Performance Letter of Credit Sample Clauses

Performance Letter of Credit. Any Letter of Credit issued to support contractual obligations for supply, service or construction contracts, including, but not limited to, bid, performance, advance payment, warranty, retention, availability and defects liability obligations. Permitted Liens. Liens permitted by §9.2.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Performance Letter of Credit. A Letter of Credit which is not a Financial Letter of Credit.
Sample 1Sample 2Sample 3
Performance Letter of Credit. (a) As security for Design-Builder’s warranty obligations during the Warranty Period, Design- Builder shall deliver, or cause to be delivered, to the City no later than Construction Completion, one or more irrevocable letters of credit (the “Performance Letter of Credit”) substantially in the form of Schedule 30 [Letter of Credit]. The Performance Letter of Credit shall be in an aggregate amount equal to thirty million dollars ($30,000,000) (the “Required Amount”). The Required Amount shall be reduced to an aggregate amount equal to $10 million dollars ($10,000,000) and the Performance Letter of Credit will be reduced accordingly after two years have passed from the Construction Completion Date. The City shall, upon receipt of a written request from Design-Builder, after two years have passed from the Construction Completion Date, provide written notice to Design-Builder and the institution issuing the Performance Letter of Credit to reduce the Performance Letter of Credit to such reduced Required Amount. (b) The Performance Letter of Credit must be issued by a Permitted Letter of Credit Provider. Design-Builder may at any time replace or substitute the Performance Letter of Credit with another letter of credit issued by any one or more Permitted Letter of Credit Provider(s) and in a form acceptable to and approved by the City, acting reasonably. (c) In the event that the Performance Letter of Credit must be renewed at any time, Design- Builder agrees to provide to the City reasonable evidence of the renewal of such Performance Letter of Credit no later than 10 Business Days prior to the renewal date, if any, of such Performance Letter of Credit. (d) In the event that Design-Builder does not deliver the Performance Letter of Credit in accordance with Section 20.4(a), the City may withhold from any amount otherwise due to Design-Builder by the City, including without limitation, any release of the Construction Completion Payment, an amount equal to the Required Amount (the “Performance Letter of Credit Holdback”), which holdback shall be held in an interest bearing account until such time as Design-Builder delivers the Performance Letter of Credit. (e) The City shall release the Performance Letter of Credit Holdback, less the amount of any claims previously satisfied by a draw in accordance with Section 20.4(f) and together with all interest accrued thereon, no later than five days following delivery of the Performance Letter of Credit to the City.
Sample 1
Performance Letter of Credit. In addition to the Security Deposit, Lessee shall deliver to Lessor, on or before the Commencement Date, an additional amount to secure the performance of Lessee's obligations under the Lease, according to the following schedule for each Lease year (the "Additional Security"): Lease Year Amount 1 $ 180,000.00 2 $ 144,000.00 3 $ 108,000.00 4 $ 72,000.00 5 $ 36,000.00 The Additional Security may be in the form of cash or a letter of credit (the "Performance Letter of Credit"). If the Additional Security is in the form of the Performance Letter of Credit, the following terms and conditions shall apply: (a) such letter of credit shall be issued by a financial institution satisfactory to Lessor, and the Performance Letter of Credit shall otherwise be in form and substance satisfactory to Lessor, provided, without limiting the generality of the foregoing, payment under the Performance Letter of Credit shall be conditional only on Lessor's certification that a default has occurred under the Lease, including, without limitation, a failure of Lessee to deliver a replacement Performance Letter of Credit when required under this Section 5.1; (b) the term of the Performance Letter of Credit shall be twelve (12) months (the "Minimum Term") beginning on the Commencement Date, and Lessee shall, sixty (60) days prior to the expiration of the term of the relevant Performance Letter of Credit, replace the Performance Letter of Credit with a letter of credit meeting the requirements of this Section 5.1 that shall be for a term at least equal to the Minimum Term; and
Sample 1
Performance Letter of Credit. Within 30 days following the Effective Date, Contractor shall provide to Owner a Performance Letter of Credit (“Performance LOC”) substantially in the form of Exhibit U and in an amount equal to twenty percent (20%) of the Contract Price. The Performance LOC shall remain in full force and effect until Contractor has achieved Unit 2 Provisional Acceptance.
