SaaS Services 6.1 Our SaaS Services are audited at least yearly in accordance with the AICPA’s Statement on Standards for Attestation Engagements (“SSAE”) No. 18. We have attained, and will maintain, SOC 1 and SOC 2 compliance, or its equivalent, for so long as you are timely paying for SaaS Services. Upon execution of a mutually agreeable Non-Disclosure Agreement (“NDA”), we will provide you with a summary of our compliance report(s) or its equivalent. Every year thereafter, for so long as the NDA is in effect and in which you make a written request, we will provide that same information.
6.2 You will be hosted on shared hardware in a Tyler data center or in a third-party data center. In either event, databases containing your Data will be dedicated to you and inaccessible to our other customers.
6.3 Our Tyler data centers have fully-redundant telecommunications access, electrical power, and the required hardware to provide access to the Tyler Software in the event of a disaster or component failure. In the event any of your Data has been lost or damaged due to an act or omission of Tyler or its subcontractors or due to a defect in Tyler’s software, we will use best commercial efforts to restore all the Data on servers in accordance with the architectural design’s capabilities and with the goal of minimizing any Data loss as greatly as possible. In no case shall the recovery point objective (“RPO”) exceed a maximum of twenty-four (24) hours from declaration of disaster. For purposes of this subsection, RPO represents the maximum tolerable period during which your Data may be lost, measured in relation to a disaster we declare, said declaration will not be unreasonably withheld.
6.4 In the event we declare a disaster, our Recovery Time Objective (“RTO”) is twenty-four (24) hours. For purposes of this subsection, RTO represents the amount of time, after we declare a disaster, within which your access to the Tyler Software must be restored.
6.5 We conduct annual penetration testing of either the production network and/or web application to be performed. We will maintain industry standard intrusion detection and prevention systems to monitor malicious activity in the network and to log and block any such activity. We will provide you with a written or electronic record of the actions taken by us in the event that any unauthorized access to your database(s) is detected as a result of our security protocols. We will undertake an additional security audit, on terms and timing to be mutually agreed to by the parties, at your written request. You may not attempt to bypass or subvert security restrictions in the SaaS Services or environments related to the Tyler Software. Unauthorized attempts to access files, passwords or other confidential information, and unauthorized vulnerability and penetration test scanning of our network and systems (hosted or otherwise) is prohibited without the prior written approval of our IT Security Officer.
6.6 We test our disaster recovery plan on an annual basis. Our standard test is not client-specific. Should you request a client-specific disaster recovery test, we will work with you to schedule and execute such a test on a mutually agreeable schedule. At your written request, we will provide test results to you within a commercially reasonable timeframe after receipt of the request.
6.7 We will be responsible for importing back-up and verifying that you can log-in. You will be responsible for running reports and testing critical processes to verify the returned Data.
6.8 We provide secure Data transmission paths between each of your workstations and our servers.
6.9 Tyler data centers are accessible only by authorized personnel with a unique key entry. All other visitors to Tyler data centers must be signed in and accompanied by authorized personnel. Entry attempts to the data center are regularly audited by internal staff and external auditors to ensure no unauthorized access.
6.10 Where applicable with respect to our applications that take or process card payment data, we are responsible for the security of cardholder data that we possess, including functions relating to storing, processing, and transmitting of the cardholder data and affirm that, as of the Effective Date, we comply with applicable requirements to be considered PCI DSS compliant and have performed the necessary steps to validate compliance with the PCI DSS. We agree to supply the current status of our PCI DSS compliance program in the form of an official Attestation of Compliance, which can be found at xxxxx://xxx.xxxxxxxxx.xxx/about- us/compliance, and in the event of any change in our status, will comply with applicable notice requirements.
Other Services At the request of the Fund, the Adviser in its discretion may make available to the Fund office facilities, equipment, personnel and other services. Such office facilities, equipment, personnel and services shall be provided for or rendered by the Adviser and billed to the Fund at the Adviser's cost.
Telecommunications Services The offering of telecommunications for a fee directly to the public, or to such classes of users as to be effectively available directly to the public, regardless of the facilities used.
