Examination and Testing Sample Clauses

Examination and Testing. At any time prior to the expiry of the last Defects Liability Period (or the last Second Defects Liability Period, whichever is the later), Honeywell may require the Works to be tested. The Subcontractor must give such assistance and make accessible such parts of the Works as may be required by Honeywell for that purpose. On completion of any tests, the Subcontractor must make good any part of the Works affected by testing so that it fully complies with the Subcontract. Except where the Subcontract otherwise provides, the cost of any tests and the cost of making good any part of the Works affected by tests will be borne by Honeywell unless the tests reveal a Defect in the Works in which case the costs of the testing and making good the Works must be borne by the Subcontractor.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Examination and Testing. At any time prior to the expiry of the last Defects Liability Period, Honeywell may require the Works to be tested. The Subcontractor must give such assistance and make accessible such parts of the Works as may be required by Honeywell for that purpose. On completion of any tests, the Subcontractor must make good any part of the Works affected by testing so that it fully complies with the Subcontract. Except where the Subcontract otherwise provides, the cost of any tests and the cost of making good any part of the Works affected by tests will be borne by Honeywell unless the tests reveal a Defect in the Works in which case the costs of the testing and making good the Works must be borne by the Subcontractor.
Sample 1Sample 2
Examination and Testing. 1At any time before the expiry of the Defects Liability Period, the Contractor may direct that any of the Works be tested. The Subcontractor shall give such assistance and samples and make accessible such parts of the Works as may be directed by the Contractor.
Sample 1
Examination and Testing. Regardless of whether an Inmate self- identifies as having a disability, ADOC will continue to evaluate Inmates for disabilities through examination and testing. 1. ADOC will identify Inmates with physical disabilities in accordance with OHS Policy. A physical exam of each Inmate will be conducted by a medical provider employed or contracted by ADOC and appropriately licensed by the State of Alabama. This exam will occur within seven (7) days of intake, not including weekends and holidays. Inmates in ADOC’s custody at the time of the Court’s final approval of this Amended Agreement will continue to be screened, evaluated and tested for disabilities to ensure that physical disability status is identified, treated and accommodated. Within six (6) months of the Court’s final approval of this Agreement, each Inmate with a health care code of 4 or above will be screened, tested and evaluated for physical disabilities. Each Inmate with a health care code of 3 or less will be evaluated within twelve (12) months of the Court’s final approval of this Agreement at the time of their annual physical. 2. ADOC will identify Inmates with intellectual disabilities through the use of appropriately administered tests under the following regimen. i. Beginning eight (8) months after the Court’s final approval of this Amended Agreement, Inmates coming into or returning to ADOC’s custody (“New Inmates”) will be screened for intellectual disabilities initially using the Beta III test. This testing will be performed in a group setting. A New Inmate who scores 80 or lower on the Beta III test will then be individually screened for intellectual disabilities using the most current version of the Weschler Abbreviated Scale of Intelligence (WASI). If the Inmate scores 75 or below on the WASI, no further IQ testing is necessary and the Inmate will be deemed to have an IQ equal to the Inmate’s WASI score. If the Inmate’s score on the Beta III is 80 or less, but the Inmate’s WASI score is greater than 75 but less than 79, then the Inmate will be given the most current version of the Weschler Adult Intelligence Scale, (WAIS), currently the WAIS IV. An Inmate who scores 79 or higher on the WASI, or 76 or higher on the WAIS, is deemed to have an IQ too high for further consideration of an intellectual disability. If an Inmate’s score on either the WASI or the WAIS is 75 or less, then additional testing to determine whether the Inmate has an intellectual or developmental disability will be p...
Sample 1
Examination and Testing a. In addition to any testing, examination or inspection requirements specified in the Agreement, Owner, as part of its inspection and at its own cost, may examine or may require Contractor to examine, inspect and test any materials and workmanship, or check the progress of manufacture of all materials and equipment being supplied. Owner shall cooperate with Contractor so that inspections do not cause any unreasonable delay, interference, or cost increase in the execution of the relevant Work. Any such inspection, examination or testing or waiver of such shall not constitute acceptance or be construed as an approval of such materials and workmanship or in any way affect or reduce Contractor’s obligations to complete the Work in accordance with this Agreement. b. If the Owner performs inspections or tests on the premises of Contractor or of a Technical Consultant or Subcontractor, Contractor shall furnish, and shall require each such Technical Consultant or Subcontractor to furnish, all reasonable facilities and assistance for the safe and convenient performance of these inspections or tests. c. If any of the Work does not conform to Agreement requirements, Owner may require Contractor to re-perform the Work in conformity with Agreement requirements. d. Inspection and testing by Owner shall not relieve Contractor from any responsibility to meet the Agreement requirements. e. Inspection and testing by Owner does not constitute acceptance of the Work to be provided under this Agreement. Acceptance of such Work shall be determined by any acceptance procedures set forth elsewhere in this Agreement, or otherwise by Owner’s failure to reject the Work within a reasonable time (but not more than thirty (30) Days) after completion of all Work under this Agreement. Acceptance shall not limit Contractor’s liability under applicable warranties, including the Warranty in Article 21.
Sample 1
Examination and Testing. No amendment
Sample 1
Examination and Testing. 13.1 Tetra Tech may order tests (a) The Contractor must perform all tests required to be performed by the Contractor under this Contract (including all such tests referred to in Tetra Tech’s Project Requirements) or otherwise required by Good Industry Practice. (b) In addition to the tests required to be performed by the Contractor under this Contract, at any time before the expiry of the Defects Liability Period, Tetra Tech may direct that any Materials and Equipment or the Works be tested (“Additional Testing”). (c) The Contractor must provide such assistance and samples and make accessible such parts of the Works as may be required by Tetra Tech for inspection or testing. (d) Tetra Tech may direct that any part of the Works shall not be covered up or made inaccessible without Tetra Tech’s prior approval. (e) Tests must be conducted as provided in this Contract or by Tetra Tech or a person (which may include the Contractor) nominated by Tetra Tech. (f) Before conducting a test under this Contract, the party conducting the test, being Tetra Tech or the Contractor, will give reasonable notice in writing to the other party of the time, date and place of the test. If the other party does not then attend, the test may nevertheless proceed. (g) Without prejudice to any other right, if Tetra Tech or the Contractor delays in conducting a test, the other party, after giving reasonable notice in writing of its intention to do so, may conduct the test. (h) Results of tests must be promptly made available by each party to the other party. (i) On completion of the tests, the Contractor must, to the extent applicable, promptly make good the work tested so that it fully complies with this Contract and provide a detailed written report to Tetra Tech, describing any Defect identified by the testing and the action taken by the Contractor to remedy and make good that Defect.
Sample 1
AutoNDA by SimpleDocs
Examination and Testing 
Sample 1Sample 2Sample 3