Sample 1
Performance Letter of Credit. At Financing/Construction Closing, Developer shall deliver to District an Acceptable Letter of Credit in the amount of One Hundred Thousand Dollars ($100,000) (the “Performance Letter of Credit”) to secure Developer’s performance of the obligations contained in the Construction and Use Covenant, whereupon the Project Deposit and the Acquisition Closing Letter of Credit shall be returned to Developer.‌
Sample 1
Performance Letter of Credit. A Letter of Credit under which the event ---------------------------- which triggers payment is performance-related, such as failure to ship a product or provide a service, and not financial, such as the failure to pay money, as set forth in greater detail in the letter dated March 30, 1995 from the Board of Governors of the Federal Reserve System attached hereto as Exhibit J or in any applicable directive or letter ruling of the Board of Governors of the Federal Reserve System issued subsequent thereto.
Sample 1
AutoNDA by SimpleDocs
Performance Letter of Credit. A Letter of Credit which is not a Financial Letter of Credit. Permitted Liens. See s. 8.2.
Sample 1

Related to Performance Letter of Credit

  • Letter of Credit The Borrower further agrees with the Issuing Lender, the Administrative Agent and the Lenders that the Issuing Lender, the Administrative Agent and the Lenders shall not be responsible for, and the Borrower's Reimbursement Obligations under Section 4.2 shall not be affected by, among other things, the validity or genuineness of documents or of any endorsements thereon even if such documents should in fact prove to be in any or all respects invalid, fraudulent or forged, or any dispute between or among the Borrower, the beneficiary of any Letter of Credit or any financing institution or other party to which any Letter of Credit may be transferred or any claims or defenses whatsoever of the Borrower against the beneficiary of any Letter of Credit or any such transferee, PROVIDED that the Borrower shall not be responsible for, and the Borrower's Reimbursement Obligations shall not include, amounts or liabilities arising solely from the gross negligence or willful misconduct of the Issuing Lender in determining whether a request presented under any Letter of Credit complied with the terms of such Letter of Credit. The Issuing Lender, the Administrative Agent and the Lenders shall not be liable for any error, omission, interruption or delay in transmission, dispatch or delivery of any message or advice, however transmitted, in connection with any Letter of Credit. The Borrower agrees that any action taken or omitted by the Issuing Lender, the Administrative Agent or any Lender under or in connection with each Letter of Credit and the related drafts and documents, if done in good faith, shall be binding upon the Borrower and shall not result in any liability on the part of the Issuing Lender, the Administrative Agent or any Lender to the Borrower.

  • Letter of Credit Request See §2.10(a).

