Procedure for Time Extension Requests Sample Clauses

Procedure for Time Extension Requests. SAMPLE a. No time extensions will be allowed unless they are set forth in a Change Order which has been approved and executed by the Commission. b. The Design-Builder expressly consents to both the time requirements and notice content requirements for requesting an extension of time set forth in this Section 10.03.5. The Design-Builder acknowledges that the notice requirements set forth in this section 10.03.5 shall be strictly enforced and agrees that any failure on the part of the Design-Builder to provide notice strictly in accordance with the requirements of this Section 10.03.5 shall constitute a waiver of the Design-Builder’s right to seek an extension of time or to file a dispute to the Executive Director under Article 18. The Design-Builder further acknowledges that the time requirements and content requirements of Section 10.03.5 have the purpose, among others, of allowing the Commission Representative and Commission to evaluate the time extension request contemporaneously with the event that has been claimed to cause the delay. c. In order to request a Time Extension, a “Notice of Delay” or “Commencement of Delay” notice must be provided in writing to the Commission Representative, no more than five (5) calendar days after the commencement of the delay, otherwise the claim for the time extension is waived. A “Notice of Delay” shall be provided for a delay event that commenced and terminated within the five (5) day notice period. The Notice of Delay shall indicate the date of commencement of the delay and the date on which the delay terminated and shall include a brief description of the delaying event. d. A “Commencement of Delay” notice shall be provided for an event of delay that continues beyond the five (5) day period for providing notice. If the cause of the delay continues for more than five (5) calendar days after the start of the delay, a “Termination of Delay” notice must be provided in writing, to the Commission Representative along with the “Request for Time Extension” within ten (10) calendar days after the termination of the delay.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Procedure for Time Extension Requests a. No time extensions will be allowed unless they are set forth in a Change Order which has been approved and executed by the Commission. b. The Contractor expressly consents to both the time requirements and notice content requirements for requesting an extension of time set forth in this Section 10.03.
Sample 1

Related to Procedure for Time Extension Requests

  • Minimum Extension Requirement If (and only if) the total of the Revolving Credit Commitments of the Revolving Credit Lenders that have agreed so to extend their scheduled Termination Date and the additional Commitments of the Assuming Lenders shall be more than 50% of the aggregate amount of the Revolving Credit Commitments in effect immediately prior to the applicable Extension Date, then, effective as of such Extension Date, the scheduled Termination Date of each Extending Lender and of each Assuming Lender shall be extended to the date falling one year after the scheduled Termination Date in effect for such Lenders (except that, if such date is not a Business Day, such Termination Date as so extended shall be the next preceding Business Day) and each Assuming Lender shall thereupon become a “Revolving Credit Lender” for all purposes of this Agreement.

  • Procedure for Termination, Amendment, Extension or Waiver A termination of this Agreement pursuant to Section 7.01, an amendment of this Agreement pursuant to Section 7.03 or an extension or waiver of this Agreement pursuant to Section 7.04 shall, in order to be effective, require in the case of Parent, Sub or the Company, action by its Board of Directors.

  • Extension Request The Borrower shall provide the applicable Extension Request at least three (3) Business Days prior to the date on which Lenders under the Existing Term Loan Tranche or Existing Revolver Tranche, as applicable, are requested to respond, and shall agree to such procedures, if any, as may be established by, or acceptable to, the Administrative Agent, in each case acting reasonably to accomplish the purposes of this Section 2.16. No Lender shall have any obligation to agree to have any of its Term Loans of any Existing Term Loan Tranche amended into Extended Term Loans or any of its Revolving Credit Commitments amended into Extended Revolving Credit Commitments, as applicable, pursuant to any Extension Request. Any Lender holding a Loan under an Existing Term Loan Tranche (each, an “Extending Term Lender”) wishing to have all or a portion of its Term Loans under the Existing Term Loan Tranche subject to such Extension Request amended into Extended Term Loans and any Revolving Credit Lender (each, an “Extending Revolving Credit Lender”) wishing to have all or a portion of its Revolving Credit Commitments under the Existing Revolver Tranche subject to such Extension Request amended into Extended Revolving Credit Commitments, as applicable, shall notify the Administrative Agent (each, an “Extension Election”) on or prior to the date specified in such Extension Request of the amount of its Term Loans under the Existing Term Loan Tranche or Revolving Credit Commitments under the Existing Revolver Tranche, as applicable, which it has elected to request be amended into Extended Term Loans or Extended Revolving Credit Commitments, as applicable (subject to any minimum denomination requirements imposed by the Administrative Agent). In the event that the aggregate principal amount of Term Loans under the Existing Term Loan Tranche or Revolving Credit Commitments under the Existing Revolver Tranche, as applicable, in respect of which applicable Term Lenders or Revolving Credit Lenders, as the case may be, shall have accepted the relevant Extension Request exceeds the amount of Extended Term Loans or Extended Revolving Credit Commitments, as applicable, requested to be extended pursuant to the Extension Request, Term Loans or Revolving Credit Commitments, as applicable, subject to Extension Elections shall be amended to Extended Term Loans or Revolving Credit Commitments, as applicable, on a pro rata basis (subject to rounding by the Administrative Agent, which shall be conclusive) based on the aggregate principal amount of Term Loans or Revolving Credit Commitments, as applicable, included in each such Extension Election.

