or promulgated. Tenant shall, at its sole cost and expense, promptly comply with all laws, statutes, ordinances and governmental rules, regulations or requirements now in force or which may hereafter be in force, and with the requirements of any board of fire insurance underwriters or other similar bodies now or hereafter constituted, relating to, or affecting the condition, use or occupancy of the Premises, excluding structural changes not related to or affected by Tenant's improvements or acts. The judgment of any court of competent jurisdiction or the admission of Tenant in any action against Tenant, whether Landlord is a party thereto or not, that Tenant has violated any law, ordinance or governmental rule, regulation or requirement, shall be conclusive of that fact as between Landlord and Tenant.

  • Observance of Holidays The Board of Trustees may establish calendars that observe holidays on dates other than those listed above, or as modified by current institutional practices.

  • Extension of Time Periods The parties may extend any period of time provided in this Article 7 by mutual agreement.

  • Amending of Time Limits The time limits fixed in both the grievance and arbitration procedure may be extended by consent of the parties.

  • Time Limits Each party involved in a grievance shall act quickly so that the grievance may be resolved promptly. Every effort should be made to complete action within the time limits contained in the grievance procedure. However, with the mutual consent of the parties, the time limitation for any step may be extended.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!