  • The Letter of Credit Facility (i) Subject to the terms and conditions hereinafter set forth (A) Issuing Bank agrees, in reliance on the Agreements of the Lenders set forth in this Section (1) to issue Letters of Credit for the account of any Borrower from time to time on any Business Day during the period from the Effective Date hereof until 10 days before the Termination Date in an aggregate Available Amount for all Letters of Credit not to exceed at any time the lesser of (x) the Letter of Credit Facility at such time and (y) the Unused Revolving Credit Commitments of the Lenders at such time (provided that in no event shall the Issuing Bank be required to issue a Letter of Credit if, after giving effect to such issuance, the aggregate amount of the Revolving Credit Exposures of all Lenders shall exceed the Revolving Credit Availability at such time) and to amend or extend Letters of Credit previously issued by it in accordance with the terms of this Section 2.16, and (2) to honor drawings under the Letters of Credit, and (B) the Lenders severally agree to participate in Letters of Credit issued for the account of any Borrower and any drawings thereunder. Each request by a Borrower for the issuance or amendment of a Letter of Credit shall be deemed to be a representation by the Borrowers that the issuance, extension or amendment of the Letter of Credit so requested complies with the conditions set forth in the preceding sentence. Within the foregoing limits, and subject to the terms and conditions hereof, each Borrower’s ability to obtain Letters of Credit shall be fully revolving, and accordingly such Borrower may, during the foregoing period, obtain Letters of Credit to replace Letters of Credit that have expired or that have been drawn upon and reimbursed. (ii) No Letter of Credit shall have an expiration date (including all rights of the applicable Borrower or the beneficiary to require renewal) later than the earlier of (A) 10 days before the Termination Date and (B) one year after the date of issuance thereof (but such Letter of Credit may by its terms be automatically renewable (each, an “Auto-Extension Letter of Credit”); provided that any such Auto-Extension Letter of Credit must permit the Issuing Bank to prevent any such extension at least once in each twelve (12) month period (commencing with the date of issuance of such Letter of Credit) by giving prior notice to the beneficiary thereof not later than a day (the “Non-Extension Notice Date”) in each such twelve (12) month period to be agreed upon at the time such Letter of Credit is issued. Unless otherwise directed by the Issuing Bank, the applicable Borrower shall not be required to make a specific request to the Issuing Bank for any such extension. Once an Auto-Extension Letter of Credit has been issued, the Lenders shall be deemed to have authorized (but may not require) the Issuing Bank to permit the extension of such Letter of Credit at any time to an expiry date not later than the date 10 days before the Termination Date; provided that the Issuing Bank shall not permit any such extension if (A) the Issuing Bank has determined that it would not be permitted, or would have no obligation at such time to issue such Letter of Credit in its revised form (as extended) under the terms hereof (by reason of the provisions of this Section 2.16 or otherwise), or (B) it has received notice (which may be by telephone or in writing) on or before the day that is seven (7) Business Days before the Non-Extension Notice Date (1) from the Agent that the Required Lenders have elected not to permit such extension or (2) from the Agent, any Lender or a Borrower that one or more of the applicable conditions specified in Section 3.02 is not then satisfied, and in each such case directing the Issuing Bank not to permit such extension. (iii) The Issuing Bank shall not be under any obligation to issue any Letter of Credit if: (A) any order, judgment or decree of any Governmental Authority or arbitrator shall by its terms purport to enjoin or restrain the Issuing Bank from issuing the Letter of Credit, or any law applicable to the Issuing Bank or any request or directive (whether or not having the force of law) from any Governmental Authority with jurisdiction over the Issuing Bank shall prohibit, or request that the Issuing Bank refrain from, the issuance of letters of credit generally or the Letter of Credit in particular or shall impose upon the Issuing Bank with respect to the Letter of Credit any restriction, reserve or capital requirement (for which the Issuing Bank is not otherwise compensated hereunder) not in effect on the Effective Date, or shall impose upon the Issuing Bank any unreimbursed loss, cost or expense which was not applicable on the Effective Date and which the Issuing Bank in good xxxxx xxxxx material to it; (B) the issuance of the Letter of Credit would violate one or more policies of the Issuing Bank applicable to letters of credit generally; (C) except as otherwise agreed by the Agent and the Issuing Bank, the Letter of Credit is in an initial stated amount of less than $100,000; (D) the Letter of Credit is to be denominated in a currency other than Dollars; (E) any Lender is at that time a Defaulting Lender, unless the Issuing Bank has entered into arrangements, including the delivery of Cash Collateral, satisfactory to the Issuing Bank (in its sole discretion) with the Borrowers or such Lender to eliminate the Issuing Bank’s actual or potential Fronting Exposure (after giving effect to Section 2.23(a)(iv)) with respect to the Defaulting Lender arising from either the Letter of Credit then proposed to be issued or that Letter of Credit and all other L/C Exposure as to which the Issuing Bank has actual or potential Fronting Exposure, as it may elect in its sole discretion; or (F) the Letter of Credit contains any provisions for automatic reinstatement of the stated amount after any drawing thereunder. (iv) The Issuing Bank shall not amend any Letter of Credit if the Issuing Bank would not be permitted at such time to issue the Letter of Credit in its amended form under the terms hereof. (v) The Issuing Bank shall be under no obligation to amend any Letter of Credit if (A) the Issuing Bank would have no obligation at such time to issue such Letter of Credit in its amended form under the terms hereof, or (B) the beneficiary of such Letter of Credit does not accept the proposed amendment to the Letter of Credit. (vi) The Issuing Bank shall act on behalf of the Lenders with respect to any Letters of Credit issued by it and the documents associated therewith, and the Issuing Bank shall have all of the benefits and immunities (A) provided to the Agent in Article VII with respect to any acts taken or omissions suffered by the Issuing Bank in connection with Letters of Credit issued by it or proposed to be issued by it and L/C Related Documents pertaining to such Letters of Credit as fully as if the term “Agent” as used in Article VII included the Issuing Bank with respect to such acts or omissions, and (B) as additionally provided herein with respect to the Issuing Bank.