Related to Examination and Testing

  • Inspection and Testing Each Constructing Entity shall cause inspection and testing of the Interconnection Facilities that it constructs in accordance with the provisions of this section. The Construction Parties acknowledge and agree that inspection and testing of facilities may be undertaken as facilities are completed and need not await completion of all of the facilities that a Constructing Entity is building.

  • Inspection and Tests 3.8.1 The Procuring entity or its representative shall have the right to inspect and/or to test the goods to confirm their conformity to the Contract specifications. The Procuring entity shall notify the tenderer in writing in a timely manner, of the identity of any representatives retained for these purposes. 3.8.2 The inspections and tests may be conducted in the premises of the tenderer or its subcontractor(s), at point of delivery, and/or at the Goods’ final destination If conducted on the premises of the tenderer or its subcontractor(s), all reasonable facilities and assistance, including access to drawings and production data, shall be furnished to the inspectors at no charge to the Procuring entity. 3.8.3 Should any inspected or tested goods fail to conform to the Specifications, the Procuring entity may reject the equipment, and the tenderer shall either replace the rejected equipment or make alterations necessary to make specification requirements free of costs to the Procuring entity. 3.8.4 The Procuring entity’s right to inspect, test and where necessary, reject the goods after the Goods’ arrival shall in no way be limited or waived by reason of the equipment having previously been inspected, tested and passed by the Procuring entity or its representative prior to the equipment delivery. 3.8.5 Nothing in paragraph 3.8 shall in any way release the tenderer from any warranty or other obligations under this Contract.

  • Examination and Review (i) After receipt of the Closing Working Capital Statement, Seller will have *** (***) days from the date on which Buyer has provided to Seller all access and information reasonably requested for such purposes (the “Review Period”) to review the Closing Working Capital Statement. During the Review Period, Seller and its accountants will have full access to the relevant books and records of Buyer, the personnel of, and work papers prepared by, Buyer and/or Buyer’s accountants to the extent that they relate to the Closing Working Capital Statement and to such historical financial information (to the extent in Buyer’s possession) relating to the Closing Working Capital Statement as Seller may reasonably request for the purpose of reviewing the Closing Working Capital Statement and to prepare a Statement of Objections. (ii) On or prior to the last day of the Review Period, Seller may object to the Closing Working Capital Statement by delivering to Buyer a written statement setting forth Seller’s objections in reasonable detail, indicating each disputed item or amount and the basis for Seller’s disagreement therewith (the “Statement of Objections”). If Seller fails to deliver the Statement of Objections before the expiration of the Review Period, then the Closing Working Capital Statement and the Post-Closing Adjustment, as the case may be, reflected in the Closing Working Capital Statement will be deemed to have been accepted by Seller. If Seller delivers the Statement of Objections before the expiration of the Review Period, Buyer and Seller will negotiate in good faith to resolve such objections within *** (***) days after the delivery of the Statement of Objections (the “Resolution Period”), and, if the same are so resolved within the Resolution Period, then the Post-Closing Adjustment and the Closing Working Capital Statement with such changes as may have been previously agreed in writing by Buyer and Seller, will be final and binding.

