Owner's Right To Inspect Work Sample Clauses

Owner's Right To Inspect Work. Except as may be otherwise provided herein, all Work furnished by the Contractor and all places where construction is carried on will be subject to inspection, examination and testing by the Owner at all times during the construction. The Owner has the right to reject defective Work including defective material and workmanship furnished by the Contractor, and require its correction subject to Contractor’s warranty obligations set forth in Section 4.10. Rejected Work shall be corrected to conform to this Agreement without charge therefor. The Contractor shall promptly segregate and remove all rejected material from the Site. The Contractor shall furnish promptly without additional charge, all reasonable facilities, labor and materials necessary for the safe and convenient inspection that may be required by the Owner. All inspection by the Owner will be performed in such manner as will not unnecessarily delay the Work. Should it be considered necessary or advisable by the Owner at any time before Substantial Completion of the entire Work to make an examination of the Work already completed, by removing or tearing out same, the Contractor shall on request furnish all necessary facilities, labor, and materials to perform such examination. If the Work subject to such examination is found to be defective or non-conforming in any material respect, due to the fault of the Contractor or its Subcontractors, such uncovering or destruction and reconstruction shall be at the expense of the Contractor. If, however, such Work exposed and examined is found to be satisfactory, the Owner will pay the Contractor the cost of such uncovering or destruction and reconstruction.
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
Owner's Right To Inspect Work. Owner and its agents and employees shall, upon reasonable prior notice to Contractor and subject to adherence to the safety procedures and other procedures and requirements applicable to the Site (including without limitation, and such procedures and requirements established in connection with any insurance coverage obtained in connection with the Project), have access to inspect all Work; provided, however, that any inspection of the Work shall be conducted at a reasonable time and in a manner that does not delay or increase the Cost of the Work by disrupting the Work. Contractor shall have the right to condition such inspection upon the persons conducting the inspection observing procedures to preserve the safety and security of the Site and to comply with any applicable requirements of Project insurers. Notwithstanding any review or inspection by the State of the Work, Contractor shall not be relieved of its responsibility for the design, construction and performance of the Project as expressly set forth in this Agreement solely by virtue of the State’s inspection or review.
Sample 1Sample 2Sample 3See All (4)
Owner's Right To Inspect Work. Owners and their agents and employees, as well as Owners’ PCO, shall, upon reasonable prior notice to Contractor and subject to adherence to the safety procedures and other procedures and requirements applicable to the Site (including without limitation, and such procedures and requirements established in connection with any insurance coverage obtained in connection with the Project), have access to inspect all Work; provided, however, that any inspection of the Work shall be conducted at a reasonable time and in a manner that does not delay or increase the Cost of the Work by disrupting the Work. Contractor shall have the right to condition such inspection upon the persons conducting the inspection observing procedures to preserve the safety and security of the Site and to comply with any applicable requirements of Project insurers. Notwithstanding any review or inspection by a Governmental Authority of the Work, Contractor shall not be relieved of its responsibility for the design, construction and performance of the Project as expressly set forth in this Agreement solely by virtue of such Governmental Authority inspection or review.
Sample 1

Related to Owner's Right To Inspect Work

  • DXC’s Right to Inspect DXC may, at any time, inspect the software, Services, or Products and associated manufacturing processes. Inspection may occur at Supplier’s facility, plant or subcontractor’s plant. Supplier will inform its vendors and subcontractors of DXC’s right to inspect and shall secure that right for DXC if necessary.

  • LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.

  • Lessor’s Right to Inspect Lessee shall permit Lessor and its authorized representatives as frequently as reasonably requested by Lessor to inspect the Leased Property and Lessee’s accounts and records pertaining thereto and make copies thereof, during usual business hours upon reasonable advance Notice, subject only to any business confidentiality requirements reasonably requested by Lessee.

  • Right to Inspect Bank (through any of its officers, employees, or agents) shall have the right, upon reasonable prior notice, from time to time during Borrower’s usual business hours but no more than twice a year (unless an Event of Default has occurred and is continuing), to inspect Borrower’s Books and to make copies thereof and to check, test, and appraise the Collateral in order to verify Borrower’s financial condition or the amount, condition of, or any other matter relating to, the Collateral.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Right to Inspect Records Engineer agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of Engineer involving transactions relating to this contract. Engineer agrees that City shall have access during normal working hours to all necessary Engineer facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. City shall give Engineer reasonable advance notice of intended audits. Engineer further agrees to include in subcontract(s), if any, a provision that any subcontractor or consultant agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of such consultant or subcontractor involving transactions to the subcontract, and further, that City shall have access during normal working hours to all consultant or subcontractor facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this paragraph. City shall give the consultant or subcontractor reasonable advance notice of intended audits.

  • OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.

  • Right to Inspect and Audit AHS and the Minister shall have the right (including all access rights required) to inspect or audit the Facility and all of the equipment, Staff and records of the Operator (and to take copies of records where either desires to do so) related to Services performed or to be performed (and goods and services sold or otherwise provided to persons receiving such Services) at all reasonable times and without prior notice in cases of emergency or whenever there is any reasonable apprehension of any ongoing danger to Clients for the purposes of determining compliance with this Agreement, the accuracy of any information provided and compliance with all Applicable Laws.

  • Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.

  • Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!