  • Letter of Credit Payments If any draft shall be presented for payment under any Letter of Credit, the Issuing Lender shall promptly notify the Borrower of the date and amount thereof. The responsibility of the Issuing Lender to the Borrower in connection with any draft presented for payment under any Letter of Credit shall, in addition to any payment obligation expressly provided for in such Letter of Credit, be limited to determining that the documents (including each draft) delivered under such Letter of Credit in connection with such presentment are substantially in conformity with such Letter of Credit.

  • The Letter of Credit Subfacility (a) On the terms and conditions set forth herein (i) the Issuer agrees (and each Revolving Lender acknowledges that such agreement is made in reliance upon the agreements of the Revolving Lenders set forth in this Article III), (A) from time to time on any Business Day, during the period from the Effective Date to the day which is five days prior to the Revolving Termination Date, to Issue Letters of Credit for the account of the Borrower (or jointly for the account of the Borrower and any of its Subsidiaries) in an aggregate Outstanding Amount at any one time that, together with the aggregate Outstanding Amount of all other outstanding Letters of Credit issued pursuant hereto (including the Existing Letters of Credit), does not exceed the L/C Commitment, and to amend or renew Letters of Credit previously issued by it, in accordance with Sections 3.02(c) and 3.02(d), and (B) to honor drafts under the Letters of Credit; and (ii) the Revolving Lenders severally agree to participate in Letters of Credit (including the Existing Letters of Credit); provided that no Issuer shall be obligated to Issue, and no Revolving Lender shall be obligated to participate in, any Letter of Credit if as of the date of Issuance of such Letter of Credit (the “Issuance Date”) (1) the Outstanding Amount of all L/C Obligations, plus the Outstanding Amount of all Revolving Loans and Swing Line Loans exceeds the Aggregate Revolving Commitment or (2) the participation of any Revolving Lender in the Outstanding Amount of all L/C Obligations plus the principal amount of the Revolving Loans of such Revolving Lender and such Revolving Lender’s Revolving Percentage of the Outstanding Amount of Swing Line Loans exceeds such Lender’s Revolving Commitment. Within the foregoing limits, and subject to the other terms and conditions hereof, the Borrower’s ability to obtain Letters of Credit shall be fully revolving, and, accordingly, the Borrower may, during the foregoing period, obtain Letters of Credit to replace Letters of Credit which have expired or which have been drawn upon and reimbursed. Each of the Existing Letters of Credit shall be deemed to be Letters of Credit Issued hereunder on the Effective Date. (b) No Issuer shall issue any Letter of Credit if: (i) subject to Section 3.02(d), the expiry date of the requested Letter of Credit would occur more than twelve months after the date of issuance or last extension, unless the Required Revolving Lenders have approved such expiry date; or (ii) the expiry date of the requested Letter of Credit would occur after the Revolving Maturity Date, unless (x) all the Revolving Lenders and the Issuer have approved such expiry date or (y) such Letter of Credit is cash collateralized or becomes a Supported Letter of Credit on terms and pursuant to arrangements satisfactory to the Issuer. (c) No Issuer shall be under any obligation to Issue any Letter of Credit if: (i) any order, judgment or decree of any Governmental Authority or arbitrator shall by its terms purport to enjoin or restrain such Issuer from Issuing such Letter of Credit, or any Requirement of Law applicable to such Issuer or any request or directive (whether or not having the force of law) from any Governmental Authority with jurisdiction over such Issuer shall prohibit, or request that such Issuer refrain from, the Issuance of letters of credit generally or such Letter of Credit in particular or shall impose upon such Issuer with respect to such Letter of Credit any restriction, reserve or capital requirement (for which such Issuer is not otherwise compensated hereunder) not in effect on the Effective Date, or shall