  • Procedure for Term Loan Borrowing (a) The U.S. Borrower shall give the Administrative Agent irrevocable notice (which notice must be received by the Administrative Agent prior to 12:00 Noon, New York City time), (a) three Business Days prior to the requested Borrowing Date, in the case of Eurodollar Loans (and accompanied by a funding indemnity letter in form and substance reasonably acceptable to the Administrative Agent) and (b) the date of the proposed Borrowing Date, in the case of ABR Loans requesting that the U.S. Term A Lenders make the U.S. Term A Loans on the Restatement Effective Date and specifying the amount to be borrowed. Upon receipt of such notice the Administrative Agent shall promptly notify each U.S. Term A Lender thereof. Not later than 12:00 Noon, New York City time, on the Restatement Effective Date each U.S. Term A Lender shall make available to the Administrative Agent at the Funding Office an amount in immediately available funds equal to the U.S. Term A Loan or U.S. Term A Loans to be made by such Lender. The Administrative Agent shall credit the account of the U.S. Borrower on the books of such office of the Administrative Agent with the aggregate of the amounts made available to the Administrative Agent by the U.S. Term A Lenders in immediately available funds. (b) The Canadian Borrower shall give the Administrative Agent irrevocable notice (which notice must be received by the Administrative Agent prior to 12:00 Noon, New York City time), (a) three Business Days prior to the requested Borrowing Date, in the case of CDOR Loans and (b) the date of the proposed Borrowing Date, in the case of Canadian Prime Rate Loans requesting that the Canadian Term A Lenders make the Canadian Term A Loans on the Restatement Effective Date and specifying the amount to be borrowed. Upon receipt of such notice the Administrative Agent shall promptly notify each Canadian Term A Lender thereof. Not later than 12:00 Noon, New York City time, on the Restatement Effective Date each Canadian Term A Lender shall make available to the Administrative Agent at the Funding Office an amount in immediately available funds equal to the Canadian Term A Loan or Canadian Term A Loans to be made by such Lender. The Administrative Agent shall credit the account of the Canadian Borrower on the books of such office of the Administrative Agent with the aggregate of the amounts made available to the Administrative Agent by the Canadian Term A Lenders in immediately available funds.

  • Notice of Extension (a) If the Property Trustee is the only registered holder of the Debentures at the time the Company selects an Extended Interest Payment Period, the Company shall give written notice to the Administrative Trustees, the Property Trustee and the Trustee of its selection of such Extended Interest Payment Period two Business Days before the earlier of (i) the next succeeding date on which Distributions on the Trust Securities issued by the Trust are payable; or (ii) the date the Trust is required to give notice of the record date, or the date such Distributions are payable, to The Nasdaq National Market or other applicable self-regulatory organization or to holders of the Preferred Securities issued by the Trust, but in any event at least one Business Day before such record date. (b) If the Property Trustee is not the only holder of the Debentures at the time the Company selects an Extended Interest Payment Period, the Company shall give the holders of the Debentures and the Trustee written notice of its selection of such Extended Interest Payment Period at least two Business Days before the earlier of (i) the next succeeding Interest Payment Date; or (ii) the date the Company is required to give notice of the record or payment date of such interest payment to The Nasdaq National Market or other applicable self-regulatory organization or to holders of the Debentures. (c) The quarter in which any notice is given pursuant to paragraphs (a) or (b) of this Section 4.2 shall be counted as one of the 20 quarters permitted in the maximum Extended Interest Payment Period permitted under Section 4.1.

  • Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:

  • Additional Termination Requirements (a) In the event the Master Servicer exercises its purchase option as provided in Section 9.01, the Trust Fund shall be terminated in accordance with the following additional requirements, unless the Trustee has been supplied with an Opinion of Counsel, at the expense of the Master Servicer, to the effect that the failure to comply with the requirements of this Section 9.03 will not (i) result in the imposition of taxes on "prohibited transactions" on any REMIC as defined in section 860F of the Code, or (ii) cause any REMIC to fail to qualify as a REMIC at any time that any Certificates are outstanding: (1) Within 90 days prior to the final Distribution Date set forth in the notice given by the Master Servicer under Section 9.02, the Master Servicer shall prepare and the Trustee, at the expense of the "tax matters person," shall adopt a plan of complete liquidation within the meaning of section 860F(a)(4) of the Code which, as evidenced by an Opinion of Counsel (which opinion shall not be an expense of the Trustee or the Tax Matters Person), meets the requirements of a qualified liquidation; and (2) Within 90 days after the time of adoption of such a plan of complete liquidation, the Trustee shall sell all of the assets of the Trust Fund to the Master Servicer for cash in accordance with Section 9.01. (b) The Trustee as agent for any REMIC hereby agrees to adopt and sign such a plan of complete liquidation upon the written request of the Master Servicer, and the receipt of the Opinion of Counsel referred to in Section 9.03(a)(1) and to take such other action in connection therewith as may be reasonably requested by the Master Servicer. (c) By their acceptance of the Certificates, the Holders thereof hereby authorize the Master Servicer to prepare and the Trustee to adopt and sign a plan of complete liquidation.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

  • Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants: a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals: (1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency; (2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and (4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.

  • ARBITRATION REQUIREMENT EXCEPT AS STATED BELOW, ANY DISPUTE BETWEEN YOU AND ANY OF US SHALL BE DECIDED BY NEUTRAL, BINDING ARBITRATION RATHER THAN IN COURT OR BY JURY TRIAL. “Dispute” will be given the broadest possible meaning allowable by law. It includes any dispute, claim, or controversy arising from or relating to your purchase of this heating or air conditioning unit, any warranty upon the unit, or the unit’s condition. It also includes determination of the scope or applicability of this Arbitration Clause. The arbitration requirement applies to claims in contract and tort, pursuant to statute, or otherwise.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!