OWNER'S INITIAL CONSTRUCTION Sample Clauses

OWNER'S INITIAL CONSTRUCTION. SECTION 12.01. Owner agrees to perform work and make installations in the Demised Premises as set forth in Addendum A. Such work and installations are referred to as "Owner's Initial Construction". All of the terms, covenants and conditions of Addendum A are incorporated in this Lease by reference and shall be deemed a part of this Lease as though fully set forth in the body of this Lease.
Sample 1Sample 2
AutoNDA by SimpleDocs
OWNER'S INITIAL CONSTRUCTION. [Alt.-- Existing Conditions/Owner's Initial Work] ARTICLE 13 Access to Demised Premises ARTICLE 14 Vault Space ARTICLE 15 Certificate of Occupancy ARTICLE 16 Default ARTICLE 17 Remedies ARTICLE 18 Damages ARTICLE 19 Fees and Expenses; Indemnity ARTICLE 20 Entire Agreement ARTICLE 21 End Of Term ARTICLE 22 Quiet Enjoyment ARTICLE 23 Escalation ARTICLE 24 No Waiver ARTICLE 25 Mutual Waiver of Trial by Jury ARTICLE 26 Inability to Perform ARTICLE 27 Notices ARTICLE 28 Partnership Tenant ARTICLE 29 Utilities and Services ARTICLE 30 Table of Contents, Etc. ARTICLE 31 Miscellaneous Definitions, Severability and Interpretation Provisions ARTICLE 32 Adjacent Excavation ARTICLE 33 Building Rules ARTICLE 34 Broker ARTICLE 35 Security ARTICLE 36 Arbitration, Etc. ARTICLE 37 Parties Bound ARTICLE 38 Deleted ARTICLE 39 Renewal Option ARTICLE 40 Tenant's Right of First Offer for Additional Space ARTICLE 41 Tenant's Single Termination Option ARTICLE 42 Satellite Dish SCHEDULE A Building Rules ADDENDUM A Owner's Initial Construction
Sample 1
OWNER'S INITIAL CONSTRUCTION. I. (A) Subject to the terms and conditions of this Addendum A, Owner agrees to supply and install in the Demised Premises all of the items set forth on Tenant's Plans referred to in Paragraph IV of this Addendum A, as it may be modified to reflect any Change Work (as defined in Paragraph IV), unless prevented by job conditions or other circumstances beyond the reasonable control of Owner or unless variations thereto are necessary to comply with Legal Requirements (such work and installations are referred to herein as "Owner's Initial Construction"). It is understood that in addition, as part of Owner's Initial Construction, Owner shall also (i) demolish the existing installations within the Demised Premises and xxxxx all known asbestos within the Demised Premises (the "Demolition and Abatement Work"); (ii) repair or replace the HVAC controls in the Demised Premises as Owner shall deem reasonably necessary to render same in good working order (the "HVAC Control Work"); and (iii) furnish and install one (1) Building standard unisex bathroom in the Demised Premises in a location to be determined by Owner which shall comply with the requirements of the Americans with Disabilities Act (such installation is referred to as "Owner's ADA Bathroom Work"). Tenant acknowledges that Owner has advised Tenant that the Demised Premises are presently affected by a letting agreement with Xxxxxx Communications Inc. (referred to as the "Present Occupant") with whom Owner is currently negotiating a surrender agreement affecting the Demised Premises, Owner agrees that Owner shall reasonably promptly commence performance of Owner's Initial Construction following the date on which the Present Occupant shall vacate and surrender possession of the Demised Premises to Owner in accordance with Owner's surrender agreement with the Present Occupant.
Sample 1

Related to OWNER'S INITIAL CONSTRUCTION

  • Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Legal Construction In the event that any one or more of the terms, provisions, or agreements that are contained in this Agreement shall be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable in any respect for any reason, the invalid, illegal, or unenforceable term, provision, or agreement shall not affect any other term, provision, or agreement that is contained in this Agreement and this Agreement shall be construed in all respects as if the invalid, illegal, or unenforceable term, provision, or agreement had never been contained herein.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).

  • Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and

  • Completion of Construction (a) For the purposes of this Agreement, the terms "

  • Specific Shall Not Limit General; Construction No specific provision contained in this Note shall limit or modify any more general provision contained herein. This Note shall be deemed to be jointly drafted by the Company and the Holder and shall not be construed against any person as the drafter hereof.

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • General Construction Principles Words in any gender are deemed to include the other genders. The singular is deemed to include the plural and vice versa. The headings and underlined paragraph titles are for guidance only and have no significance in the interpretation of this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.