OWNER'S RIGHT TO STOP SERVICE Sample Clauses

OWNER'S RIGHT TO STOP SERVICE. Owner reserves the right to stop the service of the heating, air conditioning, ventilating, elevator, plumbing, electrical or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are desirable or necessary, until said repairs, alterations, replacements or improvements shall have been completed. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant's business, or otherwise.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
OWNER'S RIGHT TO STOP SERVICE. Owner reserves the right to stop the service of the heating, air conditioning, ventilating, elevator, plumbing, electrical, communications or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are desirable or necessary, until said repairs, alterations, replacements or improvements shall have been completed. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant's business, or otherwise. Owner shall employ reasonable diligence in attempting to restore the operation of any such systems or facilities without any obligation, however, to employ labor at overtime or other premium pay rates.
Sample 1Sample 2
OWNER'S RIGHT TO STOP SERVICE. Owner reserves the right to stop the service of the heating, air conditioning, ventilating, elevator, plumbing, electrical or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are necessary, until said repairs, alterations, replacements or improvements shall have been completed. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconve nience or annoyance to Tenant, or injury to or interruption of Tenant's business, or otherwise. Owner shall employ reasonable diligence in attempting to restore the operation of any such system or facilities without any obligation, however, to employ labor at overtime or other premium pay rates, except that in cases where there is a material interference with Tenant's business or health or safety of the occupants of the Demised Premises is adversely affected, Owner shall employ contractors or labor at overtime or other premium pay rates.
Sample 1
OWNER'S RIGHT TO STOP SERVICE. Owner reserves the ----------------------------- right to stop the service of the HVAC, elevator, plumbing, electrical or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are desirable or necessary, until said repairs, alterations, replacements or improvements shall have been completed. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant's business, or otherwise. Owner shall employ reasonable diligence in attempting to restore the operation of such system or facilities including, where necessary, the employment of labor at overtime or other premium pay rates. Except in cases of emergency, Owner (i) agrees to give Tenant reasonable advance notice of any such stoppage, (ii) shall coordinate any such stoppage with Tenant In an attempt to minimize interference with Tenant's normal business operations and (iii) shall endeavor to schedule such stoppage only on those weekends or week nights upon which Owner and Tenant shall reasonably agree. If (i) by reason of an occurrence, other than such occurrences as are contemplated in Articles 9 and 10, which is an insured risk under any insurance policy carried by Owner (Owner covenants to maintain such insurance policy provided it is available at commercially reasonable rates), all or any portion of the Demised Premises is rendered untenantable for a period or more than ten (10) consecutive business days, and (ii) Owner is reimbursed under such policy for its loss of rent by reason of the rent abatement hereafter provided, the Fixed Rent and any increases therein allocable to such portion of the Demised Premises shall be abated for the period from the end of such ten (10) day period to and including the day immediately preceding the date upon which Tenant is able to use such portion of the Demised Premises. Owner agrees to use reasonable diligence to maintain a Boiler and Machinery insurance policy with business interruption covering throughout the Demised Term. Owner agrees to use reasonable diligence in making any repairs, alterations, replacements or impr...
Sample 1
OWNER'S RIGHT TO STOP SERVICE. Owner reserves the right to stop the service of the heating, air conditioning, ventilating, elevator, plumbing, electrical or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are desirable or necessary, until said repairs, alterations, replacements or improvements shall have been completed. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant’s business, or otherwise. Owner agrees to use reasonable efforts to restore any interrupted services, without any obligation, however, to employ labor at overtime or other premium pay rates.
Sample 1
OWNER'S RIGHT TO STOP SERVICE. Owner reserves the right to stop the service of the heating, air conditioning, ventilating, elevator, plumbing, electrical or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are desirable or necessary, until said repairs, alterations, replacements or improvements shall have been completed. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant's business, or otherwise. Owner agrees to use reasonable efforts to restore any interrupted services, without any obligation, however, to employ labor at overtime or other premium pay rates, except that Owner shall employ labor at such overtime or other premium pay rates in cases where the health or safety of any occupants of the Demised Premises is adversely affected. If practicable, Owner shall attempt to advise Tenant as to the estimated length of time of any such interruption of services.
Sample 1
OWNER'S RIGHT TO STOP SERVICE. Owner reserves the right to stop the service of the heating, air conditioning, ventilating, elevator, plumbing, electrical, communications or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are desirable or necessary, until said repairs, alterations, replacements or improvements shall have been completed. Except in an emergency for which no notice is required, Owner shall provide Tenant with reasonable advance notice of same. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant's business, or otherwise. Owner shall employ reasonable diligence in attempting to restore the operation of any such systems or facilities without any obligation, however, to employ labor at overtime or other premium pay rates.
Sample 1
AutoNDA by SimpleDocs
OWNER'S RIGHT TO STOP SERVICE. Owner reserves the right to stop the service of the HVAC, elevator, plumbing, electrical or other mechanical systems or facilities in the Building when necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements, which, in the judgment of Owner are desirable or necessary, until said repairs, alterations, replacements or improvements shall have been completed. The exercise of such right by Owner shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of rent, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Owner or its agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant’s business, or otherwise. Except in cases of emergency, Owner agrees to give Tenant reasonable advance notice of any such stoppage, including the estimated duration thereof. Owner agrees to use reasonable efforts to restore any interrupted services as soon as reasonably practicable, without any obligation, however, to employ labor at overtime or other premium pay rates. 
Sample 1

Related to OWNER'S RIGHT TO STOP SERVICE

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.

  • OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.

  • Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.

  • BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.

  • HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.

  • Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing. 2.1.2 The Train Operator may serve a Suspension Notice where a Network Rail Event of Default has occurred and is continuing.

  • Right to Grieve Where an employee feels that she has been aggrieved by a decision of the Employer related to promotion, demotion or transfer, the employee may grieve the decision at Step 3 of the grievance procedure in Article 9 of this Agreement within seven (7) days of being notified of the results.

  • Right to Seek Assurance The Transfer Agent may refuse to transfer, exchange or redeem shares of the Fund or take any action requested by a shareholder until it is satisfied that the requested transaction or action is legally authorized or until it is satisfied there is no basis for any claims adverse to the transaction or action. It may rely on the provisions of the Uniform Act for the Simplification of Fiduciary Security Transfers or the Uniform Commercial Code. The Company shall indemnify the Transfer Agent for any act done or omitted to be done in reliance on such laws or for refusing to transfer, exchange or redeem shares or taking any requested action if it acts on a good faith belief that the transaction or action is illegal or unauthorized.

  • Lessor's Right to Perform for Lessee If Lessee fails to make any payment of Rent required to be made by it hereunder or fails to perform or comply with any of its agreements contained herein, then (but in each case, except in the case of failure to pay Rent or in the case of failure to maintain insurance as required hereunder, no earlier than the fifteenth day after the occurrence of such failure, whether or not it shall yet constitute an Event of Default hereunder) Lessor may itself make such payment or perform or comply with such agreement but shall not be obligated hereunder to do so, and the amount of such payment and the amount of the reasonable expenses of Lessor incurred in connection with such payment or the performance of or compliance with such agreement, as the case may be, together with interest thereon at the Past Due Rate, shall be deemed Supplemental Rent, payable by Lessee upon demand.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!