  • Inspections and Tests 26.1 The Supplier shall at its own expense and at no cost to the Procuring Entity carry out all such tests and/or inspections of the Goods and Related Services as are specified in the SCC. 26.2 The inspections and tests may be conducted on the premises of the Supplier or its Subcontractor, at point of delivery, and/or at the Goods' final destination, or in another place in Kenya as specified in the SCC. Subject to GCC Sub-Clause 26.3, if conducted on the premises of the Supplier or its Subcontractor, all reasonable facilities and assistance, including access to drawings and production data, shall be furnished to the inspectors at no charge to the Procuring Entity. 26.3 The Procuring Entity or its designated representative shall be entitled to attend the tests and/or inspections referred to in GCC Sub-Clause 26.2, provided that the Procuring Entity bear all of its own costs and expenses incurred in connection with such attendance including, but not limited to, all travelling and board and lodging expenses. 26.4 Whenever the Supplier is ready to carry out any such test and inspection, it shall give a reasonable advance notice, including the place and time, to the Procuring Entity. The Supplier shall obtain from any relevant third party or manufacturer any necessary permission or consent to enable the Procuring Entity or its designated representative to attend the test and/or inspection. 26.5 The Procuring Entity may require the Supplier to carry out any test and/or inspection not required by the Contract but deemed necessary to verify that the characteristics and performance of the Goods comply with the technical specifications codes and standards under the Contract, provided that the Supplier's reasonable costs and expenses incurred in the carrying out of such test and/or inspection shall be added to the Contract Price. Further, if such test and/or inspection impedes the progress of manufacturing and/or the Supplier's performance of its other obligations under the Contract, due allowance will be made in respect of the Delivery Dates and Completion Dates and the other obligations so affected. 26.6 The Supplier shall provide the Procuring Entity with a report of the results of any such test and/or inspection. 26.7 The Procuring Entity may reject any Goods or any part thereof that fail to pass any test and/or inspection or do not conform to the specifications. The Supplier shall either rectify or replace such rejected Goods or parts thereof or make alterations necessary to meet the specifications at no cost to the Procuring Entity, and shall repeat the test and/or inspection, at no cost to the Procuring Entity, upon giving a notice pursuant to GCC Sub- Clause 26.4. 26.8 The Supplier agrees that neither the execution of a test and/or inspection of the Goods or any part thereof, nor the attendance by the Procuring Entity or its representative, nor the issue of any report pursuant to GCC Sub-Clause 26.6, shall release the Supplier from any warranties or other obligations under the Contract.

  • Search, Enquiry, Investigation, Examination And Verification a. The Property is sold on an “as is where is basis” subject to all the necessary inspection, search (including but not limited to the status of title), enquiry (including but not limited to the terms of consent to transfer and/or assignment and outstanding charges), investigation, examination and verification of which the Purchaser is already advised to conduct prior to the auction and which the Purchaser warrants to the Assignee has been conducted by the Purchaser’s independent legal advisors at the time of execution of the Memorandum. b. The intending bidder or the Purchaser is responsible at own costs and expenses to make and shall be deemed to have carried out own search, enquiry, investigation, examination and verification on all liabilities and encumbrances affecting the Property, the title particulars as well as the accuracy and correctness of the particulars and information provided. c. The Purchaser shall be deemed to purchase the Property in all respects subject thereto and shall also be deemed to have full knowledge of the state and condition of the Property regardless of whether or not the said search, enquiry, investigation, examination and verification have been conducted. d. The Purchaser shall be deemed to have read, understood and accepted these Conditions of Sale prior to the auction and to have knowledge of all matters which would have been disclosed thereby and the Purchaser expressly warrants to the Assignee that the Purchaser has sought independent legal advice on all matters pertaining to this sale and has been advised by his/her/its independent legal advisor of the effect of all the Conditions of Sale. e. Neither the Assignee nor the Auctioneer shall be required or bound to inform the Purchaser of any such matters whether known to them or not and the Purchaser shall raise no enquiry, requisition or objection thereon or thereto.