Outpatient Services Physicians, Urgent Care Centers and other Outpatient Providers located outside the BlueCard® service area will typically require You to pay in full at the time of service. You must submit a Claim to obtain reimbursement for Covered Services.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Utilities, Services Landlord shall provide, subject to the terms of this Section 11, water, electricity, heat, air conditioning, light, power, sewer, and other utilities (including gas and fire sprinklers to the extent the Project is plumbed for such services), refuse and trash collection and janitorial services (collectively, “Utilities”). Landlord shall pay, as Operating Expenses or subject to Tenant’s reimbursement obligation, for all Utilities used on the Premises, all maintenance charges for Utilities, and any storm sewer charges or other similar charges for Utilities imposed by any Governmental Authority or Utility provider, and any taxes, penalties, surcharges or similar charges thereon. Landlord shall not cause any Utilities to the Premises which are not currently separately metered to be separately metered. Tenant shall pay directly to the Utility provider, prior to delinquency, any separately metered Utilities and services which may be furnished to Tenant or the Premises during the Term. Tenant shall pay, as part of Operating Expenses, its share of all charges for jointly metered Utilities based upon consumption, as reasonably determined by Landlord. No interruption or failure of Utilities, from any cause whatsoever other than Landlord’s willful misconduct, shall result in eviction or constructive eviction of Tenant, termination of this Lease or the abatement of Rent. Tenant agrees to limit use of water and sewer with respect to Common Areas to normal restroom use. Landlord’s sole obligation for either providing emergency generators or providing emergency back-up power to Tenant shall be: (i) to provide emergency generators with not less than the capacity of the emergency generators located in the Building as of the Commencement Date, and (ii) to contract with a third party to maintain the emergency generators as per the manufacturer’s standard maintenance guidelines. Landlord shall have no obligation to provide Tenant with operational emergency generators or back-up power or to supervise, oversee or confirm that the third party maintaining the emergency generators is maintaining the generators as per the manufacturer’s standard guidelines or otherwise. During any period of replacement, repair or maintenance of the emergency generators when the emergency generators are not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative back-up generator or generators or alternative sources of back-up power. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such emergency generators will be operational at all times or that emergency power will be available to the Premises when needed.
No Other Services The execution of this Agreement does not constitute a request for, nor agreement to provide Energy, any Ancillary Services or Installed Capacity under the NYISO Market Administration and Control Area Services Tariff (“Services Tariff”). If Developer wishes to supply Energy, Installed Capacity or Ancillary Services, then Developer will make application to do so in accordance with the NYISO Services Tariff.
The Advisers Services (a) DISCRETIONARY INVESTMENT MANAGEMENT SERVICES. The Adviser shall act as investment adviser with respect to the Funds. In such capacity, the Adviser shall, subject to the supervision of the Board, regularly provide the Funds with investment research, advice and supervision and shall furnish continuously an investment program for the Funds, consistent with the respective investment objectives and policies of each Fund. The Adviser shall determine, from time to time, what securities shall be purchased for the Funds, what securities shall be held or sold by the Funds and what portion of the Funds' assets shall be held uninvested in cash, subject always to the provisions of the Trust's Agreement and Declaration of Trust, By-Laws and its registration statement on Form N-1A (the "Registration Statement") under the 1940 Act, and under the Securities Act of 1933, as amended (the "1933 Act"), covering Fund shares, as filed with the Securities and Exchange Commission (the "Commission"), and to the investment objectives, policies and restrictions of the Funds, as each of the same shall be from time to time in effect. To carry out such obligations, the Adviser shall exercise full discretion and act for the Funds in the same manner and with the same force and effect as the Funds themselves might or could do with respect to purchases, sales or other transactions, as well as with respect to all other such things necessary or incidental to the furtherance or conduct of such purchases, sales or other transactions. No reference in this Agreement to the Adviser having full discretionary authority over each Fund's investments shall in any way limit the right of the Board, in its sole discretion, to establish or revise policies in connection with the management of a Fund's assets or to otherwise exercise its right to control the overall management of a Fund.
Surgery Services This plan covers surgery services to treat a disease or injury when: • the operation is not experimental or investigational, or cosmetic in nature; • the operation is being performed at the appropriate place of service; and • the physician is licensed to perform the surgery. This plan covers reconstructive surgery and procedures when the services are performed to relieve pain, or to correct or improve bodily function that is impaired as a result of: • a birth defect; • an accidental injury; • a disease; or • a previous covered surgical procedure. Functional indications for surgical correction do not include psychological, psychiatric or emotional reasons. This plan covers the procedures listed below to treat functional impairments. • abdominal wall surgery including panniculectomy (other than an abdominoplasty); • blepharoplasty and ptosis repair; • gastric bypass or gastric banding; • nasal reconstruction and septorhinoplasty; • orthognathic surgery including mandibular and maxillary osteotomy; • reduction mammoplasty; • removal of breast implants; • removal or treatment of proliferative vascular lesions and hemangiomas; • treatment of varicose veins; or • gynecomastia.
Inpatient Services Hospital Rehabilitation Facility