impose upon such Issuer any unreimbursed loss, cost or expense which was not applicable on the Effective Date and which such Issuer in good xxxxx xxxxx material to it; (ii) such Issuer has received written notice from any Revolving Lender, the Agent or the Borrower, on or prior to the Business Day prior to the requested date of Issuance of such Letter of Credit, that one or more of the applicable conditions contained in Article V is not then satisfied; (iii) any requested Letter of Credit does not provide for drafts, or is not otherwise in form and substance acceptable to such Issuer, or the Issuance of a Letter of Credit shall violate any applicable policies of such Issuer; (iv) such Letter of Credit is to be denominated in a currency other than Dollars; or (v) any Revolving Lender is at that time a Defaulting Lender, unless the Issuer has entered into arrangements, including the delivery of Cash Collateral, with the Borrower or such Revolving Lender to eliminate the Issuer’s actual or potential Fronting Exposure (after giving effect to Section 3.11(a)(iv)) with respect to the Defaulting Lender arising from either the Letter of Credit then proposed to be issued or that Letter of Credit and all other L/C Obligations as to which the Issuer has actual or potential Fronting Exposure, as it may elect in its sole discretion. (d) Each Issuer shall act on behalf of the Revolving Lenders with respect to any Letters of Credit Issued by it and the documents associated therewith, and the Issuer shall have all of the benefits and immunities (A) provided to the Agent in Article X with respect to any acts taken or omissions suffered by the Issuer in connection with Letters of Credit Issued by it or proposed to be Issued by it and Issuer Documents pertaining to such Letters of Credit as fully as if the term “Agent” as used in Article X included the Issuer with respect to such acts or omissions, and (B) as additionally provided herein with respect to the Issuer.

  • Compensation for Facility Letters of Credit (a) The Borrower shall pay to the Administrative Agent, for the ratable account of the Lenders (including the Issuing Bank), based upon the Lenders’ respective Percentages, a per annum fee (the “Facility Letter of Credit Fee”) as a percentage of the face amount of each Facility Letter of Credit outstanding equal to the LIBOR Applicable Margin in effect from time to time hereunder while such Facility Letter of Credit is outstanding. The Facility Letter of Credit Fee relating to any Facility Letter of Credit shall accrue on a daily basis and shall be due and payable in arrears on the first Business Day of each calendar quarter following the issuance of such Facility Letter of Credit and, to the extent any such fees are then due and unpaid, on the Facility Termination Date or any other earlier date that the Obligations are due and payable in full. The Administrative Agent shall promptly (on the same day as received by the Administrative Agent if received prior to noon (Cleveland time) on such day and otherwise on the next Business Day) remit such Facility Letter of Credit Fees, when paid, to the other Lenders in accordance with their Percentages thereof. The Borrower shall not have any liability to any Lender for the failure of the Administrative Agent to promptly deliver funds to any such Lender and shall be deemed to have made all such payments on the date the respective payment is made by the Borrower to the Administrative Agent, provided such payment is received by the time specified in Section 2.13 hereof. (b) The Issuing Bank also shall have the right to receive solely for its own account an issuance fee equal to the greater of (A) $1,500 or (B) one-eighth of one percent (0.125%) per annum to be calculated on the face amount of each Facility Letter of Credit for the stated duration thereof, based on the actual number of days and using a 360-day year basis. The issuance fee shall be payable by the Borrower on the Issuance Date for each such Facility Letter of Credit and on the date of any increase therein or extension thereof. The Issuing Bank shall also be entitled to receive its reasonable out-of-pocket costs and the Issuing Bank’s standard charges of issuing, amending and servicing Facility Letters of Credit and processing draws thereunder.

