Pole Owner’s Approval Process Sample Clauses

Pole Owner’s Approval Process. ‌ Pole Owner shall process permit Applications and provide Cost Estimates of the costs for Make- Ready Work in accordance with R746-345-3.C of the Utah Administrative Rules. If Licensee rejects the Cost Estimate, as discussed in R746-345-3.C., Licensee may, at its own expense and only as permitted by R746-345-3.C., exercise the self build option outlined in Section 4.06. After processing an Attachment Application, Pole Owner shall inform Licensee that the Application has been approved or denied by returning the Application with an appropriate notation to Licensee at the address set forth in Article XI. Any denial of an Application by Pole Owner shall be in writing and describe with specificity the lack of Pole capacity, safety or reliability problems, or generally applicable engineering standards that led to the denial of the Application. If notice of approval or denial of the Application is not received from Pole Owner within the time frames set forth in R746-345-3.C of the UAR, Licensee may appeal to the Commission for permission to proceed due to lack of response by Pole Owner; however, Licensee must receive permission from the Commission or written approval from Pole Owner before proceeding with the installation of the Attachments. Furthermore, Licensee may appeal to the Commission that Pole Owner’s stated reasons are insufficient grounds for rejection as allowed by UAR R746-345- 3. Rental charges for each approved Attachment shall commence as of the date of Pole Owner’s approval of the Application pursuant to the Rental Rate Schedule (Exhibit A) and the first charge for annual rent on the Attachment shall be due and payable at this time, with no abatement for the period of the current annual billing period prior to the Attachment approval. For illustrative purposes only, if the Attachment is approved in December and the current annual billing period is the prior July through the following June, for $100 per Attachment, Licensee shall be charged $100 in December for the new approved attachment and then $100 for the Attachment the following July for the next annual billing period.
Sample 1
AutoNDA by SimpleDocs

Related to Pole Owner’s Approval Process

  • Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.

  • Project Approval The County may issue a Job Order Authorization for the Work, to include the firm-fixed-price of the Job Order and the project duration. Contractor agrees that all clauses of this Contract are applicable to any Job Order issued hereunder. The County reserves the right to reject a Contractor’s Quote based on unjustifiable quantities and/or methods, performance periods, inadequate documentation, or other inconsistencies or deficiencies on the Contractor’s part in the sole opinion of the County. The County reserves the right to issue a unilateral Job Order authorization for the Work if a Quote price cannot be mutually agreed upon. This is based upon unjustifiable quantities in the sole opinion of the County. The County also reserves the right to not issue a Job Order Authorization if the County’s requirement is no longer valid or the project is not funded. In these instances, the Contractor has no right of claim to recover Quote expenses. The County may pursue continuing valid requirements by other means where Contract was not reached with the Contractor.

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

  • Project Approvals The Borrower will promptly obtain all Project approvals not heretofore obtained by the Borrower (including those listed and described on ­Exhibit “N” hereto and any other Project Approvals which may hereaf­ter become required, necessary or desirable) and will furnish the Lender with evidence that the Borrower has obtained such Project Approvals promptly upon its request. The Borrower will give all such notices to, and take all such other actions with respect to, such Governmental Authority as may be required under applicable Requirements to construct the Improvements and to use, occupy and operate the Project following the completion of the construction of the Improvements. The Borrower will also promptly obtain all utility installations and connections required for the operation and servicing of the Project for its intended purposes, and will furnish the Lender with evidence thereof. The Borrower will duly perform and comply with all of the terms and conditions of all Project Approvals obtained at any time, including all Project Approvals listed and described on Exhibit “Q” hereto.

  • Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!