  • Inspection and Verification The Secured Parties and such persons as the Secured Parties may reasonably designate shall have the right to inspect the Collateral, all records related thereto (and to make extracts and copies from such records) and the premises upon which any of the Collateral is located, to discuss the Grantor’s affairs with the officers of the Grantor and its independent accountants and to verify under reasonable procedures the validity, amount, quality, quantity, value, condition and status of, or any other matter relating to, the Collateral, including, in the case of collateral in the possession of any third Person, by contacting any account debtor or third Person possessing such Collateral for the purpose of making such a verification. Out-of-pocket expenses in connection with any inspections by representatives of the Secured Parties shall be (a) the obligations of the Grantor with respect to any inspection after the Secured Parties’ demand payment of the Notes or (b) the obligation of the Secured Parties in any other case.

  • Examination of Implementation 1. Without prejudice to the procedures set out in Article 188 (Compensation), once the period of time set out in paragraph 3 of Article 186 (Implementation of the Report) has expired, and there is disagreement between the disputing Parties as to the existence or consistency of the measures taken to comply with the Panel report, such dispute shall be referred to the original Panel wherever possible. If not possible, the procedure pursuant to Article 179 (Panel Selection) shall be followed to appoint a new Panel, in which event the periods set out thereof shall be reduced by half (22). 2. This Panel shall issue its report on the matter within 60 days after the date of the referral of the matter to it. When the Panel considers that it cannot provide its report within this timeframe, it shall inform the Parties in writing of the reasons for the delay together with an estimate of the period within which it will submit its report. Any delay shall not exceed a further period of 30 days unless the Parties otherwise agree.

  • Audit and Testing 4.1 The Contractor shall conduct tests of the processes and countermeasures contained in the Security Plan ("Security Tests") on an annual basis or as otherwise agreed by the Parties. The date, timing, content and conduct of such Security Tests shall be agreed in advance with the Authority. 4.2 The Authority shall be entitled to send a representative to witness the conduct of the Security Tests. The Contractor shall provide the Authority with the results of such tests (in a form approved by the Authority in advance) as soon as practicable after completion of each Security Test. 4.3 Without prejudice to any other right of audit or access granted to the Authority pursuant to this Contract, the Authority shall be entitled at any time and without giving notice to the Contractor to carry out such tests (including penetration tests) as it may deem necessary in relation to the Security Plan and the Contractor's compliance with and implementation of the Security Plan. The Authority may notify the Contractor of the results of such tests after completion of each such test. Security Tests shall be designed and implemented so as to minimise the impact on the delivery Services. If such tests impact adversely on its ability to deliver the Services to the agreed Service Levels, the Contractor shall be granted relief against any resultant under-performance for the period of the tests. 4.4 Where any Security Test carried out pursuant to paragraphs 4.2 or 4.3 above reveals any actual or potential security failure or weaknesses, the Contractor shall promptly notify the Authority of any changes to the Security Plan (and the implementation thereof) which the Contractor proposes to make in order to correct such failure or weakness. Subject to the Authority's approval in accordance with paragraph 3.12, the Contractor shall implement such changes to the Security Plan in accordance with the timetable agreed with the Authority or, otherwise, as soon as reasonably possible. For the avoidance of doubt, where the change to the Security Plan to address a non-compliance with the Security Policy or security requirements, the change to the Security Plan shall be at no additional cost to the Authority. For the purposes of this paragraph 4, a weakness means a vulnerability in security and a potential security failure means a possible breach of the Security Plan or security requirements.

  • Inspection/Testing In order to assess Supplier’s work quality and/or compliance with this Order, upon reasonable notice by Buyer: (a) all goods, materials and services related to the items purchased hereunder, including, raw materials, components, assemblies, work in process, tools and end products shall be subject to inspection and testing by Buyer, its customer, representative or regulatory authorities at all places, including sites where the goods are made or located or the services are performed, whether at Supplier’s premises or elsewhere; and (b) all of Supplier’s facilities, books and records relating to this Order shall be subject to inspection by Buyer or its designee. If specific Buyer and/or Buyer’s customer tests, inspection and/or witness points are included in this Order, the goods shall not be shipped without an inspector’s release or a written waiver of test/inspection/witness with respect to each such point; however, Buyer shall not be permitted to unreasonably delay shipment; and Supplier shall notify Buyer in writing at least twenty (20) days prior to each of Supplier’s scheduled final and, if applicable, intermediate test/inspection/witness points. Supplier agrees to cooperate with such/audit inspection including, completing and returning questionnaires and making available its knowledgeable representatives. Buyer’s failure to inspect or test goods, materials or services or Buyer’s failure to reject or detect defects by inspection or testing shall not relieve Supplier from its warranty obligations or any of its other obligations or responsibilities under this Order. Supplier agrees to provide small business as well as minority and/or women owned business utilization and demographic data upon request.

  • Medical Examination Where the Employer requires an employee to submit to a medical examination or medical interview, it shall be at the Employer's expense and on the Employer's time.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!