  • Letter of Credit Subfeature As a subfeature under the Line of Credit, Bank agrees from time to time during the term thereof to issue or cause an affiliate to issue commercial and standby letters of credit for the account of Borrower (each, a “Letter of Credit” and collectively, “Letters of Credit”); provided however, that the aggregate undrawn amount of all outstanding Letters of Credit shall not at any time exceed Fifteen Million Dollars ($15,000,000.00). The form and substance of each Letter of Credit shall be subject to approval by Bank, in its sole discretion. Each Letter of Credit shall be issued for a term not to exceed three hundred sixty-five (365) days, as designated by Borrower; provided however, that no Letter of Credit shall have an expiration date more than one hundred twenty (120) days beyond the maturity date of the Line of Credit. The undrawn amount of all Letters of Credit shall be reserved under the Line of Credit and shall not be available for borrowings thereunder. Each Letter of Credit shall be subject to the additional terms and conditions of the Letter of Credit agreements, applications and any related documents required by Bank in connection with the issuance thereof. Each drawing paid under a Letter of Credit shall be deemed an advance under the Line of Credit and shall be repaid by Borrower in accordance with the terms and conditions of this Agreement applicable to such advances; provided however, that if advances under the Line of Credit are not available, for any reason, at the time any drawing is paid, then Borrower shall immediately pay to Bank the full amount drawn, together with interest thereon from the date such drawing is paid to the date such amount is fully repaid by Borrower, at the rate of interest applicable to advances under the Line of Credit. In such event Borrower agrees that Bank, in its sole discretion, may debit any account maintained by Borrower with Bank for the amount of any such drawing.

  • Letter of Credit Facility (a) Subject to and upon the terms and conditions herein set forth, each L/C Account Party, or Interface on behalf of any L/C Account Party, may request, in accordance with the provisions of this Article IIA, that, on and after the Restatement Date, the Domestic L/C Issuer issue one or more Domestic Letters of Credit for the account of such L/C Account Party; provided, however, that any Letter of Credit to be so issued shall conform to the following conditions and requirements: (i) The Letter of Credit shall be in a form customarily used by the L/C Issuer or in any other form requested by the L/C Account Party and approved by the L/C Issuer; (ii) No Letter of Credit shall have an expiration date later than one year from the date of issuance thereof, and no Letter of Credit shall have an expiration date later than the fifth (5th) Business Day prior to the Maturity Date, regardless of its date of issuance; (iii) [Intentionally omitted]; (iv) No Letter of Credit shall be requested or issued having a stated amount less than $250,000; (v) No Letter of Credit shall be requested or issued if, after giving effect to such issuance, the aggregate outstanding principal amount of all Extensions of Credit would exceed the aggregate amount of all Lenders’ Domestic Syndicated Loan Commitments; (vi) No Domestic Letter of Credit shall be requested or issued if, after giving effect to such issuance the Aggregate Domestic L/C Outstandings would exceed the lesser of (A) the Domestic Borrowing Limit, minus the amount of all outstanding Domestic Revolving Loans and (B) the aggregate Domestic L/C Subcommitments; (vii) [Intentionally Omitted]; (viii) [Intentionally Omitted]; and (ix) Any such Letter of Credit shall be subject to the Uniform Customs and/or ISP98 (or any other customary set of rules, regulations, or standards adopted and employed by the L/C Issuer in its customary practices), as set forth in the application for such Letter of Credit or other applicable law as determined by the L/C Issuer. Upon expiration or termination of the Domestic Syndicated Loan Commitments, the foregoing Domestic Letter of Credit facility shall automatically expire or terminate, as the case may be, without further action or notice hereunder. (b) Each Letter of Credit may provide that the L/C Issuer may (but shall not be required to), upon the occurrence of an Event of Default and the acceleration of the maturity of the Loans, or the exercise of any remedies set forth in Article IX, pay the beneficiary thereof or, if payment is not then due to the beneficiary, provide for the deposit of funds in an account to secure payment to the beneficiary and that any funds so deposited shall be paid to the beneficiary of the Letter of Credit if conditions to such payment are satisfied, or returned to the L/C Issuer for distribution to the Domestic Agent (or, if all Obligations shall have been indefeasibly paid in full, to the applicable L/C Account Party) if no payment to the beneficiary has been made and the final date available for drawings under the Letter of Credit has passed. Each payment or deposit of funds as provided in this Section 2A.01(b) shall be treated for all purposes of this Agreement as a drawing duly honored by the L/C Issuer under the related Letter of Credit.

  • Letter of Credit Requests (a) Whenever the Borrower desires that a Letter of Credit be issued for its account or amended, it shall give the Administrative Agent and the Letter of Credit Issuer a Letter of Credit Request by no later than 1:00 p.m. (New York City time) at least two (or such lesser number as may be agreed upon by the Administrative Agent and the Letter of Credit Issuer) Business Days prior to the proposed date of issuance or amendment. Each notice shall be executed by the Borrower and shall be in the form of Exhibit G to the Original Credit Agreement (each a “Letter of Credit Request”). (b) In the case of a request for an initial issuance of a Letter of Credit, such Letter of Credit Request shall specify in form and detail satisfactory to the Letter of Credit Issuer: (A) the proposed issuance date of the requested Letter of Credit (which shall be a Business Day)); (B) the Stated Amount thereof in the relevant currency; (C) the expiry date thereof; (D) the name and address of the beneficiary thereof; (E) the documents to be presented by such beneficiary in case of any drawing thereunder; (F) the full text of any certificate to be presented by such beneficiary in case of any drawing thereunder and (G) such other matters as the Letter of Credit Issuer may reasonably require. In the case of a request for an amendment of any outstanding Letter of Credit, such Letter of Credit Request shall specify in form and detail satisfactory to the Letter of Credit Issuer (A) the Letter of Credit to be amended; (B) the proposed date of amendment thereof (which shall be a Business Day); (C) the nature of the proposed amendment; and (D) such other matters as the Letter of Credit Issuer may reasonably require. Additionally, the Borrower shall furnish to the Letter of Credit Issuer and the Administrative Agent such other documents and information pertaining to such requested Letter of Credit issuance or amendment, including any Issuer Documents, as the Letter of Credit Issuer or the Administrative Agent may require. (c) Promptly after receipt of any Letter of Credit Request, the Letter of Credit Issuer will confirm with the Administrative Agent (by telephone or in writing) that the Administrative Agent has received a copy of such Letter of Credit Request from the Borrower and, if not, the Letter of Credit Issuer will provide the Administrative Agent with a copy thereof. Unless the Letter of Credit Issuer has received written notice from any Revolving Credit Lender, the Administrative Agent or any Credit Party, at least one Business Day prior to the requested date of issuance or amendment of the applicable Letter of Credit, that one or more applicable conditions contained in Sections 6 and 7 shall not then be satisfied, then, subject to the terms and conditions hereof, the Letter of Credit Issuer shall, on the requested date, issue a Letter of Credit for the account of the Borrower (or the applicable Restricted Subsidiary) or enter into the applicable amendment, as the case may be, in each case in accordance with the Letter of Credit Issuer’s usual and customary business practices. (d) If the Borrower so requests in any applicable Letter of Credit Request, the Letter of Credit Issuer may, in its sole and absolute discretion, agree to issue a Letter of Credit that has automatic extension provisions (each, an “Auto-Extension Letter of Credit”); provided that any such Auto-Extension Letter of Credit must permit the Letter of Credit Issuer to prevent any such extension at least once in each twelve-month period (commencing with the date of issuance of such Letter of Credit) by giving prior notice to the beneficiary thereof not later than a day (the “Non-Extension Notice Date”) in each such twelve-month period to be agreed upon at the time such Letter of Credit is issued. Unless otherwise directed by the Letter of Credit Issuer, the Borrower shall not be required to make a specific request to the Letter of Credit Issuer for any such extension. Once an Auto-Extension Letter of Credit has been issued, the Lenders shall be deemed to have authorized (but may not require) the Letter of Credit Issuer to permit the extension of such Letter of Credit at any time to an expiry date not later than the L/C Maturity Date; provided, however, that the Letter of Credit Issuer shall not permit any such extension if (A) the Letter of Credit Issuer has determined that it would not be permitted, or would have no obligation, at such time to issue such Letter of Credit in its revised form (as extended) under the terms hereof (by reason of the provisions of clause (b) of Section 3.1 or otherwise), or (B) it has received notice (which may be by telephone or in writing) on or before the day that is five Business Days before the Non-Extension Notice Date (1) from the Administrative Agent that the Required Revolving Credit Lenders have elected not to permit such extension or (2) from the Administrative Agent, any Lender or the Borrower that one or more of the applicable conditions specified in Sections 6 and 7 are not then satisfied, and in each such case directing the Letter of Credit Issuer not to permit such extension. (e) Promptly after its delivery of any Letter of Credit or any amendment to a Letter of Credit (including any Existing Secured Letter of Credit) to an advising bank with respect thereto or to the beneficiary thereof, the Letter of Credit Issuer will also deliver to the Borrower and the Administrative Agent a true and complete copy of such Letter of Credit or amendment. On the last Business Day of each month, each Letter of Credit Issuer shall provide the Administrative Agent a list of all Letters of Credit (including any Existing Secured Letter of Credit) issued by it that are outstanding at such time. (f) The making of each Letter of Credit Request shall be deemed to be a representation and warranty by the Borrower that the Letter of Credit may be issued in accordance with, and will not violate the requirements of, Section 3.1(b).

  • Letter of Credit Draw If (1) the Trustee shall have delivered a Demand Notice as provided in Section 3.5(b)(iii) of this Series Supplement and Hertz shall have failed to pay to the Trustee or deposit into the Series 2009-1 Distribution Account the amount specified in such Demand Notice in whole or in part by 12:00 noon (New York City time) on the Business Day following the making of the Demand Notice, (2) due to the occurrence of an Event of Bankruptcy (or the occurrence of an event described in clause (a) of the definition thereof, without the lapse of a period of 60 consecutive days) with respect to Hertz, the Trustee shall not have delivered such Demand Notice to Hertz or (3) there is a Preference Amount, the Trustee shall draw on the Series 2009-1 Letters of Credit, if any, by 12:00 p.m. (New York City time) on such Business Day in an amount equal to the lesser of (A) the amount that Hertz failed to pay under the Series 2009-1 Demand Note, the amount that the Trustee failed to demand for payment thereunder or the Preference Amount, as the case may be; and (B) the Series 2009-1 Letter of Credit Amount on such Business Day, by presenting to each Series 2009-1 Letter of Credit Provider a draft accompanied by a Series 2009-1 Certificate of Unpaid Demand Note Demand or, in the case of a Preference Amount, a Series 2009-1 Certificate of Preference Payment Demand; provided, however that if the Series 2009-1 Cash Collateral Account has been established and funded, the Trustee shall withdraw from the Series 2009-1 Cash Collateral Account and deposit in the Series 2009-1 Distribution Account an amount equal to the lesser of (x) the Series 2009-1 Cash Collateral Percentage on such Business Day of the lesser of the amounts set forth in clause (A) and (B) above and (y) the Series 2009-1 Available Cash Collateral Account Amount on such Business Day and draw an amount equal to the remainder of such amount on the Series 2009-1 Letters of Credit. The Trustee shall deposit, or cause the deposit of, the proceeds of any such draw on the Series 2009-1 Letters of Credit and the proceeds of any such withdrawal from the Series 2009-1 Cash Collateral Account into the Series 2009-1 Distribution Account and such proceeds shall be treated as Principal Collections.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!